Limited Assignment of Construction Contract. Limited Assignment of Construction Contract means the Agreement so-named between Project Co, Hospital and Contractor respecting the assignment of this Contract by Project Co to Hospital.
Limited Assignment of Construction Contract Sample Clauses
Related to Limited Assignment of Construction Contract
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Amendment or Assignment of Agreement Any amendment to this Agreement shall be in writing signed by the parties hereto; PROVIDED, that no such amendment shall be effective unless authorized (i) by resolution of the Trustees of the Trust, including the vote or written consent of a majority of the Trustees of the Trust who are not parties to this Agreement or interested persons of either party hereto, and (ii) by vote of a majority of the outstanding voting securities of the Fund affected by such amendment as required by applicable law. This Agreement shall terminate automatically and immediately in the event of its assignment.
Assignment of Contract A. Unless expressly agreed to elsewhere in the Contract, no assignment by a party hereto of any rights under or interests in the Contract will be binding on another party hereto without the written consent of the party sought to be bound; and, specifically but without limitation, money that may become due and money that is due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents.
Construction of Contract Both parties have participated fully in the review and revision of this contract. Any rule of construction to the effect that ambiguities are to be resolved against the drafting party shall not apply to the interpretation of this contract.
Commencement and Completion of Construction Subject to Unavoidable Delays, Developer shall cause construction of the Minimum Improvements to be undertaken and completed: (i) by no later than June 1, 2020; or (ii) by such other date as the parties shall mutually agree upon in writing. Time lost as a result of Unavoidable Delays shall be added to extend this date by a number of days equal to the number of days lost as a result of Unavoidable Delays. All work with respect to the Minimum Improvements shall be in conformity with the Construction Plans approved by the building official or any amendments thereto as may be approved by the building official. Developer agrees that it shall permit designated representatives of the City, upon reasonable notice (which does not have to be written), to enter upon the Development Property during the construction of the Minimum Improvements to inspect such construction and the progress thereof.
Commencement of Construction Construction of the Project will start within thirty (30) days after notification to the Developer by the Owner, or as soon thereafter as weather and ground conditions permit.
Governing Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the laws of the State of New York. The section headings in this Agreement have been inserted as a matter of convenience of reference and are not a part of this Agreement.
Deed; Xxxx of Sale; Assignment To the extent required and permitted by applicable law, this Agreement shall also constitute a “deed,” “xxxx of sale” or “assignment” of the assets and interests referenced herein.
Change of Control; Assignment and Subcontracting Except as set forth in this Section 7.5, neither party may assign any of its rights and obligations under this Agreement without the prior written approval of the other party, which approval will not be unreasonably withheld. For purposes of this Section 7.5, a direct or indirect change of control of Registry Operator or any subcontracting arrangement that relates to any Critical Function (as identified in Section 6 of Specification 10) for the TLD (a “Material Subcontracting Arrangement”) shall be deemed an assignment. (a) Registry Operator must provide no less than thirty (30) calendar days advance notice to ICANN of any assignment or Material Subcontracting Arrangement, and any agreement to assign or subcontract any portion of the operations of the TLD (whether or not a Material Subcontracting Arrangement) must mandate compliance with all covenants, obligations and agreements by Registry Operator hereunder, and Registry Operator shall continue to be bound by such covenants, obligations and agreements. Registry Operator must also provide no less than thirty (30) calendar days advance notice to ICANN prior to the consummation of any transaction anticipated to result in a direct or indirect change of control of Registry Operator. (b) Within thirty (30) calendar days of either such notification pursuant to Section 7.5(a), ICANN may request additional information from Registry Operator establishing (i) compliance with this Agreement and (ii) that the party acquiring such control or entering into such assignment or Material Subcontracting Arrangement (in any case, the “Contracting Party”) and the ultimate parent entity of the Contracting Party meets the ICANN-‐adopted specification or policy on registry operator criteria then in effect (including with respect to financial resources and operational and technical capabilities), in which case Registry Operator must supply the requested information within fifteen (15) calendar days. (c) Registry Operator agrees that ICANN’s consent to any assignment, change of control or Material Subcontracting Arrangement will also be subject to background checks on any proposed Contracting Party (and such Contracting Party’s Affiliates). (d) If ICANN fails to expressly provide or withhold its consent to any assignment, direct or indirect change of control of Registry Operator or any Material Subcontracting Arrangement within thirty (30) calendar days of ICANN’s receipt of notice of such transaction (or, if ICANN has requested additional information from Registry Operator as set forth above, thirty (30) calendar days of the receipt of all requested written information regarding such transaction) from Registry Operator, ICANN shall be deemed to have consented to such transaction. (e) In connection with any such assignment, change of control or Material Subcontracting Arrangement, Registry Operator shall comply with the Registry Transition Process. (f) Notwithstanding the foregoing, (i) any consummated change of control shall not be voidable by ICANN; provided, however, that, if ICANN reasonably determines to withhold its consent to such transaction, ICANN may terminate this Agreement pursuant to Section 4.3(g), (ii) ICANN may assign this Agreement without the consent of Registry Operator upon approval of the ICANN Board of Directors in conjunction with a reorganization, reconstitution or re-‐incorporation of ICANN upon such assignee’s express assumption of the terms and conditions of this Agreement, (iii) Registry Operator may assign this Agreement without the consent of ICANN directly to a wholly-‐owned subsidiary of Registry Operator, or, if Registry Operator is a wholly-‐owned subsidiary, to its direct parent or to another wholly-‐owned subsidiary of its direct parent, upon such subsidiary’s or parent’s, as applicable, express assumption of the terms and conditions of this Agreement, and (iv) ICANN shall be deemed to have consented to any assignment, Material Subcontracting Arrangement or change of control transaction in which the Contracting Party is an existing operator of a generic top-‐level domain pursuant to a registry agreement between such Contracting Party and ICANN (provided that such Contracting Party is then in compliance with the terms and conditions of such registry agreement in all material respects), unless ICANN provides to Registry Operator a written objection to such transaction within ten (10) calendar days of ICANN’s receipt of notice of such transaction pursuant to this Section 7.5. Notwithstanding Section 7.5(a), in the event an assignment is made pursuant to clauses (ii) or (iii) of this Section 7.5(f), the assigning party will provide the other party with prompt notice following any such assignment.
Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.
