Landlord will Sample Clauses

Landlord will supply for normal office use heat and air conditioning service, elevator service, janitorial and cleaning services, electricity, and hot and cold water, all in amounts and at times consistent with similar services provided in Class A office buildings in Upper Dublin Township, provided that: (i) Landlord will not be liable for failure to supply any such services for any cause beyond its control, or for any cause which in Landlord's judgment shall require the suspension of any such service for purposes of necessary or proper maintenance or repair of Building facilities; (ii) if Tenant requires janitorial and cleaning services beyond those provided by Landlord, Tenant shall arrange such additional services through Landlord, for which Tenant shall pay Landlord upon receipt of billing therefor; and (iii) if Tenant requires installation of additional heating, ventilating and/or air conditioning system, Tenant shall pay for the furnishing and installation thereof, and in addition shall pay the metered costs plus ten percent (10%) of such metered costs to compensate Landlord for its costs in respect of such separate system;
View Source
Landlord will. As an advisor to, and a representative of Tenant, provide administrative, management and related services as required to coordinate work of the entire team. Landlord will concentrate its efforts in the coordination of the Contractor, Subcontractor (s) and all other consultants contracted to perform services on the Project in order to complete the project in accordance with Tenant’s objectives for cost, time and quality.
View Source

Related to Landlord will

  • LANDLORD The covenants and obligations contained in this Lease on the part of Landlord are binding on Landlord, its successors, and assigns only during their respective period of ownership of an interest in the Building. In the event of any transfer or transfers of such title to the Building, Landlord (and, in the case of any subsequent transfers or conveyances, the then grantor) shall be concurrently freed and relieved from and after the date of such transfer or conveyance, without any further instrument or agreement, of all liability with respect to the performance of any covenants or obligations on the part of Landlord contained in this Lease thereafter to be performed.

  • Tenant Tenant shall not make any alterations to or modifications of the Leased Premises or construct any improvements within the Leased Premises until Landlord shall have first approved, in writing, the plans and specifications therefore, which approvals shall not be unreasonably withheld or delayed. Landlord's consent shall not be required for non-structural interior improvements costing less than $10,000 in any calendar year. Plans are required. All such modifications, alterations or improvements, once so approved, shall be made, constructed or installed by Tenant at Tenant's expense (including all permit fees and governmental charges related thereto), using a licensed contractor first approved by Landlord, in substantial compliance with the Landlord approved plans and specifications therefore. All work undertaken by Tenant shall be done in accordance with all Laws and in a good and workmanlike manner using new materials of good quality. Tenant shall not commence the making of any such modifications or alterations or the construction of any such improvements until (i) all required governmental approvals and permits shall have been obtained, (ii) all requirements regarding insurance imposed by this Lease have been satisfied, (iii) Tenant shall have given Landlord at least five business days prior written notice of its intention to commence such work so that Landlord may post and file notices of non-responsibility, and (iv) if requested by Landlord, Tenant shall have obtained contingent liability and broad form builder's risk insurance in an amount reasonably satisfactory to Landlord to cover any perils relating to the proposed work not covered by insurance carried by Tenant pursuant to Article 9. In no event shall Tenant make any modifications, alterations or improvements whatsoever to the Outside Areas or the exterior or structural components of the Building including, without limitation, any cuts or penetrations in the floor, roof or exterior walls of the Leased Premises without Landlord's approval which shall not be unreasonably withheld. As used in this Article, the term "modifications, alterations and/or improvements" shall include, without limitation, the installation of additional electrical outlets, overhead lighting fixtures, drains, sinks, partitions, doorways, or the like.

  • Landlord Repairs (a) Throughout the Term, Landlord shall diligently perform all repairs, maintenance and replacements required to keep the roof, foundation, floor slab, structural elements and exterior walls of the Premises in compliance with the Incentive Agreements and in a good, clean and safe condition, in proper working order at all times; except (i) Tenant shall be responsible for normal preventive maintenance of the roof of the Building to the extent expressly provided in Section 9.02, and (ii) Tenant shall be responsible for repairing the roof membrane and roof insulation as expressly provided in Section 9.02 (excluding the roof deck and trusses) from and after the end of the first (1st) Extension Period if Tenant exercises the second (2nd) Extension Option and the Term is extended as a result thereof. In addition, Landlord shall cause the Premises to comply with Applicable Laws as of the Delivery Date, including, but not limited to, the Americans with Disabilities Act, 42 U.S.C. § 12101, et seq., or any successor thereto. All repairs, maintenance and replacements to be made by Landlord under this Lease shall be completed in a good and workmanlike manner, in compliance with all Applicable Laws, and consistent with (or better than) the initial quality of Landlord’s Work. Landlord shall use its best efforts to perform all maintenance, repairs and replacements that are Landlord’s responsibility under this Section 9.01 in a manner that does not materially interfere with Tenant’s use and enjoyment of the Premises. (b) Landlord shall use reasonable efforts to enforce all manufacturer, supplier, contractor, subcontractor and other warranties and guaranties related to Landlord’s Work; provided if Landlord fails to enforce any such warranties or guaranties, Tenant may (but shall not be obligated to) enforce the same and Landlord shall cooperate, assist and join in such efforts. (c) If any repairs, maintenance or replacements are required to the roof, foundation, structural elements, floor slab or exterior walls of the Building as a result of damage to the Premises caused by Tenant or its Affiliates, agents, employees, contractors or representatives, excluding ordinary wear and tear and damage that is subject to the waiver set forth in Section 11.04, then Tenant shall reimburse Landlord for the third party actual, verifiable and reasonable cost of such repairs, maintenance or replacements, within sixty (60) days of Tenant’s receipt of a written demand for the same from Landlord, accompanied by reliable evidence of the costs for which reimbursement is sought.

  • Landlord Approval (Check one)

  • Landlord Improvements Prior to Tenant’s occupancy, Landlord shall complete the Landlord Improvements. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by the Anticipated Rent Commencement Date. (a) As of November 4, 2011, after consultation with Tenant, Landlord has provided Tenant with Landlord’s proposed plans and specifications (defined below in subpart (c))for the Landlord Improvements (such plans and specifications, as amended in accordance with the provisions of this Rider 101, are hereafter called “Plans and Specifications”). (b) The Plans and Specifications have been accepted by both Tenant and Landlord, the Plans and Specifications are incorporated herein by reference and made a part hereof for all purposes. (c) Landlord and Tenant acknowledge that the plans dated November 4, 2011, by Page ▇▇▇▇▇▇▇▇▇▇▇ Page, LLP have been approved by both parties and shall constitute the “Plans and Specifications.” (d) Promptly upon approval of the Plans and Specifications, Landlord has caused general contractors to bid for construction of the Landlord Improvements. All bids have been opened together, with Landlord selecting the general contractor with the lowest bid to construct the Landlord Improvements (the “General Contractor”), subject to the reasonable approval of Tenant. Landlord shall enter into a guaranteed maximum price construction contract with the General Contractor in the amount of its bid (the “Approved Bid”) and shall not modify such contract without Tenant’s consent, which shall not be unreasonably withheld, delayed or conditioned. Landlord and Tenant have reviewed the Plans and Specifications and the bids and have agreed upon the scope of work to be constructed at a cost of construction not to exceed the Landlord’s Contribution.