Liquidated Damages for Failure to Satisfy Certain Performance Guarantees Sample Clauses

Liquidated Damages for Failure to Satisfy Certain Performance Guarantees. Contractor acknowledges that if the Project does not achieve the Net Capacity Guarantee and the Net Heat Rate Guarantee, Owner will suffer substantial damages that are difficult to ascertain. Therefore, the Parties agree that if the Project does not achieve the Net Capacity Guarantee, as calculated in accordance with Part I, Section 8.2.1 of the Scope Book, Contractor shall pay liquidated damages to Owner in the amount of *** Dollars ($***) per kilowatt for each kilowatt by which the Project fails to satisfy the Net Capacity Guarantee. The Parties further agree that if the Project does not achieve the Net Heat Rate Guarantee, as calculated in accordance with Part I, Section 8.2.2 of the Scope Book, Contractor shall pay liquidated damages to Owner in the amount of *** Dollars ($***) per Btu/kilowatt for each Btu/kilowatt by which the Project exceeds the Net Heat Rate Guarantee. In addition, the Parties agree that if the Project does not achieve (i) the Ammonia Consumption Rate Guarantee, as calculated in accordance with Part I, Section 8.1.4 of the Scope Book, Contractor shall pay liquidated damages to Owner in the amount of *** Dollars ($***) per lb/hour for each lb/hour by which the Project exceeds the Ammonia Consumption Rate Guarantee, and (ii) the Limestone Consumption Rate Guarantee, as calculated in accordance with Part I, Section 8.1.3 of the Scope Book, Contractor shall pay liquidated damages to Owner in the amount of *** Dollars ($***) per lb/hour for each lb/hour by which the Project exceeds the Limestone Consumption Rate Guarantee. The Parties agree that the foregoing liquidated damages described in this Section 15.3 with respect to failure of the Project to achieve the Net Capacity Guarantee, the Net Heat Rate Guarantee, the Ammonia Consumption Rate Guarantee, or the Limestone Consumption Rate Guarantee shall apply regardless of the actual amount of damage that may be suffered. Performance Liquidated Damages that are ultimately determined to be due and owing shall accrue interest at the Contract Interest Rate as of the date such amounts should have been paid if undisputed, from such date until paid.
Sample 1
AutoNDA by SimpleDocs

Related to Liquidated Damages for Failure to Satisfy Certain Performance Guarantees

  • Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.

  • Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.

  • Default in Performance of Certain Covenants Any Borrower or any other Credit Party shall default in the performance or observance of any covenant or agreement contained in Sections 7.1, 7.2 or 7.4(a)(i)(A) or Articles IX or X.

  • Failure to Satisfy Conditions If the Secured Party or its Custodian fails to satisfy any conditions for holding Posted Collateral, then upon a demand made by the Pledgor, the Secured Party will, not later than five Local Business Days after the demand, Transfer or cause its Custodian to Transfer all Posted Collateral held by it to a Custodian that satisfies those conditions or to the Secured Party if it satisfies those conditions.

  • Investor’s Rights and Remedies Cumulative; Liquidated Damages All rights, remedies, and powers conferred in this Agreement and the Transaction Documents are cumulative and not exclusive of any other rights or remedies, and shall be in addition to every other right, power, and remedy that Investor may have, whether specifically granted in this Agreement or any other Transaction Document, or existing at law, in equity, or by statute, and any and all such rights and remedies may be exercised from time to time and as often and in such order as Investor may deem expedient. The parties acknowledge and agree that upon Company’s failure to comply with the provisions of the Transaction Documents, Investor’s damages would be uncertain and difficult (if not impossible) to accurately estimate because of the parties’ inability to predict future interest rates and future share prices, Investor’s increased risk, and the uncertainty of the availability of a suitable substitute investment opportunity for Investor, among other reasons. Accordingly, any fees, charges, and default interest due under the Note and the other Transaction Documents are intended by the parties to be, and shall be deemed, liquidated damages (under Company’s and Investor’s expectations that any such liquidated damages will tack back to the Closing Date for purposes of determining the holding period under Rule 144 under the 1933 Act). The parties agree that such liquidated damages are a reasonable estimate of Investor’s actual damages and not a penalty, and shall not be deemed in any way to limit any other right or remedy Investor may have hereunder, at law or in equity. The parties acknowledge and agree that under the circumstances existing at the time this Agreement is entered into, such liquidated damages are fair and reasonable and are not penalties. All fees, charges, and default interest provided for in the Transaction Documents are agreed to by the parties to be based upon the obligations and the risks assumed by the parties as of the Closing Date and are consistent with investments of this type. The liquidated damages provisions of the Transaction Documents shall not limit or preclude a party from pursuing any other remedy available at law or in equity; provided, however, that the liquidated damages provided for in the Transaction Documents are intended to be in lieu of actual damages.

  • Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.

  • Events Excusing Performance Neither party shall be liable to the other party for failure to perform any of the services required herein in the event of strikes, lock-outs, calamities, acts of God, unavailability of supplies or other events over which that party has no control for so long as such events continue, and for a reasonable period of time thereafter.

  • FAILURE TO MAKE OTHER PAYMENTS The failure by the Borrower to pay when due (or upon demand, if payable on demand) any payment Liability other than under the Revolving Credit.

  • Failure to Fulfill Conditions In the event that either of the parties hereto determines that a condition to its respective obligations to consummate the transactions contemplated hereby cannot be fulfilled on or prior to the termination of this Agreement, it will promptly notify the other party.

  • Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.

Time is Money Join Law Insider Premium to draft better contracts faster.