Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Maintenance and Support NCR Voyix is solely responsible for providing any maintenance and support services with respect to the Software as specified in the Agreement, or as required under applicable law. The parties acknowledge that Apple has no obligation whatsoever to furnish any maintenance and support services with respect to the Software.
Network Maintenance and Management 38.1 The Parties will work cooperatively to implement this Agreement. The Parties will exchange appropriate information (for example, maintenance contact numbers, network information, information required to comply with law enforcement and other security agencies of the government, escalation processes, etc.) to achieve this desired result.
38.2 Each Party will administer its network to ensure acceptable service levels to all users of its network services. Service levels are generally considered acceptable only when End Users are able to establish connections with little or no delay encountered in the network. Each Party will provide a twenty four (24)-hour contact number for Network Traffic Management issues to the other’s surveillance management center.
38.3 Each Party maintains the right to implement protective network traffic management controls, such as “cancel to”, “call gapping” or seven (7)-digit and ten (10)-digit code gaps, to selectively cancel the completion of traffic over its network, including traffic destined for the other Party’s network, when required to protect the public-switched network from congestion as a result of occurrences such as facility failures, switch congestion or failure or focused overload. Each Party shall immediately notify the other Party of any protective control action planned or executed.
38.4 Where the capability exists, originating or terminating traffic reroutes may be implemented by either Party to temporarily relieve network congestion due to facility failures or abnormal calling patterns. Reroutes shall not be used to circumvent normal trunk servicing. Expansive controls shall be used only when mutually agreed to by the Parties.
38.5 The Parties shall cooperate and share pre-planning information regarding cross-network call-ins expected to generate large or focused temporary increases in call volumes to prevent or mitigate the impact of these events on the public-switched network, including any disruption or loss of service to the other Party’s End Users. Facsimile (FAX) numbers must be exchanged by the Parties to facilitate event notifications for planned mass calling events.
38.6 Neither Party shall use any Interconnection Service provided under this Agreement or any other service related thereto or used in combination therewith in any manner that interferes with or impairs service over any facilities of AT&T-21STATE, its affiliated companies or other connecting telecommunications carriers, prevents any carrier from using its Telecommunications Service, impairs the quality or the privacy of Telecommunications Service to other carriers or to either Party’s End Users, causes hazards to either Party’s personnel or the public, damage to either Party’s or any connecting carrier’s facilities or equipment, including any malfunction of ordering or billing systems or equipment. Upon such occurrence either Party may discontinue or refuse service, but only for so long as the other Party is violating this provision. Upon any such violation, either Party shall provide the other Party notice of the violation at the earliest practicable time.
38.7 AT&T TENNESSEE hereby commits to provide Disaster Recovery to CLEC according to the plan below.
38.7.1 AT&T TENNESSEE Disaster Recovery Plan
38.7.2 In the unlikely event of a disaster occurring that affects AT&T TENNESSEE’s long-term ability to deliver traffic to a CLEC, general procedures have been developed by AT&T TENNESSEE to hasten the recovery process in accordance with the Telecommunications Service Priority (TSP) Program established by the FCC to identify and prioritize telecommunication services that support national security or emergency preparedness (NS/EP) missions. A description of the TSP Program as it may be amended from time to time is available on AT&T TENNESSEE’s Wholesale – Southeast Region Web site. Since each location is different and could be affected by an assortment of potential problems, a detailed recovery plan is impractical. However, in the process of reviewing recovery activities for specific locations, some basic procedures emerge that appear to be common in most cases.
38.7.3 These general procedures should apply to any disaster that affects the delivery of traffic for an extended time period. Each CLEC will be given the same consideration during an outage, and service will be restored as quickly as possible. AT&T TENNESSEE reserves the right to make changes to these procedures as improvements become available or as business conditions dictate.
38.7.4 This plan will cover the basic recovery procedures that would apply to every CLEC.
Maintenance and Repairs (1) Except for matters specified under Paragraph 4 above and Paragraph 8A(3) below as being Landlord's obligation, Tenant shall, at Tenant's sole cost and expense, maintain the Premises in good order, condition and repair, ordinary wear and tear and damage by fire and casualty excepted, including: the interior surfaces of the ceilings, walls and floors; all doors and interior windows; furnishings installed within the Premises; all equipment installed by or at the expense of Tenant; and all plumbing, heating, ventilating, electrical and lighting facilities and fixtures; all landscaping, parking lots, fences and signs located within the Premises.
(2) In the event that Tenant fails to maintain the Premises in good order, condition and repair as required under this Lease, Landlord shall give Tenant prior written notice to do such acts as are required to so maintain the Premises. In the event that Tenant fails to commence such work within 30 days after written demand by Landlord, and diligently prosecute it to completion, then Landlord shall have the right, but shall not be obligated, to do such acts and expend such funds at the expense of Tenant as are reasonably required to perform such work. Landlord shall have no liability to Tenant for any reasonable damage, inconvenience or interference with Tenant's use of the Premises as a result of performing any such work.
(3) Landlord will maintain, repair and replace all structural components of the Premises and the roof of the Building, and if a repair, replacement or alteration or other change would be considered a capital improvement or replacement to the Premises under generally accepted accounting principles, then it shall be Landlord's responsibility to promptly make and pay for such repair, replacement, alteration or other change. The cost of any such capital improvement shall be amortized over the useful life of such item and Tenant agrees to pay its percentage share (which shall be determined by dividing the square footage of the Building by the square footage of all buildings benefitted by such improvement, including the Building) of the annual amortized amount. Such payment will be made by Tenant as set forth in Paragraph 4 above. Landlord shall do all acts required to comply with all applicable laws, ordinances, regulations and rules of any public authority relating to the Premises, except to the extent that the foregoing are solely a result of Tenant's use of the Premises. Tenant shall do all acts required to comply with all applicable laws, ordinances, regulations and rules of any public authority relating solely to Tenant's use of the Premises. If a repair is required as a result of Tenant's negligence and such repair cost is not covered by insurance proceeds, Tenant will pay for the cost of such repair. Notwithstanding anything in this Lease to the contrary, in the event that the need for repairs or the making of repairs (or both) which Landlord is obligated to effect at Landlord's expense renders a material portion of the Premises unusable for more than three consecutive business days, then Tenant shall be entitled to an abatement of rent commencing with the fourth business day that the same are unusable; provided, however, that Tenant shall not be entitled to a pro rata abatement of rent under the foregoing due to unusability (i) caused directly or indirectly by any act or omission of Tenant or any of Tenant's servants, employees, agents, contractors, visitors or licensees, (ii) where Tenant makes a decoration, alteration, improvement or addition which directly causes such unusability, or (iii) where the repair in question is one which Tenant is obligated to furnish under the provisions of this Lease.
Maintenance, Etc The Company will maintain, preserve and keep, and will cause each Consolidated Subsidiary to maintain, preserve and keep, its properties which are used in the conduct of its business (whether owned in fee or a leasehold interest) in good repair and working order, ordinary wear and tear excepted, and from time to time will make all necessary repairs, replacements and renewals as the Company may determine to be appropriate to the conduct of its business.
Maintenance and Inspection Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to this Agreement. Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement.
Maintenance and Operation Member-Generator agrees to maintain their system and facilities in accordance with applicable manufacturer's recommended maintenance schedule and standard prudent engineering practices. Member-Generator covenants and agrees to operate their system, facilities and equipment so as to minimize the likelihood for a malfunction or other disturbance, damaging or otherwise affecting or impairing Cooperative’s electrical system. Member-Generator shall comply with all applicable laws, regulations, zoning, building codes, safety rules and other environmental regulations or restrictions applicable to the design, installation, operation and maintenance of the Member-Generator's System.
Maintenance and Insurance (a) The Company shall maintain or cause to be maintained, at its own expense, all of its assets and properties in good working order and condition, making all necessary repairs thereto and renewals and replacements thereof.
(b) The Company shall maintain or cause to be maintained, at its own expense, insurance in form, substance and amounts (including deductibles), which the Company deems reasonably necessary to the Company's business, (i) adequate to insure all assets and properties of the Company, which assets and properties are of a character usually insured by persons engaged in the same or similar business against loss or damage resulting from fire or other risks included in an extended coverage policy; (ii) against public liability and other tort claims that may be incurred by the Company; (iii) as may be required by the Transaction Documents and/or applicable law and (iv) as may be reasonably requested by Secured Party, all with adequate, financially sound and reputable insurers.
MAINTENANCE AND REPAIR; RULES Tenant will, at its sole expense, keep and maintain the Premises and appurtenances in good and sanitary condition and repair during the term of this Agreement and any renewal thereof. Without limiting the generality of the foregoing, Tenant shall:
(a) Not obstruct the driveways, sidewalks, courts, entry ways, stairs and/or halls, which shall be used for the purposes of ingress and egress only;
(b) Keep all windows, glass, window coverings, doors, locks and hardware in good, clean order and repair;
(c) Not obstruct or cover the windows or doors;
(d) Not leave windows or doors in an open position during any inclement weather;
(e) Not hang any laundry, clothing, sheets, etc. from any window, rail, porch or balcony nor air or dry any of same within any yard area or space;
(f) Not cause or permit any locks or hooks to be placed upon any door or window without the prior written consent of Landlord;
(g) Keep all air conditioning filters clean and free from dirt;
(h) Keep all lavatories, sinks, toilets, and all other water and plumbing apparatus in good order and repair and shall use same only for the purposes for which they were constructed. Tenant shall not allow any sweepings, rubbish, sand, rags, ashes or other substances to be thrown or deposited therein. Any damage to any such apparatus and the cost of clearing stopped plumbing resulting from misuse shall be borne by Tenant;
(i) And Tenant's family and guests shall at all times maintain order in the Premises and at all places on the Premises, and shall not make or permit any loud or improper noises, or otherwise disturb other residents;
(j) Keep all radios, television sets, stereos, phonographs, etc., turned down to a level of sound that does not annoy or interfere with other residents;
(k) Deposit all trash, garbage, rubbish or refuse in the locations provided therefor and shall not allow any trash, garbage, rubbish or refuse to be deposited or permitted to stand on the exterior of any building or within the common elements;
(l) Abide by and be bound by any and all rules and regulations affecting the Premises or the common area appurtenant thereto which may be adopted or promulgated by the Condominium or Homeowners' Association having control over them.
Record Maintenance and Retention A. Grantee shall keep and maintain under GAAP or GASB, as applicable, full, true, and complete records necessary to fully disclose to the System Agency, the Texas State Auditor’s Office, the United States Government, and their authorized representatives sufficient information to determine compliance with the terms and conditions of this Grant Agreement and all state and federal rules, regulations, and statutes.
B. Grantee shall maintain and retain legible copies of this Grant Agreement and all records relating to the performance of the Grant Agreement, including supporting fiscal documents adequate to ensure that claims for grant funds are in accordance with applicable State of Texas requirements. These records shall be maintained and retained by the Grantee for a minimum of seven (7) years after the Grant Agreement expiration date or seven (7) years after all audits, claims, litigation or disputes involving the Grant Agreement are resolved, whichever is later.
