Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Limitations on Indemnification Obligations The rights of the Indemnified Parties to indemnification pursuant to the provisions of Section 7.2(a) and Section 7.2(b) are subject to the following provisions:
(a) None of the Indemnified Parties shall be entitled to recover for any particular Loss pursuant to Section 7.2(a)(i) or Section 7.2(b)(i) (except in the case of Fraud) unless such Loss equals or exceeds $10,000 (and no such Loss less than $10,000 shall be applied against the Deductible).
(b) The Indemnified Parties shall not be entitled to recover Losses pursuant to Section 7.2(a)(i) or Section 7.2(b)(i) (except in the case of Fraud) until the total amount which the Indemnified Parties would recover under Section 7.2(a)(i) or Section 7.2(b)(i), as applicable, in the aggregate (as limited by the other provisions hereof), but for this Section 7.4(b), exceeds $1,192,500 (the “Deductible”), in which case the applicable Indemnified Parties shall only be entitled to recover Losses in excess of such amount, subject to the other limitations herein.
(c) Except, in each case, in the case of Fraud, (i) the maximum liability of Seller to the Purchaser Indemnitees with respect to any Losses of the Purchaser Indemnitees indemnifiable pursuant to Section 7.2(a)(i) shall not exceed $1,192,500 and (ii) the maximum liability of Seller or Purchaser, as applicable, for indemnifiable Losses pursuant to this Article VII shall not exceed the Aggregate Purchase Price.
(d) The amount of any and all Losses indemnifiable hereunder shall be determined net of any amounts actually recovered by the Indemnified Parties under insurance policies (excluding, in the case of the Purchaser Indemnitees, the Representation and Warranty Insurance Policy) or other collateral sources (such as contractual indemnities of any Person which are contained outside of this Agreement) with respect to such Losses (which amounts actually recovered by the Indemnified Parties shall be calculated, in each case, net of any reasonable out-of-pocket costs and any Taxes incurred in connection with such recovery). In any case where a Purchaser Indemnitee actually recovers, under insurance policies (excluding, in the case of the Purchaser Indemnitees, the Representation and Warranty Insurance Policy) or from other collateral sources, any amount in respect of a matter for which such Indemnified Party was previously indemnified hereunder, such Indemnified Party shall promptly pay over to the Responsible Party a refund equal to the amount so recovered (after deducting therefrom the amount of the reasonable out-of-pocket costs and expenses and any Taxes incurred in connection with such recovery), if and solely to the extent that such amount of recovery would have reduced the amount to which the Indemnified Party would have been entitled pursuant to the first sentence of this Section 7.4(d), but not in excess of the aggregate amount previously paid to the Indemnified Parties hereunder in respect of such matter.
(e) The Purchaser Indemnitees shall use commercially reasonable efforts to recover under the Representation and Warranty Insurance Policy, to the extent available and subject to applicable retention and other coverage limitations thereunder, for any Losses for Indemnified Taxes pursuant to Section 7.2(a)(iv) or for any Losses pursuant to Section 7.2(a)(ii) prior to seeking indemnification from Seller under this Agreement; provided that nothing in this Section 7.4(e) shall limit the Purchaser Indemnitees’ rights to indemnification pursuant to Section 7.2(a)(iv) or pursuant to Section 7.2(a)(ii) to the extent that recovery is not available under the Representation and Warranty Insurance Policy for any reason with respect to all or any portion of such Losses. The amount of any and all indemnifiable Losses for Indemnified Taxes pursuant to Section 7.2(a)(iv) or for any indemnifiable Losses pursuant to Section 7.2(a)(ii) shall be determined net of any amounts actually recovered by the Indemnified Parties under the Representation and Warranty Insurance Policy with respect to such Losses (which amounts actually recovered by the Indemnified Parties shall be calculated, in each case, net of any reasonable out-of-pocket costs and any Taxes incurred in connection with such recovery). In any case where a Purchaser Indemnitee actually recovers under the Representation and Warranty Insurance Policy any amount in respect of a matter for which such Indemnified Party was previously indemnified hereunder, such Indemnified Party shall promptly pay over to the Responsible Party a refund equal to the amount so recovered (after deducting therefrom the amount of the reasonable out-of-pocket costs and expenses and any Taxes incurred in connection with such recovery), if and solely to the extent that such amount of recovery would have reduced the amount to which the Indemnified Party would have been entitled pursuant to the first sentence of this Section 7.4(e), but not in excess of the aggregate amount previously paid to the Indemnified Parties hereunder in respect of such matter; provided that for the avoidance of doubt, Purchaser shall not be required to repay to Seller any amounts recovered under the Representation and Warranty Insurance Policy to the extent such repayment would, after taking into account the deductible and other limitations under the Representation and Warranty Insurance Policy, have the effect of reducing the amount of indemnifiable Losses actually recovered by Purchaser with respect to such claim below the amount of indemnified Losses to which Purchaser would otherwise be entitled to recover from Seller pursuant to this Article VII, but for this Section 7.4(e). Purchaser covenants and agrees that the Representation and Warranty Insurance Policy will expressly exclude any right of subrogation against the Seller Group (other than with respect to Fraud).
(f) The Indemnified Parties shall be entitled to recover for a Loss only once under Article VII even if a claim or claims for indemnification in respect of such Loss has been made as a result of a breach of more than one representation, warranty, covenant or agreement contained in this Agreement.
(g) The Indemnified Parties shall not be entitled to recover any Loss to the extent such Loss was included in or otherwise expressly taken into account in the determination of the Aggregate Purchase Price.
(h) The rights to indemnification of the Indemnified Parties under this Article VII shall not be affected or deemed waived by reason of any investigation made by or on behalf of any party hereto (including by any of such party’s advisors or representatives) or by reason of the fact that such party or any of such advisors or representatives knew or should have known that any representation or warranty is, was or might be inaccurate.
(i) For purposes of determining the breach or inaccuracy of any representation or warranty of the Company set forth in Article III or the Seller set forth in Article IV and in calculating the amount of any Losses attributable thereto, any “materiality,” “Material Adverse Effect,” or similar qualifications in such representations and warranties shall be disregarded, except that the foregoing shall not apply to (i) the use of the term “Material Contract” in any representation or warranty or (ii) any representation or warranty set forth in Section 3.4(a) or Section 3.6(a).
(j) The Purchaser Indemnitees shall only be entitled to recover under this Article VII for any breach of any representations and warranties regarding Losses for Taxes with respect to taxable periods, or portions thereof, that end on or before the Closing Date, except to the extent such Losses arise from or are attributable to a breach of the representations or warranties contained in Sections 3.15(e), 3.15(k) or 3.15(l).
Defense and Settlement of Third Party Claims The Indemnifying Party shall have the right (without prejudice to the right of any Indemnified Party to participate at its or his own expense through counsel of its or his own choosing) to defend against any Third Party Claim at its or his expense and through counsel of its or his own choosing and to control such defense if the Indemnifying Party gives written notice of its or his intention to do so within 15 business days of its or his receipt of notice of the Third Party Claim. The Indemnified Party shall cooperate fully in all reasonable respects in the defense of such Third Party Claim and shall make available to the Indemnifying Party or its or his counsel all pertinent information under their control relating thereto. The Indemnified Party shall have the right to elect to settle any Third Party Claim; provided, however, the Indemnifying Party shall not have any indemnification obligation with respect to any monetary payment to any third party required by such settlement unless the Indemnifying Party shall have consented thereto. The Indemnifying Party shall have the right to elect to settle any Third Party Claim subject to the consent of the Indemnified Party; provided, however, that if the Indemnified Party fails to give such consent within 15 business days of being requested to do so, the Indemnified Party shall, at its expense, assume the defense of such Third Party Claim and regardless of the outcome of such matter, the Indemnifying Party's liability hereunder shall be limited to the amount of any such proposed settlement. The foregoing provisions notwithstanding, in no event (a) may either Indemnifying Party adjust, compromise or settle any Third Party Claim unless such adjustment, compromise or settlement unconditionally releases the Indemnified Party from all liability, (b) may the Company Indemnifying Party adjust, compromise or settle any Third Party Claim if such adjustment, compromise or settlement affects the absolute and sole right of Provant or the Surviving Corporation to own or use any of the Company's assets or (c) may the Company Indemnifying Party defend any Third Party Claim which, if adversely determined, would materially impair the financial condition, business or prospects of Provant or the Surviving Corporation.
Third Party Claim Procedures In the case of any claim asserted by a third party (a “Third Party Claim”) against a party entitled to indemnification under this Agreement (an “Indemnified Party”), notice shall be given by the Indemnified Party to the party required to provide indemnification (the “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of such Third Party Claim, and the Indemnified Party shall permit the Indemnifying Party (at the expense of such Indemnifying Party and so long as the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party for Losses related to such Third Party Claim) to assume the defense of such Third Party Claim, provided that (a) counsel for the Indemnifying Party who shall conduct the defense of such Third Party Claim shall be reasonably satisfactory to the Indemnified Party, and the Indemnified Party may participate in such defense at such Indemnified Party’s expense, and (b) the failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except to the extent that such failure results in a lack of actual notice to the Indemnifying Party and such Indemnifying Party is materially prejudiced as a result of such failure to be given notice. If the Indemnifying Party does not promptly assume the defense of such Third Party Claim following notice thereof, the Indemnified Party shall be entitled to assume and control such defense and to settle or agree to pay in full such Third Party Claim without the consent of the Indemnifying Party without prejudice to the ability of the Indemnified Party to enforce its claim for indemnification against the Indemnifying Party hereunder. Except with the prior written consent of the Indemnified Party, no Indemnifying Party, in the defense of any such Third Party Claim, shall consent to entry of any judgment or enter into any settlement that provides for injunctive or other nonmonetary relief affecting the Indemnified Party or that does not include as an unconditional term thereof the giving by each claimant or plaintiff to such Indemnified Party of an irrevocable release from all liability and wrongdoing with respect to such Third Party Claim. Seller and Buyers shall cooperate in the defense of any Third Party Claim subject to this Article IX and the records of each shall be reasonably available to the other with respect to such defense.
Indemnification Procedures for Non-Third Party Claims In the event any Indemnified Party should have an indemnification claim against the Shareholder under this Agreement that does not involve a claim by a third party, the Indemnified Party shall promptly deliver notice of such claim to the Shareholder in writing and in reasonable detail. The failure by any Indemnified Party to so notify the Shareholder shall not relieve the Shareholder from any liability that it may have to such Indemnified Party, except to the extent that the Shareholder has been actually prejudiced by such failure. If the Shareholder does not notify the Indemnified Party within fifteen (15) Business Days following its receipt of such notice that the Shareholder disputes such claim, such claim specified by the Shareholder in such notice shall be conclusively deemed a liability of the Shareholder under this Article VII and the Shareholder shall pay the amount of such liability to the Indemnified Party on demand, or in the case of any notice in which the amount of the claim is estimated, on such later date when the amount of such claim is finally determined. If the Shareholder disputes its liability with respect to such claim in a timely manner, Shareholder and the Indemnified Party shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through negotiations, such dispute shall be submitted to arbitration pursuant to Section 9.9.
Indemnification Procedure for Third Party Claims (a) In the event that any party (the “Indemnified Person”) desires to make a claim against any other party (the “Indemnifying Person”) in connection with any Losses for which the Indemnified Person may seek indemnification hereunder in respect of a claim or demand made by any Person not a party to this Agreement against the Indemnified Person (a “Third-Party Claim”), such Indemnified Person must notify the Indemnifying Person in writing, of the Third-Party Claim (a “Third-Party Claim Notice”) as promptly as reasonably possible after receipt, but in no event later than fifteen (15) calendar days after receipt, by such Indemnified Person of notice of the Third-Party Claim; provided, that failure to give a Third-Party Claim Notice on a timely basis shall not affect the indemnification provided hereunder except to the extent the Indemnifying Person shall have been actually and materially prejudiced as a result of such failure. Upon receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall be entitled, at the Indemnifying Person’s election, to assume or participate in the defense of any Third-Party Claim at the cost of Indemnifying Person. In any case in which the Indemnifying Person assumes the defense of the Third-Party Claim, the Indemnifying Person shall give the Indemnified Person ten (10) calendar days’ notice prior to executing any settlement agreement and the Indemnified Person shall have the right to approve or reject the settlement and related expenses; provided, however, that upon rejection of any settlement and related expenses, the Indemnified Person shall assume control of the defense of such Third-Party Claim and the liability of the Indemnifying Person with respect to such Third-Party Claim shall be limited to the amount or the monetary equivalent of the rejected settlement and related expenses.
(b) The Indemnified Person shall retain the right to employ its own counsel and to discuss matters with the Indemnifying Person related to the defense of any Third-Party Claim, the defense of which has been assumed by the Indemnifying Person pursuant to Section 10.3(a) of this Agreement, but the Indemnified Person shall bear and shall be solely responsible for its own costs and expenses in connection with such participation; provided, however, that, subject to Section 10.3(a) above, all decisions of the Indemnifying Person shall be final and the Indemnified Person shall cooperate with the Indemnifying Person in all respects in the defense of the Third-Party Claim, including refraining from taking any position adverse to the Indemnifying Person.
(c) If the Indemnifying Person fails to give notice of the assumption of the defense of any Third-Party Claim within a reasonable time period not to exceed forty-five (45) days after receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall no longer be entitled to assume (but shall continue to be entitled to participate in) such defense. The Indemnified Person may, at its option, continue to defend such Third-Party Claim and, in such event, the Indemnifying Person shall indemnify the Indemnified Person for all reasonable fees and expenses in connection therewith (provided it is a Third-Party Claim for which the Indemnifying Person is otherwise obligated to provide indemnification hereunder). The Indemnifying Person shall be entitled to participate at its own expense and with its own counsel in the defense of any Third-Party Claim the defense of which it does not assume. Prior to effectuating any settlement of such Third-Party Claim, the Indemnified Person shall furnish the Indemnifying Person with written notice of any proposed settlement in sufficient time to allow the Indemnifying Person to act thereon. Within fifteen (15) days after the giving of such notice, the Indemnified Person shall be permitted to effect such settlement unless the Indemnifying Person (a) reimburses the Indemnified Person in accordance with the terms of this Article 10 for all reasonable fees and expenses incurred by the Indemnified Person in connection with such Claim; (b) assumes the defense of such Third-Party Claim; and (c) takes such other actions as the Indemnified Person may reasonably request as assurance of the Indemnifying Person’s ability to fulfill its obligations under this Article 10 in connection with such Third-Party Claim.
PROCEDURE FOR INDEMNIFICATION--THIRD PARTY CLAIMS (a) Promptly after receipt by an indemnified party under Section 12.1 or 12.2 of notice of the commencement of any proceeding against it, such indemnified party will, if a claim is to be made against an indemnifying party under such Section, give notice to the indemnifying party of the commencement of such claim, but the failure to notify the indemnifying party will not relieve the indemnifying party of any liability that it may have to any indemnified party, except to the extent that the indemnifying party demonstrates that the defense of such action is prejudiced by the indemnifying party's failure to give such notice.
(b) If any proceeding referred to in Section 12.4(a) is brought against an indemnified party and it gives notice to the indemnifying party of the commencement of such proceeding, the indemnifying party will be entitled to participate in such proceeding and, to the extent that it wishes (unless the indemnifying party is also a party to such proceeding and the indemnified party determines in good faith that joint representation would be inappropriate), to assume the defense of such proceeding with counsel satisfactory to the indemnified party and, after notice from the indemnifying party to the indemnified party of its election to assume the defense of such proceeding, the indemnifying party will not, as long as it diligently conducts such defense, be liable to the indemnified party under this Section 12 for any fees of other counsel or any other expenses with respect to the defense of such proceeding, in each case subsequently incurred by the indemnified party in connection with the defense of such proceeding, other than reasonable costs of investigation. If the indemnifying party assumes the defense of a proceeding, (i) it will be conclusively established for purposes of this Agreement that the claims made in that proceeding are within the scope of and subject to indemnification; (ii) no compromise or settlement or such claims may be effected by the indemnifying party without the indemnified party's consent unless the sole relief provided is monetary damages that are paid in full by the indemnifying party; and (iii) the indemnified party will have no liability with respect to any compromise or settlement of such claims effected without its consent. If notice is given to an indemnifying party of the commencement of any proceeding and the indemnifying party does not, within ten days after the indemnified party's notice is given, give notice to the indemnified party of its election to assume the defense of such proceeding, the indemnifying party will be bound by any determination made in such proceeding or any compromise or settlement effected by the indemnified party.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Indemnification in Third Party Proceedings Subject to Section 10 below, the Company shall indemnify Indemnitee to the fullest extent permitted by the Code, as the same may be amended from time to time (but, only to the extent that such amendment permits Indemnitee to broader indemnification rights than the Code permitted prior to adoption of such amendment), if Indemnitee is a party to or threatened to be made a party to or otherwise involved in any proceeding, for any and all expenses, actually and reasonably incurred by Indemnitee in connection with the investigation, defense, settlement or appeal of such proceeding.
Amendments to Clarify and Correct Errors and Defects The parties may amend this Agreement to clarify an ambiguity, correct an error or correct or supplement any term of this Agreement that may be defective or inconsistent with the other terms of this Agreement, in each case, without the consent of the Noteholders, the Certificateholders or any other Person. The parties may amend any term or provision of this Agreement from time to time for the purpose of conforming the terms of this Agreement to the description thereof in the Prospectus, without the consent of Noteholders, the Certificateholders or any other Person.
