Professional Development; Adverse Consequences of School Exclusion; Student Behavior The Board President or Superintendent, or their designees, will make reasonable efforts to provide ongoing professional development to Board members about the adverse consequences of school exclusion and justice-system involvement, effective classroom management strategies, culturally responsive discipline, appropriate and available supportive services for the promotion of student attendance and engagement, and developmentally appropriate disciplinary methods that promote positive and healthy school climates, i.e., Senate Bill 100 training topics. The Board will conduct periodic self-evaluations with the goal of continuous improvement. New Board Member Orientation The orientation process for newly elected or appointed Board members includes:
Independence from Material Breach Determination Except as set forth in Section X.D.1.c, these provisions for payment of Stipulated Penalties shall not affect or otherwise set a standard for OIG’s decision that Xxxxx has materially breached this IA, which decision shall be made at OIG’s discretion and shall be governed by the provisions in Section X.D, below.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement through no fault of its own then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon. Upon delivering such notice, the obligation of the affected party, so far as it is affected by such Force Majeure as described, shall be suspended during the continuance of the inability then claimed but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. In the event that Vendor’s obligations are suspended by reason of Force Majeure, all TIPS Sales accepted prior to the Force Majeure event shall be the legal responsibility of Vendor and the terms of the TIPS Sale Supplemental Agreement shall control Vendor’s failure to fulfill for a Force Majeure event.
Labor Disputes and Acts of God Neither the business nor the properties of the Borrower or any Subsidiary or any Guarantor are affected by any fire, explosion, accident, strike, lockout, or other labor dispute, drought, storm, hail, earthquake, embargo, act of God or of the public enemy, or other casualty (whether or not covered by insurance), materially and adversely affecting such business or properties or the operation of the Borrower or such Subsidiary or such Guarantor.
Prevention or Delay in Performance by the Depositary or the Company Neither the Depositary nor the Company nor any of their respective directors, employees, agents or affiliates shall incur any liability to any Owner or Holder (i) if by reason of any provision of any present or future law or regulation of the United States or any other country, or of any governmental or regulatory authority or stock exchange, or by reason of any provision, present or future, of the articles of association or similar document of the Company, or by reason of any provision of any securities issued or distributed by the Company, or any offering or distribution thereof, or by reason of any act of God or war or terrorism or other circumstances beyond its control, the Depositary or the Company shall be prevented, delayed or forbidden from, or be subject to any civil or criminal penalty on account of, doing or performing any act or thing which by the terms of this Deposit Agreement or the Deposited Securities it is provided shall be done or performed, (ii) by reason of any non-performance or delay, caused as aforesaid, in the performance of any act or thing which by the terms of this Deposit Agreement it is provided shall or may be done or performed, (iii) by reason of any exercise of, or failure to exercise, any discretion provided for in this Deposit Agreement, (iv) for the inability of any Owner or holder to benefit from any distribution, offering, right or other benefit which is made available to holders of Deposited Securities but is not, under the terms of this Deposit Agreement, made available to Owners or holders, or (v) for any special, consequential or punitive damages for any breach of the terms of this Deposit Agreement. Where, by the terms of a distribution pursuant to Section 4.01, 4.02 or 4.03, or an offering or distribution pursuant to Section 4.04, or for any other reason, such distribution or offering may not be made available to Owners, and the Depositary may not dispose of such distribution or offering on behalf of such Owners and make the net proceeds available to such Owners, then the Depositary shall not make such distribution or offering, and shall allow any rights, if applicable, to lapse.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Termination for Force Majeure 15.5.1. The License Agreement may be terminated for Force Majeure Reasons as specified in Article -14.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
