Specific Obligations The HSP:
Letters of Credit for Payment Bond Notwithstanding the provisions of B4.3, Purchaser may use letters of credit in lieu of a surety bond for payment bond purposes when approved by Contracting Officer.
Limited Obligations This Agreement does not create any obligation of the Securities Intermediary except for those expressly set forth in this Agreement. The Securities Intermediary may conclusively rely and shall be fully protected in acting or refraining from acting upon notices and communications it believes to be genuine and given by the appropriate party. Except for permitting a withdrawal, delivery or payment in violation of Article III, the Securities Intermediary shall not be liable to the Secured Party, the Servicer or the Issuer for any error of judgment made in good faith and in accordance with this Agreement, nor shall it otherwise be liable under this Agreement except as a result of its own willful misconduct, bad faith or negligence.
NOTICE TO UTAH BORROWERS This written agreement is a final expression of the agreement between you and the Credit Union. This written agreement may not be contradicted by evidence of any oral agreement.
Refinancing Preparation Advance; Capitalizing Front-end Fee and Interest (a) If the Loan Agreement provides for the repayment out of the proceeds of the Loan of an advance made by the Bank or the Association (“Preparation Advance”), the Bank shall, on behalf of such Loan Party, withdraw from the Loan Account on or after the Effective Date the amount required to repay the withdrawn and outstanding balance of the advance as at the date of such withdrawal from the Loan Account and to pay all accrued and unpaid charges, if any, on the advance as at such date. The Bank shall pay the amount so withdrawn to itself or the Association, as the case may be, and shall cancel the remaining unwithdrawn amount of the advance.”
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Commitment of Current Revenues Only In the event that, during any term hereof, the Commissioners Court does not appropriate sufficient funds to meet the obligations of County under this Agreement, County may terminate this Agreement upon ninety (90) days written notice to Company. County agrees, however, to use reasonable efforts to secure funds necessary for the continued performance of this Agreement. The parties intend this provision to be a continuing right to terminate this Agreement at the expiration of each budget period of County. Agreements for the acquisition, including lease of real or personal property under Tex. Loc. Govt. Code §271.903: In the event that, during any term hereof, the Commissioner’s Court does not appropriate sufficient funds to meet the obligations of County under this Agreement, County may terminate this Agreement upon ninety (90) days written notice to Company, County agrees, however, to use a best efforts attempt to obtain and appropriate funds for payment of the Agreement. The parties intend this provision, if applicable, to be a continuing right to terminate this at the expiration of each budget period of County in accordance with Tex. Loc. Govt. Code §271.903 (Xxxxxx Supp. 1996).
IMPACT ON CURRENT SERVICES (OR PROJECTS) There will be no negative impact on current County services or projects during the performance of the recommended services.
Review of Commitments The Parties shall enter into successive rounds of negotiations, beginning not later than three years from the date of entry into force of this Agreement, and periodically thereafter as determined by the FTA Joint Committee, with a view to further improving specific commitments under this Chapter so as to progressively liberalise trade in services among the Parties.
Specific Commitments Investments in respect of a particular undertaking of one of the Contracting Parties with respect to nationals and companies of the other Contracting Party shall be governed, without prejudice to the provisions of this Agreement, the terms of that commitment to the extent that it is more favourable provisions than those laid down in this Agreement.
