Common use of Modification of Premises Clause in Contracts

Modification of Premises. Landlord shall have the sole judgment and discretion to determine the architecture, design, appearance, construction, workmanship, materials and equipment with respect to the construction of the Building; provided, however, Landlord shall not materially alter the areas, floor elevations and other characteristics of the Premises as shown on Exhibit "A" without the express consent of Tenant, which consent shall not be unreasonably withheld or delayed.

Modification of Premises. Landlord shall have the sole judgment and discretion to determine the architecture, design, appearance, construction, workmanship, materials and equipment with respect to the construction of the Building; provided, however, Landlord shall not materially alter the areas, floor elevations and other characteristics of the Premises as shown on Exhibit "“A" ” without the express consent of Tenant, which consent shall not be unreasonably withheld or delayed.