Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.
Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof.
6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement.
6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement.
6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER.
6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing.
6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8.
6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.
Inspection Checklist (Check one)
Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:
Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.
Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.
Material Project Documents (a) The Company shall at all times (i) perform and observe all of the covenants under the Material Project Documents to which it is a party and take reasonable actions to enforce all of its rights thereunder, other than to the extent the same could not reasonably be expected to have a Material Adverse Effect, (ii) subject to the provisions of clause (b) of this Section 9.8, maintain the System Leases (other than Leases constituting System Leases only pursuant to clause (5) of the definition thereof) in full force and effect, and (iii) maintain the Leases (other than the System Leases referred to in the foregoing clause (ii) of this Section 9.8(a)) to which it or any of its Subsidiaries is a party in full force and effect, except to the extent the same could not reasonably be expected to have a Material Adverse Effect.
(b) If the term of a Lease with the Company or one of its Subsidiaries expires and the Qualified Lessee under such Lease has either ceased operating the related assets or has ceased paying rent as required under the applicable Lease, the Company shall, or shall cause a Subsidiary, as applicable, to enter into a supplement or a new Lease with respect to the related leasehold assets with a Qualified Lessee that provides for rent that, when combined with all other expected revenue, will, in the reasonable judgment of the Company, as of the commencement date of such supplement or new Lease, generate sufficient revenue to satisfy the requirements of Section 9.9 and will not otherwise result in a materially worse position for the Company as compared to the terms of the applicable expired Lease. Each such new Lease shall have a term of at least five years. Notwithstanding the foregoing, if (i) such expired Lease relates to transmission and/or distribution assets that are not generating significant revenue, (ii) the failure to renew such Lease would not constitute a Material Adverse Effect and (iii) the Company reasonably believes it will generate sufficient revenue and hold sufficient assets (without giving effect to the leasehold assets with respect to such Lease) to satisfy the requirements of Section 9.9, then this Section 9.8(b) will not require a supplement or new lease with respect to such leasehold assets.
Substantial Completion 9.8.1 When the Contractor considers that the Work, or a designated portion thereof which has been accepted in writing to by the State, is substantially complete as defined in Subparagraph
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.
