Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
Fees and Other Charges (a) The Borrower will pay a fee on all outstanding Letters of Credit at a per annum rate equal to the Applicable Margin then in effect with respect to Eurodollar Loans under the Revolving Facility, shared ratably among the Revolving Lenders and payable quarterly in arrears on each Fee Payment Date after the issuance date. In addition, the Borrower shall pay to the Issuing Lender for its own account a fronting fee of 0.25% per annum on the undrawn and unexpired amount of each Letter of Credit, payable quarterly in arrears on each Fee Payment Date after the issuance date.
PAYMENT OF OTHER HOUSING CANCELLATION FEES AND OTHER ASSESSMENTS Except for rental charges, all housing charges, including but not limited to cancellation fees, rekey fees, and any other non-rental housing charge are due and payable when billed.
COMMISSIONS, CHARGES AND OTHER COSTS 23.1. The provision of services is subject to the payment of costs, fees, commissions, charges, taxes, etc (the “Costs”). In addition to those Costs, other costs may be due by the Client directly to third parties. The Client shall be obliged to pay all such costs the commissions, charges and other costs set. Costs to the Company are set out in the Company Website.
Rent and Other Payments This paragraph contains detailed commercial terms. ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ .
Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.
Reimbursement of Legal Fees and Expenses and Other Expenses Upon the occurrence of an Event of Default hereunder by the Company or any Sponsor Affiliate, should the County be required to employ attorneys or incur other reasonable expenses for the collection of payments due hereunder or for the enforcement of performance or observance of any obligation or agreement, the County shall be entitled, within thirty (30) days of demand therefor, to reimbursement of the reasonable fees of such attorneys and such other reasonable expenses so incurred.
Payment of Taxes and Other Expenses Should City, in its discretion, or a relevant taxing authority such as the Internal Revenue Service or the State Employment Development Division, or both, determine that Contractor is an employee for purposes of collection of any employment taxes, the amounts payable under this Agreement shall be reduced by amounts equal to both the employee and employer portions of the tax due (and offsetting any credits for amounts already paid by Contractor which can be applied against this liability). City shall then forward those amounts to the relevant taxing authority. Should a relevant taxing authority determine a liability for past services performed by Contractor for City, upon notification of such fact by City, Contractor shall promptly remit such amount due or arrange with City to have the amount due withheld from future payments to Contractor under this Agreement (again, offsetting any amounts already paid by Contractor which can be applied as a credit against such liability). A determination of employment status pursuant to the preceding two paragraphs shall be solely for the purposes of the particular tax in question, and for all other purposes of this Agreement, Contractor shall not be considered an employee of City. Notwithstanding the foregoing, should any court, arbitrator, or administrative authority determine that Contractor is an employee for any other purpose, then Contractor agrees to a reduction in City’s financial liability so that City’s total expenses under this Agreement are not greater than they would have been had the court, arbitrator, or administrative authority determined that Contractor was not an employee.
SETTLEMENT AND OTHER EXPENSES A. The following expenses must be paid at or prior to closing:
Damages and Costs You agree to pay for damages, lost property or extraordinary service or administrative costs you, your designated roommate or your guests cause to University residence facilities whether through accident, neglect or intent. See Appendix II for more information about assessments. All residents of a floor or unit may be assessed for cleaning, damages, lost property or extraordinary service costs where the person(s) responsible cannot be ascertained by the University but where the damages, lost property, or excessive mess were reasonably believed by Student Housing and Hospitality Services to be caused by one or more residents of a floor or unit. Where charges and costs have not been paid by the specified date, a late fee will be added. Failure to pay assessments may result in the relocation of you or other resident(s) to another floor or unit, denial of future residence assignment or eviction from residence. To appeal an assessment you must follow the written appeal procedure outlined on the assessment form. Appeals will only be considered if you are not in arrears for any other fees, charges or amounts owed to Student Housing and Hospitality Services.
