Milestone Requirements Sample Clauses

Milestone Requirements. To ensure compliance with the required deadlines in Section 2(d) for the HTI Operational System to become operational to the full extent required to deliver the PASS Service in accordance with Section 2 of this Agreement, and the PASS Service to become available to all Subscribers, HTI shall meet each of the specific milestone requirements identified in the attached Exhibit N by the respective dates set forth therein (“Milestone Requirements”); provided, however, that HTI shall not be responsible for any delay in meeting a Milestone Requirement to the extent the delay results from any action or failure under a duty to act on the part of DCC or any change in the Technical Specifications required by DCC and HTI could not reasonably avoid, overcome or mitigate the effect of the delay in order to meet the Milestone Requirement.
AutoNDA by SimpleDocs
Milestone Requirements. (a) The Licensees will use their commercially reasonable best efforts to construct, or to have constructed, a demonstration Licensee Plant (the Demonstration Plant) in the Territory within [***] after the Effective Date. The Demonstration Plant, as completed, must (i) have a Nameplate Capacity (as adjusted to reflect changes in the Nameplate Capacity from the date of the execution of the License Agreement to the commencement of operation of the Licensee Plant) of no more than [***] US gallons of ethanol through use of the Licensor Technology; and (ii) be used for demonstration and research and development purposes only and may not otherwise use, sell or distribute any product therefrom, or manufacture any product for commercial use, sale or distribution. Licensees will be deemed to have satisfied their obligations under this Section 2.5(a) if, in lieu of a Demonstration Plant, they construct within [***] after the Effective Date a fully-functioning Licensee Plant. (b) At least one License Agreement for the Licensor Technology must be executed by Licensor and a Licensee (with respect to a Licensee Plant or the Demonstration Plant), or by Licensee and a third party (with respect to a Plant for an Ethanol Project or a Sugar Project), within [***] after the Effective Date (the Initial Marketing Period). (c) During the term of this Agreement, at least one additional License Agreement for the Licensor Technology must be executed by Licensor and a Licensee (with respect to a Licensee Plant or the Demonstration Plant), or by a Licensee and a third party (with respect to a Plant for an Ethanol Project or a Sugar Project), during each [***] period following the Initial Marketing Period); provided that if neither Licensor nor any licensee of the Licensor Technology (other than the Licensees) has constructed, anywhere in the world, a Plant and commenced commercial production of ethanol therein prior to the expiration of the Initial Marketing Period, the Initial Marketing Period will be extended until the date of such commencement of commercial ethanol production at such a Plant. (d) Failure to comply with Section 2.5(a), (b) or (c) will result in immediate conversion of all exclusive rights granted to Licensees in Section 2.1 to non-exclusive rights. (e) Throughout the term of this Agreement, the Licensees will each provide Licensor with reasonably detailed, periodic summary reports on the progress and plans for meeting the Milestone Requirements, such reports to be p...
Milestone Requirements. To ensure compliance with the required deadlines in Section 2(f) for the HTI Operational System to become operational to the full extent required to deliver the PASS Services and the MBTA Services in accordance with Section 2 of this Agreement, and the PASS Services and the MBTA Services to become available to all Subscribers, HTI shall meet each Material Milestone Obligation identified in the attached Exhibit N by the respective dates set forth therein (“Milestone Requirements”) or else pay the applicable penalties set forth, if any, for each milestone in Exhibit N; provided, however, that HTI shall not be responsible for any delay in meeting a Milestone Requirement to the extent the delay directly results from any action or failure under a duty to act on the part of MBUSA or any change in the Technical Specifications required by MBUSA and which delay HTI could not reasonably avoid, overcome or mitigate in order to meet the Milestone Requirement.
Milestone Requirements. To ensure compliance with the required deadlines in Section 2(f) for the HTI Operational System to become operational to the full extent required to deliver the PASS Services and the MBTA Services in accordance with Section 2 of this Agreement, and the PASS Services and the MBTA Services to become available to all Subscribers, HTI shall meet each Material Milestone Obligation identified in the attached Exhibit N by the respective dates set forth therein (“Milestone Requirements”) ***; provided, however, that HTI shall not be responsible for any delay in meeting a Milestone Requirement to the extent the delay directly results from any action or failure under a duty to act on the part of MBUSA or any change in the Technical Specifications required by MBUSA and which delay HTI could not reasonably avoid, overcome or mitigate in order to meet the Milestone Requirement.
Milestone Requirements. The Discharger agrees that this Stipulation includes the Milestone Requirements set forth below. The Discharger acknowledges that credit for completing any Milestone Requirement is dependent on the Regional Water Board’s or its delegate’s adoption of this Stipulation as an Order. The implementation schedule for completion of the CP is as follows: Milestone Deadline
Milestone Requirements. Section 6.11 is amended in its entirety and replaced with the following:
Milestone Requirements. (a) At all times prior to the occurrence of the 2022 Equity Event, Borrower shall be required to (i) achieve the Milestone Event, and (ii) maintain unrestricted and unencumbered cash in accounts in the name of Borrower with Bank in an aggregate amount of greater than Twenty Million Dollars ($20,000,000.00) ((i) and (ii) collectively, the “Milestone Requirement”). If Borrower fails to comply with the Milestone Requirement prior to the occurrence of the 2022 Equity Event (which failure in and of itself is not an Event of Default) (the “Trigger Event”), Borrower shall immediately deposit into the Cash Collateral Account unrestricted and unencumbered cash in an amount of at least one hundred percent (100.0%) of the outstanding Obligations of Borrower to Bank (other than Obligations under Bank Services Agreements that are cash collateralized in accordance with Section 4.1 of this Agreement) as of the date of the Trigger Event (as determined by Bank), to secure all of the Obligations of Borrower to Bank (other than Obligations under Bank Services Agreements that are cash collateralized in accordance with Section 4.1 of this Agreement) (a “Cash Collateralization”). For the avoidance of doubt, the receipt by Borrower of negative data for the PRISM Trial, as determined by Bank in its sole and absolute discretion, constitutes a Trigger Event. Borrower hereby authorizes and directs Bank to transfer to the Cash Collateral Account an amount equal to one hundred percent (100.0%) of the outstanding Obligations of Borrower to Bank (other than Obligations under Bank Services Agreements that are cash collateralized in accordance with Section 4.1 of this Agreement) as of the date of the Trigger Event (as determined by Bank) if Borrower fails to effect a Cash Collateralization as required under this Section 6.11(a), it being understood that the foregoing authorization shall constitute an immediate Cash Collateralization, irrespective of any delay by Bank in effecting such transfer, to the extent that sufficient Borrower funds are then available for Bank to effect such transfer. Borrower further authorizes Bank, at the election of Bank, in Bank’s sole and absolute discretion, to apply the funds held in the Cash Collateral Account on account of the outstanding Obligations of Borrower to Bank (the “Paydown Payment”). For the avoidance of doubt, the Paydown Payment shall not be subject to the Prepayment Premium. Notwithstanding the foregoing, upon Bank’s receipt of evidence from ...
AutoNDA by SimpleDocs

Related to Milestone Requirements

  • Performance Requirements A. There is no guaranteed minimum amount of work which will be ordered under this Contract. B. The total Contract amount will not exceed $4,900,000. C. This is a Contract for work specified in individual Job Orders. Work ordered prior to but not completed by the expiration of the Contract period, and any additional work required as a result of unforeseen conditions encountered during construction up to six (6) months after the contract expiration date, will be completed with all provisions of this Contract still in force. Performance time for each Job Order issued under this Contract will be determined in accordance with the Contract. This performance time will be determined and agreed upon by both Parties for each individual Job Order. Contractor must self-perform 20% of the Work under this Contract for ‘A’ and ‘B’ licenses. Contractor must self-perform 75% of the Work under this Contract, unless otherwise approved by the County, for ‘C’ licenses. D. This is an indefinite-quantity Contract for the supplies or services specified and effective for the period stated. Work or performance shall be made only as authorized by Job Orders issued in accordance with the ordering procedures clause. The Contractor agrees to furnish to the County when and if ordered, the supplies or services specified in the Contract up to and including the quantity designated in the Job Orders issued as the maximum designated in the Contract.

  • Project Requirements 1. Project must conform to regulations under 24 CFR Part 92, commonly known as the HOME Regulations.

  • License Requirements The Hotel’s alcoholic beverage license requires that the Hotel shall: (i) request proper identification (photo ID) of any person of questionable age and refuse alcoholic beverage service if the person is either under age or proper identification cannot be produced, and (ii) refuse alcoholic beverage service to any person who, in the Hotel’s judgment, appears to be intoxicated; and (iii) instruct its personnel to avoid encouraging patrons to consume alcoholic beverages (commonly referred to as “over-pouring”).

  • Service Requirements Grantee shall:

  • Time Requirements The Independent Contractor will not be required to follow or establish a regular or daily work schedule, but shall devote during the term of this Agreement the time, energy and skill as necessary to perform the services of this engagement and shall, periodically or at any time upon the request of the Company, submit information as to the amount of time worked and scope of work performed.

  • Basic Requirements To be eligible for PayPal’s Seller Protection program, all of the following basic requirements must be met, as well as any applicable additional requirements: • The primary address for your PayPal account must be in the United States. • The item must be a physical, tangible good that can be shipped, except for items subject to the Intangible Goods Additional Requirements. Transactions involving items that you deliver in person in connection with payment made in your physical store, may also be eligible for PayPal’s Seller Protection program so long as the buyer paid for the transaction in person by using a PayPal goods and services QR code. • You must ship the item to the shipping address on the Transaction Details page in your PayPal account for the transaction. If you originally ship the item to the recipient’s shipping address on the Transaction Details page but the item is later redirected to a different address, you will not be eligible for PayPal’s Seller Protection program. We therefore recommend not using a shipping service that is arranged by the buyer, so that you will be able to provide valid proof of shipping and delivery. • The shipping requirement does not apply to eligible transactions involving items that you deliver in person; provided, however, that you agree to provide us with alternative evidence of delivery or such additional documentation or information relating to the transaction that we may request. • You must respond to PayPal’s requests for documentation and other information in a timely manner as requested in our email correspondence with you or in our correspondence with you through the Resolution Center. If you do not respond to PayPal’s request for documentation and other information in the time requested, you may not be eligible for PayPal’s Seller Protection program. • If the sale involves pre-ordered or made-to-order goods, you must ship within the timeframe you specified in the listing. Otherwise, it is recommended that you ship all items within 7 days after receipt of payment. • You provide us with valid proof of shipment or delivery. • The payment must be marked “eligible” or “partially eligible” in the case of Unauthorized Transaction claims, or “eligible” in the case of Item Not Received claims, for PayPal’s Seller Protection program on the Transaction Details page. • In the case of an Unauthorized Transaction claim, you must provide valid proof of shipment or proof of delivery that demonstrates that the item was shipped or provided to the buyer no later than two days after PayPal notified you of the dispute or reversal. For example, if PayPal notifies you of an Unauthorized Transaction claim on September 1, the valid proof of shipment must indicate that the item was shipped to the buyer no later than September 3 to be eligible for PayPal’s Seller Protection program. PayPal determines, in its sole discretion, whether your claim is eligible for PayPal’s Seller Protection program. PayPal will make a decision, in its sole discretion, based on the eligibility requirements, any information or documentation provided during the resolution process, or any other information PayPal deems relevant and appropriate under the circumstances. To be eligible for PayPal’s Seller Protection program for a buyer’s Item Not Received claim, you must meet both the basic requirements and the additional requirements listed below: • Where a buyer files a chargeback with the issuer for a card-funded transaction, the payment must be marked “eligible” for PayPal’s Seller Protection on the Transaction Details page. • You must provide proof of delivery as described below.

  • Sublicense Requirements Any Sublicense: (A) is subject to this Agreement; (B) will reflect that any sublicensee will not further sublicense; (C) will prohibit sublicensee from paying royalties to an escrow or other similar account; (D) will expressly include the provisions of Sections 8, 9, and 10 for the benefit of Stanford; and (E) will include the provisions of Section 4.4 and require the transfer of all the sublicensee’s obligations to *****, including the payment of royalties specified in the Sublicense, to Stanford or its designee, if this Agreement is terminated. If the sublicensee is a spin-out from *****, ***** must guarantee the sublicensee’s performance with respect to the payment of Stanford’s share of Sublicense royalties.

  • Interface Requirements 2.4.5.1 The NID shall be equal to or better than all of the requirements for NIDs set forth in the applicable industry standard technical references.

  • Notice Requirements A. All notices given by Xxxxxxx shall be in writing, include the Grant Agreement contract number, comply with all terms and conditions of the Grant Agreement, and be delivered to the System Agency’s Contract Representative identified above. B. Grantee shall send legal notices to System Agency at the address below and provide a copy to the System Agency’s Contract Representative: Health and Human Services Commission Attn: Office of Chief Counsel 0000 X. Xxxxxxxxx, Mail Code 1100 Austin, Texas 78751 C. Notices given by System Agency to Grantee may be emailed, mailed or sent by common carrier. Email notices shall be deemed delivered when sent by System Agency. Notices sent by mail shall be deemed delivered when deposited by the System Agency in the United States mail, postage paid, certified, return receipt requested. Notices sent by common carrier shall be deemed delivered when deposited by the System Agency with a common carrier, overnight, signature required. D. Notices given by Grantee to System Agency shall be deemed delivered when received by System Agency. E. Either Party may change its Contract Representative or Legal Notice contact by providing written notice to the other Party.

  • Compliance Requirements A. Nondiscrimination. The Contractor agrees to comply, and to require its subcontractor(s) to comply, with the nondiscrimination provisions of MCL 37.2209. The Contractor further agrees to comply with the provisions of Section 9:158 of Chapter 112 of the Xxx Arbor City Code and to assure that applicants are employed and that employees are treated during employment in a manner which provides equal employment opportunity.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!