Indemnification Limitation of Liability This Section 10 shall survive the termination of this Agreement.
a. The Participant hereby agrees to indemnify and hold harmless the Distributor, Trust, Funds, Transfer Agent and their respective subsidiaries, Affiliated Persons, directors, officers, employees and agents, and each person, if any, who controls such persons within the meaning of Section 15 of the 1933 Act (each a “Participant-Indemnified Party”) from and against any loss, liability, cost and expense (including reasonable attorneys’ fees, collectively “Losses”) incurred by such Participant-Indemnified Party as a result of (i) any breach by the Participant of any provision of this Agreement; (ii) any failure on the part of the Participant to perform any of its obligations set forth in this Agreement; (iii) any failure by the Participant to comply with applicable Law; (iv) representations by any Distributor-Indemnified Party or any Participant Client about the Shares or any Participant-Indemnified Party (including the Trust and/or Fund(s)) that is not included in the Trust’s then-current Prospectus; (v) any untrue statement or alleged untrue statement of a material fact contained in any Section 8.b Materials or any alleged omission to state therein a material fact required to be stated therein or necessary to make the statements therein, in light of the circumstances under which they were made, not misleading to the extent that such statement or omission relates to the Shares or any Participant-Indemnified Party unless, in either case, such representation, statement or omission was included by the Participant at the written direction of the Trust or the Distributor or taken verbatim (in context and without omission) from the Prospectus or marketing material approved by the Distributor and the Trust; and (vi) actions of such Participant-Indemnified Party in reliance upon any instructions issued to the Trust, the Distributor or the Transfer Agent reasonably believed by any of them to be genuine and to have been given by the Participant or an Authorized Person. The foregoing shall not apply to any Losses incurred by any Participant-Indemnified Party arising out of any Participant-Indemnified Party’s own fraud, bad faith, willful misconduct, gross negligence or reckless disregard of its duties hereunder.
b. The Distributor hereby agrees to indemnify and hold harmless the Participant, its respective subsidiaries, Affiliated Persons, directors, officers, employees and agents, and each person, if any, who controls such persons within the meaning of Section 15 of the 1933 Act (each a “Distributor-Indemnified Party”) from and against any Losses incurred by such Distributor-Indemnified Party as a result of (i) any breach by the Distributor of any provision of this Agreement; (ii) any failure on the part of the Distributor to perform any of its obligations set forth in this Agreement; (iii) any failure by the Distributor to comply with applicable Law; (iv) any untrue statement or alleged untrue statement of a material fact contained in the Prospectus or any alleged omission to state therein a material fact required to be stated therein or necessary to make the statements therein, in light of the circumstances under which they were made, not misleading, other than any statement made or omitted in reliance upon information provided to the Distributor, the Trust or any other person on behalf of the Trust or the Fund by a Distributor-Indemnified Party in writing and (v) actions of such Distributor-Indemnified Party in reliance upon any instructions reasonably believed by the Participant to be genuine and to have been given by the Distributor. The foregoing shall not apply to any Losses incurred by any Distributor-Indemnified Party arising out of any Distributor-Indemnified Party’s own fraud, bad faith, willful misconduct, gross negligence or reckless disregard of its duties hereunder.
c. Notwithstanding anything to the contrary in this Agreement, the Distributor, the Transfer Agent and the Fund will not indemnify the Participant for any violations of the U.S. federal or state securities laws (or other applicable Law) committed by the Participant through its failure to deliver a Prospectus in connection with the offer or sale of Shares and for any oral or written representation or warranty by Participant that is not contained in the Prospectus.
d. Notwithstanding anything to the contrary in this Agreement, none of the Participant, Distributor, Trust or Transfer Agent shall be liable to each other for any Losses under this Agreement arising out of (i) mistakes or errors in data provided in connection with Orders, except for data provided by the other or (ii) mistakes or errors by or out of interruptions or delays of communications with a service provider to the Trust.
e. Each of the Participant, Distributor and Transfer Agent undertakes to perform such duties and only such duties as are expressly set forth herein, or expressly incorporated herein by reference, and no implied covenants or obligations shall be read into this Agreement.
f. In the absence of fraud, bad faith, gross negligence, willful misconduct, or reckless disregard on its part, neither the Distributor nor the Transfer Agent, whether acting directly or through agents or attorneys, shall be liable for any action taken or omitted, or for any error of judgment made, in the performance of their duties hereunder.
g. In no event shall any Party be liable for special, indirect or consequential loss or damage of any kind whatsoever (including but not limited to lost profits), even if advised of the likelihood of such loss or damage and regardless of the form of action. In no event shall any Party be liable under this Agreement to another Party for the acts or omissions of the CNS Clearing Process, DTC, NSCC, the Custodian or any securities depository, clearing corporation, exchange or communications service.
h. None of the Distributor, the Transfer Agent or the Trust shall be liable for any failure or delay in the performance of its obligations or those of its agents under this Agreement arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including without limitation: acts of God; earthquakes; extreme weather events, including blizzards, hurricanes, tornados thunder storms, fires and floods; wars; civil or military disturbances; blackouts; terrorism; breakdowns in communications systems; riots; loss or malfunction of utilities or computer or internet services; labor disputes; acts of any civil, military or governmental authority.
i. Neither the Transfer Agent nor the Distributor shall be required to advance, expend or risk its own funds or otherwise incur or become exposed to financial liability in the performance of its duties hereunder.
Disclaimer; Limitation of Liability IN NO EVENT WILL COMPANY BE LIABLE TO YOU FOR (A) ANY SPECIAL, INCIDENTAL, INDIRECT, PUNITIVE, EXEMPLARY, CONSEQUENTIAL, OR EXTRA- CONTRACTUAL DAMAGES OF ANY KIND; OR (B) ANY LOSS OF DATA OR BUSINESS, DIMINUTION IN VALUE, LOSS OF PROFITS OR REVENUE, OR BUSINESS INTERRUPTION, REGARDLESS OF LEGAL THEORY (INCLUDING, BUT NOT LIMITED TO, NEGLIGENCE), WHETHER OR NOT FORESEEABLE, EVEN IF WE HAVE BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. EXCEPT TO THE EXTENT LIMITED BY APPLICABLE LAW, AND REGARDLESS OF THE BASIS FOR ANY CLAIM BY YOU (EVEN IF BASED ON NEGLIGENCE), OUR MAXIMUM AGGREGATE LIABILITY UNDER OR RELATED TO THIS AGREEMENT OR ITS SUBJECT MATTER IS LIMITED TO $50.00 USD. THE LIMITATIONS IN THIS SECTION 5 (DISCLAIMER; LIMITATION OF LIABILITY) WILL APPLY NOTWITHSTANDING A FAILURE OF ESSENTIAL PURPOSE. YOU ARE SOLELY RESPONSIBLE FOR ANY CONTENT, APPLICATION OR NON- COMPANY SOFTWARE THAT YOU LOAD INTO OR CREATE WITHIN THE EVALUATION ENVIRONMENT, AND AGREE, AT YOUR SOLE COST AND EXPENSE, TO DEFEND US AGAINST ANY CLAIM AND INDEMNIFY US FROM ANY DAMAGES, LIABILITIES, COSTS AND EXPENSES OR THE SETTLEMENT AGREED TO BY YOU, ARISING OUT OF OR IN ANY WAY CONNECTED WITH ANY SUCH CONTENT, APPLICATION OR NON- COMPANY SOFTWARE. WE ARE NOT RESPONSIBLE FOR THE SECURITY OF ANY CONTENT, APPLICATION OR SOFTWARE THAT YOU LOAD INTO OR CREATE WITHIN THE EVALUATION ENVIRONMENT.
Limitation of Liability No provision hereof, in the absence of any affirmative action by the Holder to exercise this Warrant to purchase Warrant Shares, and no enumeration herein of the rights or privileges of the Holder, shall give rise to any liability of the Holder for the purchase price of any Common Stock or as a stockholder of the Company, whether such liability is asserted by the Company or by creditors of the Company.
Disclaimers and Limitation of Liability EXCEPT AS EXPRESSLY SET FORTH HEREIN, ALL SERVICES TO BE PROVIDED BY FLG AND FLG MEMBER (FOR PURPOSES OF THIS PARAGRAPH 6, COLLECTIVELY “FLG”) HEREUNDER ARE PROVIDED “AS IS” WITHOUT ANY WARRANTY WHATSOEVER. CLIENT RECOGNIZES THAT THE “AS IS” CLAUSE OF THIS AGREEMENT IS AN IMPORTANT PART OF THE BASIS OF THIS AGREEMENT, WITHOUT WHICH FLG WOULD NOT HAVE AGREED TO ENTER INTO THIS AGREEMENT. FLG EXPRESSLY DISCLAIMS ALL OTHER WARRANTIES, TERMS OR CONDITIONS, WHETHER EXPRESS, IMPLIED, OR STATUTORY, REGARDING THE PROFESSIONAL SERVICES, INCLUDING ANY, WARRANTIES OF MERCHANTABILITY, TITLE, FITNESS FOR A PARTICULAR PURPOSE AND INFRINGEMENT. NO REPRESENTATION OR OTHER AFFIRMATION OF FACT REGARDING THE SERVICES PROVIDED HEREUNDER SHALL BE DEEMED A WARRANTY FOR ANY PURPOSE OR GIVE RISE TO ANY LIABILITY OF FLG WHATSOEVER. IN NO EVENT SHALL FLG BE LIABLE FOR ANY INCIDENTAL, INDIRECT, EXEMPLARY, SPECIAL, PUNITIVE OR CONSEQUENTIAL DAMAGES, UNDER ANY CIRCUMSTANCES, INCLUDING, BUT NOT LIMITED TO: LOST PROFITS; REVENUE OR SAVINGS; WAIVER BY CLIENT, WHETHER INADVERTENT OR INTENTIONAL, OF CLIENT’S ATTORNEY-CLIENT PRIVILEGE THROUGH CLIENT’S DISCLOSURE OF LEGALLY PRIVILEGED INFORMATION TO FLG; OR THE LOSS, THEFT, TRANSMISSION OR USE, AUTHORIZED OR OTHERWISE, OF ANY DATA, EVEN IF CLIENT OR FLG HAVE BEEN ADVISED OF, KNEW, OR SHOULD HAVE KNOWN, OF THE POSSIBILITY THEREOF. NOTWITHSTANDING ANYTHING IN THIS AGREEMENT TO THE CONTRARY, FLG’S AGGREGATE CUMULATIVE LIABILITY HEREUNDER, WHETHER IN CONTRACT, TORT, NEGLIGENCE, MISREPRESENTATION, STRICT LIABILITY OR OTHERWISE, SHALL NOT EXCEED AN AMOUNT EQUAL TO THE LAST TWO (2) MONTHS OF FEES PAYABLE BY CLIENT UNDER PARAGRAPH 2(A) OF THIS AGREEMENT. CLIENT ACKNOWLEDGES THAT THE COMPENSATION PAID BY IT UNDER THIS AGREEMENT REFLECTS THE ALLOCATION OF RISK SET FORTH IN THIS AGREEMENT AND THAT FLG WOULD NOT ENTER INTO THIS AGREEMENT WITHOUT THESE LIMITATIONS ON ITS LIABILITY. THIS PARAGRAPH SHALL NOT APPLY TO EITHER PARTY WITH RESPECT TO A BREACH OF ITS CONFIDENTIALITY OBLIGATIONS.
A. As a condition for recovery of any amount by Client against FLG, Client shall give FLG written notice of the alleged basis for liability within ninety (90) days of discovering the circumstances giving rise thereto, in order that FLG will have the opportunity to investigate in a timely manner and, where possible, correct or rectify the alleged basis for liability; provided that the failure of Client to give such notice will only affect the rights of Client to the extent that FLG is actually prejudiced by such failure. Notwithstanding anything herein to the contrary, Client must assert any claim against FLG by the sooner of: (i) ninety (90) days after discovery; (ii) ninety (90) days after the termination of this Agreement; (iii) ninety (90) days after the last date on which the Services were performed; or, (iv) sixty (60) days after completion of a financial or accounting audit for the period(s) to which a claim pertains.
LIMITATION OF LIABILITY OF THE TRUSTEES AND SHAREHOLDERS A copy of the Agreement and Declaration of Trust of the Trust is on file with the Secretary of The Commonwealth of Massachusetts, and notice is hereby given that this instrument is executed on behalf of the Trustees of the Trust as Trustees and not individually and that the obligations of this instrument are not binding upon any of the Trustees or shareholders individually but are binding only upon the assets and property of the Fund.
LIMITATION OF LIABILITY OF ADVISER You may rely on information reasonably believed by you to be accurate and reliable. Except as may otherwise be required by the 1940 Act or the rules thereunder, neither you nor your shareholders, members, officers, directors, employees, agents, control persons or affiliates of any thereof shall be subject to any liability for, or any damages, expenses or losses incurred by the Trust in connection with, any error of judgment, mistake of law, any act or omission connected with or arising out of any services rendered under, or payments made pursuant to, this Agreement or any other matter to which this Agreement relates, except by reason of willful misfeasance, bad faith or gross negligence on the part of any such persons in the performance of your duties under this Agreement, or by reason of reckless disregard by any of such persons of your obligations and duties under this Agreement. Any person, even though also a director, officer, employee, member, shareholder or agent of you, who may be or become an officer, director, trustee, employee or agent of the Trust, shall be deemed, when rendering services to the Trust or acting on any business of the Trust (other than services or business in connection with your duties hereunder), to be rendering such services to or acting solely for the Trust and not as a director, officer, employee, member, shareholder or agent of you, or one under your control or direction, even though paid by you.
Disclaimer and Limitation of Liability PROVIDER DISCLAIMS ALL WARRANTIES, EXPRESS,IMPLIED, STATUTORY OR ARISING FROM A COURSE OF DEALING OR PERFORMANCE OR CUSTOM, WITH RESPECT TO THE SERVICES, EQUIPMENT, AND ANY OTHER PROVIDER PRODUCTS, SERVICES OR EQUIPMENT PROVIDED HEREUNDER, INCLUDING, BUT NOT LIMITED TO, WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, PERFORMANCE IN A XXXXXXX-LIKE MANNER, COMPLIANCE WITH LAWS, QUALITY, ACCURACY, COMPLETENESS OR CURRENCY OF INFORMATION, SYSTEM INTEGRABILITY, TITLE, QUIET ENJOYMENT AND NON-INFRINGEMENT. PROVIDERDOES NOT REPRESENT, WARRANT OR COVENANT THAT THE PRODUCTS, SERVICES OR EQUIPMENT PROVIDED WILL OPERATE UNINTERRUPTED, ERROR FREE OR WITHOUT DEGRADATION OR LOSS OF DATA, OR BE SECURE. NEITHER PROVIDER NOR ITS SERVICE PROVIDERS WILL BE LIABLE FOR UNAUTHORIZED ACCESS TO OR ALTERATION, THEFT OR DESTRUCTION OF CUSTOMER’S OR A USER’S DATA FILES, PROGRAMS, PROCEDURES OR INFORMATION, INCLUDING, WITHOUT LIMITATION, ANY SUCH DATA IN PROVIDER’S POSSESSION, CUSTODY OR CONTROL, THROUGH ACCIDENT, FRAUDULENT MEANS OR DEVICES, OR ANY OTHER METHOD, REGARDLESS OF WHETHER SUCH DAMAGE OCCURS AS A RESULT OF PROVIDER’S OR ITS SERVICE PROVIDER’S NEGLIGENCE. IN NO EVENT WILL PROVIDER OR ITS AFFILIATE, SERVICE PROVIDER, FACILITY OPERATOR OR CARRIER, OR THEIR RESPECTIVE OWNERS, DIRECTORS, MANAGERS, OFFICERS, EMPLOYEES OR AGENTS (COLLECTIVELY, “PROVIDER PARTIES”) BE LIABLE FOR ANY DIRECT, ACTUAL, INDIRECT, CONSEQUENTIAL, SPECIAL, PUNITIVE OR OTHER DAMAGES, OR FOR ANY COST OF COVER OR LOST PROFITS OF ANY KIND OR NATURE WHATSOEVER, ARISING FROM OR RELATED TO THIS AGREEMENT OR A PROVIDER PARTY’S PERFORMANCE OR NONPERFORMANCE OF OBLIGATIONS HEREUNDER, A FAILURE OF OR A DEFECT IN THE SERVICES, EQUIPMENT OR ANY PRODUCT, A PROVIDER PARTY’S VIOLATION OF A THIRD PARTY’S RIGHT, OR A PROVIDER PARTY’S ACTS OR OMISSIONS. PROVIDER WILL NOT BE LIABLE FOR THE ACTS OR OMISSIONS OF, A FAILURE OF OR A DEFECT IN ANY PRODUCT OR SERVICE PROVIDED BY, OR VIOLATION OF ANY THIRD PARTY’S RIGHTS BY ANY THIRD-PARTY SERVICE PROVIDER, FACILITY OPERATOR OR CARRIER. THE PROVIDER PARTIES’ MAXIMUM TOTAL LIABILITY TO CUSTOMER WILL NOT EXCEED THE AMOUNTS PAID BY CUSTOMER TO PROVIDER IN THE THREE (3) MONTHS PRECEDING THE DATE THE CLAIM ACCRUED. THE PROVIDER PARTIES WILL NOT BE LIABLE IN ANY WAY TO ANY USER.
Limitation of Liability of Sub-Adviser The Sub-Adviser shall not be liable for any error of judgment or mistake of law or for any loss suffered by the Trust or the Fund or the Adviser in connection with the matters to which this Agreement relates, except a loss resulting from willful misfeasance, bad faith or gross negligence on the Sub-Adviser's part in the performance of its duties or from reckless disregard by it of its obligations and duties under this Agreement. Any person, even though also employed by the Sub-Adviser, who may be or become an employee of and paid by the Trust or the Fund shall be deemed, when acting within the scope of his employment by the Trust or the Fund, to be acting in such employment solely for the Trust or the Fund and not as the Sub-Adviser's employee or agent.
Exclusion and Limitation of Liability 10.1 SUPPLIER DOES NOT EXCLUDE OR LIMIT ITS LIABILITY (IF ANY) TO BUYER FOR ANY MATTER FOR WHICH IT WOULD BE ILLEGAL FOR SUPPLIER TO EXCLUDE OR LIMIT OR TO ATTEMPT TO EXCLUDE OR LIMIT ITS LIABILITY.
10.2 OTHER THAN ANY LIABILITY OF SUPPLIER ARISING UNDER CLAUSE 10.1, WHICH SHALL NOT BE LIMITED, AND WITHOUT PREJUDICE TO THE OTHER PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY), SUPPLIER'S AGGREGATE LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) UNDER EACH CONTRACT WILL BE LIMITED TO AN AMOUNT EQUAL TO THE GREATER OF 115% OF THE AMOUNT PAID BY BUYER TO SUPPLIER UNDER THAT CONTRACT OR $10,000.00.
10.3 EXCEPT AS PROVIDED IN CLAUSE 10.1, SUPPLIER WILL BE UNDER NO LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) TO BUYER WHATSOEVER IN RESPECT OF
10.3.1 ANY CLAIM ARISING OUT OF AN EVENTWHICH IS CAUSED, OR CONTRIBUTED TO, BY THE GOODS AND SUCH EVENT OCCURS AFTER THE COMMENCEMENT OF THE LAUNCH PROCEDURE OF THE VEHICLE CARRYING SUCH GOODS INTO SPACE;
10.3.2 PURE ECONOMIC LOSS, LOSS OF PROFITS, LOSS OF BUSINESS, LOSS OF REVENUE, LOSS OF CONTRACTS, LOSS OF GOODWILL, LOSS OF ANTICIPATED EARNINGS OR SAVINGS (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.3 LOSS OF USE OR VALUE OR DAMAGE OF ANY DATA OR EQUIPMENT (INCLUDING SOFTWARE), WASTED MANAGEMENT, OPERATION OR OTHER TIME (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.4 ANY SPECIAL, INDIRECT, PUNITIVE, INCIDENTAL OR CONSEQUENTIAL LOSS, IN EACH CASE HOWSOEVER CAUSED ARISING OUT OF OR IN CONNECTION WITH:
10.3.5 ANY OF THE WORKS, OR THE MANUFACTURE OR SALE OR SUPPLY, OR FAILURE OR DELAY IN SUPPLY, OF THE WORKS BY SUPPLIER OR ON THE PART OF SUPPLIER’S EMPLOYEES, AGENTS OR SUBCONTRACTORS;
10.3.6 ANY BREACH BY SUPPLIER OF ANY OF THE EXPRESS OR IMPLIED TERMS OF THE CONTRACT;
10.3.7 ANY USE MADE OR RESALE BY BUYER OF ANY OF THE WORKS, OR OF ANY PRODUCT INCORPORATING ANY OF THE WORKS; OR
10.3.8 ANY STATEMENT MADE OR NOT MADE, OR ADVICE GIVEN OR NOT GIVEN, BY OR ON BEHALF OF SUPPLIER.
10.4 EXCEPT AS EXPRESSLY SET OUT IN THE CONTRACT, SUPPLIER HEREBY EXCLUDES TO THE FULLEST EXTENT PERMISSIBLE IN LAW, ALL CONDITIONS, WARRANTIES AND STIPULATIONS, EXPRESS (OTHER THAN THOSE SET OUT IN THE CONTRACT) OR IMPLIED, STATUTORY, CUSTOMARY OR OTHERWISE WHICH, BUT FOR SUCH EXCLUSION, WOULD OR MIGHT SUBSIST IN FAVOR OF BUYER, INCLUDING, WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE.
10.5 EACH OF SUPPLIER’S EMPLOYEES, AGENTS AND SUBCONTRACTORS MAY RELY UPON AND ENFORCE THE EXCLUSIONS AND RESTRICTIONS OF LIABILITY IN THE CONTRACT IN THAT PERSON’S OWN NAME AND FOR THAT PERSON’S OWN BENEFIT, AS IF THE WORDS “ITS EMPLOYEES, AGENTS AND SUBCONTRACTORS” FOLLOWED THE WORD SUPPLIER WHEREVER IT APPEARS IN THOSE CLAUSES SAVE FOR EACH REFERENCE IN CLAUSE10.3.5.
10.6 BUYER ACKNOWLEDGES THAT THE ABOVE PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY) ARE REASONABLE AND REFLECTED IN THE PRICE WHICH WOULD BE HIGHER WITHOUT THOSE PROVISIONS, AND BUYER WILL ACCEPT SUCH RISK AND/OR INSURE ACCORDINGLY.
10.7 BUYER IS SOLELY RESPONSIBLE AND LIABLE FOR THE PROPER LEGAL DISPOSAL OF ALL MATERIALS PURCHASED FROM SUPPLIER AT THE END-OF- LIFE CYCLE OF SUCH MATERIALS.
Limitation of Liability of Trustees and Shareholders The Adviser acknowledges the following limitation of liability:
