Additional Indemnification Provisions (a) With respect to each indemnification obligation under this Agreement (i) each such obligation shall be calculated on an After-Tax Basis and (ii) all Losses shall be net of any third-party insurance proceeds that have been recovered or are recoverable by the Indemnified Party in connection with the facts giving rise to the right of indemnification.
(b) If an Indemnifying Party makes any payment for any Losses suffered or incurred by an Indemnified Party pursuant to the provisions of this Article VII, such Indemnifying Party shall be subrogated, to the extent of such payment, to all rights and remedies of the Indemnified Party to any insurance benefits or other claims of the Indemnified Party with respect to such Losses and with respect to the claim giving rise to such Losses.
(c) The right to indemnification or other remedy based on any representations, warranties, obligations, covenants and agreements set forth in this Agreement or in any of the Ancillary Agreements, will not be affected by any investigation conducted with respect to, or any notice or knowledge acquired (or capable of being acquired), with respect to the accuracy or inaccuracy of or compliance with, any such representation, warranty, covenant or agreement; provided, however, that notwithstanding anything to the contrary contained herein, except as set forth on Section 7.7(c) of the ABI Disclosure Letter, ABI shall not have any liability relating to any breach of, or inaccuracy in, any representation or warranty made herein that, as of the date hereof, any Buyer Party had Knowledge of the breach or inaccuracy of the representation or warranty or of the facts relating to such breach or inaccuracy.
Additional Indemnification (a) Notwithstanding any limitation in Sections 3, 4, or 5, the Company shall indemnify Indemnitee to the fullest extent permitted by applicable law if Indemnitee is a party to or threatened to be made a party to any Proceeding (including a Proceeding by or in the right of the Company to procure a judgment in its favor) against all Expenses, judgments, fines and amounts paid in settlement actually and reasonably incurred by Indemnitee in connection with the Proceeding.
(b) For purposes of Section 7(a), the meaning of the phrase “to the fullest extent permitted by applicable law” shall include, but not be limited to:
i. to the fullest extent permitted by the provision of the DGCL that authorizes or contemplates additional indemnification by agreement, or the corresponding provision of any amendment to or replacement of the DGCL, and
ii. to the fullest extent authorized or permitted by any amendments to or replacements of the DGCL adopted after the date of this Agreement that increase the extent to which a corporation may indemnify its officers and directors.
Additional Indemnification; Limitation of Liability A. Subject to Section 2(A), USBFS CANNOT AND DOES NOT GUARANTEE AVAILABILITY OF THE ELECTRONIC SERVICES. Accordingly, USBFS’s sole liability to the Trust or any third party (including End Users) for any claims, notwithstanding the form of such claims (e.g., contract, negligence, or otherwise), arising out of the delay of or interruption in the Electronic Services to be provided by USBFS hereunder shall be to use its best reasonable efforts to commence or resume the Electronic Services as promptly as is reasonably possible.
B. USBFS shall, at its sole cost and expense, defend, indemnify, and hold harmless the Trust and its trustees, officers and employees from and against any and all claims, demands, losses, expenses and liabilities of any and every nature (including reasonable attorneys’ fees) arising out of or relating to (a) any infringement, or claim of infringement, of any United States patent, trademark, copyright, trade secret, or other proprietary rights based on the use or potential use of the Electronic Services and (b) the provision of the Trust Files (as defined below) or Confidential Information (as defined below) to a person other than a person to whom such information may be properly disclosed hereunder.
C. If an injunction is issued against the Trust’s use of the Electronic Services by reason of infringement of a patent, copyright, trademark, or other proprietary rights of a third party, USBFS shall, at its own option and expense, either (i) procure for the Trust the right to continue to use the Electronic Services on substantially the same terms and conditions as specified hereunder, or (ii) after notification to the Trust, replace or modify the Electronic Services so that they become non-infringing, provided that, in the Trust’s judgment, such replacement or modification does not materially and adversely affect the performance of the Electronic Services or significantly lessen their utility to the Trust. If in the Trust’s judgment, such replacement or modification does materially adversely affect the performance of the Electronic Services or significantly lessen their utility to the Trust, the Trust may terminate all rights and responsibilities under this Exhibit C immediately on written notice to USBFS.
D. Because the ability of USBFS to deliver Electronic Services is dependent upon the Internet and equipment, software, systems, data and services provided by various telecommunications carriers, equipment manufacturers, firewall providers and encryption system developers and other vendors and third parties, USBFS shall not be liable for delays or failures to perform its obligations hereunder to the extent that such delays or failures are attributable to circumstances beyond its reasonable control which interfere with the delivery of the Electronic Services by means of the Internet or any of the equipment, software and services which support the Internet provided by such third parties. USBFS shall also not be liable for the actions or omissions of any third party wrongdoers (i.e., hackers not employed by USBFS or its affiliates) or of any third parties involved in the Electronic Services and shall not be liable for the selection of any such third party, unless USBFS selected the third party in bad faith or in a grossly negligent manner.
E. USBFS shall not be responsible for the accuracy of input material from End Users nor the resultant output derived from inaccurate input. The accuracy of input and output shall be judged as received at USBFS’s data center as determined by the records maintained by USBFS.
F. Notwithstanding anything to the contrary contained herein, USBFS shall not be obligated to ensure or verify the accuracy or actual receipt, or the transmission, of any data or information contained in any transaction via the Electronic Services or the consummation of any inquiry or transaction request not actually reviewed by USBFS.
General Indemnification Provisions (a) The Indemnifying Party shall pay the Indemnified Party immediately available funds on an as-incurred basis for any Losses for which the Indemnified Party is entitled to indemnification hereunder.
(b) If and to the extent that any provision of Section 4.01 is unenforceable for any reason, each Party hereto agrees to make the maximum contribution to the payment and satisfaction of any Losses as to which such Party would otherwise have been responsible for indemnification which is permissible under applicable Law.
(c) Each Indemnifying Party hereby waives (i) presentment, demand, protest, notice of protest, notice of dishonor and notice of nonpayment; (ii) the right, if any, to the benefit of, or to direct the application of, any security hypothecated to Indemnified Party (if any), until all indemnification liability of another Indemnifying Party to Indemnified Party, howsoever arising, shall have been satisfied; (iii) the right to require the Indemnified Party to proceed against another Indemnifying Party, or to pursue any other remedy in Indemnified Party’s power (if any); and agrees that Indemnified Party may proceed against Indemnifying Party directly and independently of any other Indemnifying Party, and that any extension, forbearance, amendment, or acceptance, release or substitution of security, or any impairment or suspension of Indemnified Party’s remedies or rights against another Indemnifying Party or the cessation of the liability for indemnification hereunder of another Indemnifying Party for any reason other than full satisfaction of the indemnification obligation at issue, shall not in anywise affect the liability of Indemnifying Party hereunder.
Indemnification Provisions Contractor agrees to indemnify, defend with counsel approved in writing by County, and hold County, its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) harmless from any claims, demands or liability of any kind or nature, including but not limited to personal injury or property damage, arising from or related to the services, products or other performance provided by Contractor pursuant to this Contract. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County or County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither party shall request a jury apportionment.
Additional Indemnity Provisions A. GRANTEE AND SYSTEM AGENCY AGREE TO FURNISH TIMELY WRITTEN NOTICE TO EACH OTHER OF ANY INDEMNITY CLAIM. GRANTEE SHALL BE LIABLE TO PAY ALL COSTS OF DEFENSE, INCLUDING ATTORNEYS’ FEES.
B. THE DEFENSE SHALL BE COORDINATED BY THE GRANTEE WITH THE OFFICE OF THE TEXAS ATTORNEY GENERAL WHEN TEXAS STATE AGENCIES ARE NAMED DEFENDANTS IN ANY LAWSUIT AND GRANTEE MAY NOT AGREE TO ANY SETTLEMENT WITHOUT FIRST OBTAINING THE CONCURRENCE FROM THE OFFICE OF THE TEXAS ATTORNEY GENERAL.
C. GRANTEE SHALL REIMBURSE SYSTEM AGENCY AND THE STATE OF TEXAS FOR ANY CLAIMS, DAMAGES, COSTS, EXPENSES OR OTHER AMOUNTS, INCLUDING, BUT NOT LIMITED TO, ATTORNEYS’ FEES AND COURT COSTS, ARISING FROM ANY SUCH CLAIM. IF THE SYSTEM AGENCY DETERMINES THAT A CONFLICT EXISTS BETWEEN ITS INTERESTS AND THOSE OF GRANTEE OR IF SYSTEM AGENCY IS REQUIRED BY APPLICABLE LAW TO SELECT SEPARATE COUNSEL, SYSTEM AGENCY WILL BE PERMITTED TO SELECT SEPARATE COUNSEL AND GRANTEE SHALL PAY ALL REASONABLE COSTS OF SYSTEM AGENCY’S COUNSEL.
Other Indemnification Provisions The foregoing indemnification provisions are in addition to, and not in derogation of, any statutory, equitable, or common law remedy any Party may have for breach of representation, warranty, or covenant.
Mandatory Indemnification; Indemnification as a Witness (i) To the extent that Indemnitee shall have been successful on the merits or otherwise in defense of any Claim relating to an Indemnifiable Event or any portion thereof or in defense of any issue or matter therein, including without limitation dismissal without prejudice, Indemnitee shall be indemnified against all Losses relating to such Claim in accordance with Section 2 to the fullest extent allowable by law, and no Standard of Conduct Determination (as defined in Section 8(b)) shall be required.
(ii) To the extent that Xxxxxxxxxx’s involvement in a Claim relating to an Indemnifiable Event is to prepare to serve and serve as a witness, and not as a party, the Indemnitee shall be indemnified against all Losses incurred in connection therewith to the fullest extent allowable by law and no Standard of Conduct Determination (as defined in Section 8(b)) shall be required.
Basic Indemnification Arrangement (a) In the event Indemnitee was, is or becomes a party to or witness or other participant in, or is threatened to be made a party to or witness or other participant in, a Claim by reason of (or arising in part out of) an Indemnifiable Event, the Company shall indemnify Indemnitee to the fullest extent permitted by law as soon as practicable but in any event no later than thirty days after written demand is presented to the Company, against any and all Expenses, judgments, fines, penalties and amounts paid in settlement (including all interest, assessments and other charges paid or payable in connection with or in respect of such Expenses, judgments, fines, penalties or amounts paid in settlement) of such Claim. If so requested by Indemnitee, the Company shall advance (within five business days of such request) any and all Expenses to Indemnitee (an “Expense Advance”).
(b) Notwithstanding the foregoing, (i) the obligations of the Company under Section 2(a) shall be subject to the condition that the Reviewing Party shall not have determined (in a written opinion, in any case in which the Independent Legal Counsel referred to in Section 3 hereof is involved) that Indemnitee would not be permitted to be indemnified under applicable law, and (ii) the obligation of the Company to make an Expense Advance pursuant to Section 2(a) shall be subject to the condition that, if, when and to the extent that the Reviewing Party determines that Indemnitee would not be permitted to be so indemnified under applicable law, the Company shall be entitled to be reimbursed by Indemnitee (who hereby agrees to reimburse the Company) for all such amounts theretofore paid; provided, however, that if Indemnitee has commenced or thereafter commences legal proceedings in a court of competent jurisdiction to secure a determination that Indemnitee should be indemnified under applicable law, any determination made by the Reviewing Party that Indemnitee would not be permitted to be indemnified under applicable law shall not be binding and Indemnitee shall not be required to reimburse the Company for any Expense Advance until a final judicial determination is made with respect thereto (as to which all rights of appeal therefrom have been exhausted or lapsed). If there has not been a Change in Control, the Reviewing Party shall be selected by the Board of Directors, and if there has been such a Change in Control (other than a Change in Control which has been approved by a majority of the Company’s Board of Directors who were directors immediately prior to such Change in Control), the Reviewing Party shall be the Independent Legal Counsel referred to in Section 3 hereof. If there has been no determination by the Reviewing Party or if the Reviewing Party determines that Indemnitee substantively would not be permitted to be indemnified in whole or in part under applicable law, Indemnitee shall have the right to commence litigation in any court in the State of Colorado or Delaware having subject matter jurisdiction thereof and in which venue is proper seeking an initial determination by the court or challenging any such determination by the Reviewing Party or any aspect thereof, including the legal or factual bases therefor, and the Company hereby consents to service of process and agrees to appear in any such proceeding. Any determination by the Reviewing Party otherwise shall be conclusive and binding on the Company and Indemnitee.
Additional Indemnification by the Servicer; Third Party Claims The Servicer shall indemnify the Seller, the Depositor, the Trustee and the Master Servicer (and each of their respective directors, officers, employees and agents) and the Trust Fund, and hold them harmless against any and all Costs that any such indemnified party may sustain in any way related to (i) the failure of the Servicer to perform its duties and service the Mortgage Loans in material compliance with the terms of this Agreement (including, but not limited to its obligation to provide the certification pursuant to Section 5.03(b) hereunder) or for any inaccurate or misleading information provided in the certification required pursuant to Section 5.03(b) or (ii) the failure of the Servicer to cause any event to occur or not to occur which would have occurred or would not have occurred, as applicable, if the Servicer were applying Accepted Servicing Practices under this Agreement. The Servicer shall immediately notify the Seller, the Depositor, the Master Servicer, the Trustee or any other relevant party if a claim is made by a third party with respect to this Agreement or the Mortgage Loans, assume (with the prior written consent of the indemnified party in the event of an indemnified claim) the defense of any such claim and pay all expenses in connection therewith, including counsel fees, promptly pay, discharge and satisfy any judgment or decree which may be entered against it or any other party in respect of such claim and follow any written instructions received from such indemnifying party in connection with such claim. Subject to the Servicer’s indemnification pursuant to Section 6.02, or the failure of the Servicer to service and administer the Mortgage Loans in material compliance with the terms of this Agreement, the Trust Fund shall indemnify the Servicer and hold the Servicer harmless against any and all Costs that the Servicer may sustain in connection with any legal action relating to this Agreement, the Certificates or the origination or Servicing of the Mortgage Loans by any prior owner or servicer, other than any Costs incurred by reason of the Servicer’s willful misfeasance, bad faith or negligence in the performance of duties hereunder or by reason of its reckless disregard of obligations and duties hereunder.
