Common use of No Additional Representations or Warranties Clause in Contracts

No Additional Representations or Warranties. EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONS, THE PRODUCTS AND SERVICES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE PRODUCTS, SERVICES, GIVEXPAY SERVICES, OR GIVEX PLAFTORM TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORS.

Appears in 5 contracts

Samples: Merchant Agreement, Merchant Agreement, Givexpay Merchant Agreement

AutoNDA by SimpleDocs

No Additional Representations or Warranties. EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES SET FORTH AS PROVIDED IN THIS TERMS AND CONDITIONSARTICLE III, THE PRODUCTS AND SERVICESNONE OF SELLER, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORMCOMPANY, ARE PROVIDED “AS IS” WITHOUT WARRANTY COMPANY’S SUBSIDIARIES NOR ANY OF THEIR RESPECTIVE AFFILIATES, NOR ANY KIND. GIVEX MAKES NO REPRESENTATIONS OF THEIR RESPECTIVE DIRECTORS, OFFICERS, EMPLOYEES, STOCKHOLDERS, PARTNERS, MEMBERS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE PRODUCTS, SERVICES, GIVEXPAY SERVICESOTHER REPRESENTATIVES HAS MADE, OR GIVEX PLAFTORM IS MAKING, ANY REPRESENTATION OR WARRANTY WHATSOEVER TO ACQUIROR OR ITS AFFILIATES AND NO SUCH PARTY SHALL BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING LIABLE IN RESPECT OF THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES ANY INFORMATION PROVIDED TO ACQUIROR OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMSAFFILIATES. WITHOUT LIMITING THE FOREGOING, GIVEX DOES ACQUIROR ACKNOWLEDGES THAT IT, TOGETHER WITH ITS ADVISORS, HAS MADE ITS OWN INVESTIGATION OF COMPANY, ITS SUBSIDIARIES AND THE BUSINESS AND IS NOT WARRANT RELYING ON ANY IMPLIED WARRANTIES OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVEREDUPON ANY REPRESENTATION OR WARRANTY WHATSOEVER AS TO THE PROSPECTS (FINANCIAL OR OTHERWISE) OR THE VIABILITY OR LIKELIHOOD OF SUCCESS OF THE BUSINESS OF COMPANY AND ITS SUBSIDIARIES AS CONDUCTED AFTER THE CLOSING, REPORTED AS CONTAINED IN ANY MATERIALS PROVIDED BY SELLER, COMPANY, COMPANY’S SUBSIDIARIES OR REMEDIEDTHEIR RESPECTIVE AFFILIATES OR ANY OF THEIR RESPECTIVE DIRECTORS, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATESOFFICERS, EMPLOYEES, REPRESENTATIVESSTOCKHOLDERS, AGENTS PARTNERS, MEMBERS OR CONTRACTORSOTHER REPRESENTATIVES OR OTHERWISE, EXCEPT IN EACH CASE THE REPRESENTATIONS AND WARRANTIES PROVIDED IN THIS AGREEMENT. FOR THE PURPOSES HEREIN, ANY INFORMATION PROVIDED TO, OR MADE AVAILABLE TO, ACQUIROR BY OR ON BEHALF OF SELLER, COMPANY OR COMPANY’S SUBSIDIARIES OR THEIR RESPECTIVE AFFILIATES SHALL INCLUDE ANY AND ALL INFORMATION THAT IS CONTAINED OR POSTED IN ANY ELECTRONIC DATA ROOM ESTABLISHED BY SELLER OR ITS REPRESENTATIVES IN CONNECTION WITH THE TRANSACTIONS CONTEMPLATED BY THIS AGREEMENT.

Appears in 3 contracts

Samples: Stock Purchase Agreement (Pinafore Holdings B.V.), Stock Purchase Agreement (Gates Global Inc.), Stock Purchase Agreement (Pinafore Holdings B.V.)

No Additional Representations or Warranties. EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONS, THE PRODUCTS AND SERVICES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE PRODUCTS, SERVICES, GIVEXPAY SERVICES, OR GIVEX PLAFTORM TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-THIRD PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORS.

Appears in 2 contracts

Samples: Merchant Agreement, Merchant Agreement

No Additional Representations or Warranties. EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES AS OTHERWISE EXPRESSLY SET FORTH IN THIS TERMS AND CONDITIONSARTICLE 3 (AS MODIFIED BY THE COMPANY DISCLOSURE SCHEDULES), THE PRODUCTS AND SERVICES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY YUCATAN EXPRESSLY DISCLAIMS ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS KIND OR WARRANTIESNATURE, EXPRESS OR IMPLIED, REGARDING AS TO THE PRODUCTS, SERVICES, GIVEXPAY SERVICES, OR GIVEX PLAFTORM TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE VALUE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIESCOMPANIES OR THEIR ASSETS OR EQUITY INTERESTS, INCLUDING ANY REPRESENTATION OR WARRANTY OF MERCHANTABILITY, USAGE, SUITABILITY OR FITNESS FOR ANY PARTICULAR PURPOSE WITH RESPECT TO ANY OF THE INTERNETCOMPANIES’ ASSETS OR EQUITY INTERESTS, OR THE ABSENCE OF ANY DEFECTS THEREIN, WHETHER LATENT OR PATENT, IT BEING UNDERSTOOD THAT, EXCEPT AS OTHERWISE EXPRESSLY SET FORTH IN THIS ARTICLE 3, SUCH SUBJECT ASSETS AND EQUITY INTERESTS ARE BEING ACQUIRED THROUGH THE ACQUISITION “AS IS, WHERE IS” ON THE CLOSING DATE, AND IN THEIR PRESENT CONDITION, AND BUYER SHALL RELY ON ITS OWN EXAMINATION AND INVESTIGATION THEREOF. EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES CONTAINED IN THIS ARTICLE 3 (AS MODIFIED BY THE COMPANY DISCLOSURE SCHEDULES), YUCATAN HEREBY DISCLAIMS ALL LIABILITY AND RESPONSIBILITY FOR ANY REPRESENTATION, WARRANTY, STATEMENT, OR INFORMATION MADE, COMMUNICATED, OR FURNISHED (ORALLY OR IN WRITING) TO BUYER OR ITS AFFILIATES OR REPRESENTATIVES (INCLUDING ANY OPINION, INFORMATION, PROJECTION, OR ADVICE THAT THE SERVICES MAY HAVE BEEN OR MAY BE SUBJECT PROVIDED TO LIMITATIONSBUYER BY ANY DIRECTOR, DELAYSOFFICER, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYSEMPLOYEE, DELIVERY FAILURESAGENT, CONSULTANT, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT REPRESENTATIVE OF A COMPANY OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORS).

Appears in 2 contracts

Samples: Capital Contribution and Partnership Interest and Stock Purchase Agreement, Capital Contribution and Partnership Interest and Stock Purchase Agreement (Landec Corp \Ca\)

No Additional Representations or Warranties. EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES AS OTHERWISE EXPRESSLY SET FORTH IN THIS TERMS AND CONDITIONSARTICLE 6, THE PRODUCTS AND SERVICES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY EACH EQUITYHOLDER EXPRESSLY DISCLAIMS ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS KIND OR WARRANTIESNATURE, EXPRESS OR IMPLIED, REGARDING AS TO THE PRODUCTS, SERVICES, GIVEXPAY SERVICES, OR GIVEX PLAFTORM TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE VALUE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIESCOMPANIES’ OR THEIR ASSETS OR SECURITIES, INCLUDING ANY REPRESENTATION OR WARRANTY OF MERCHANTABILITY, USAGE, SUITABILITY OR FITNESS FOR ANY PARTICULAR PURPOSE WITH RESPECT TO ANY OF THE INTERNETCOMPANIES’ ASSETS OR EQUITY INTERESTS, OR THE ABSENCE OF ANY DEFECTS THEREIN, WHETHER LATENT OR PATENT, IT BEING UNDERSTOOD THAT, EXCEPT AS OTHERWISE EXPRESSLY SET FORTH IN THIS ARTICLE 6, SUCH SUBJECT ASSETS ARE BEING ACQUIRED THROUGH THE ACQUISITION “AS IS, WHERE IS” ON THE CLOSING DATE, AND IN THEIR PRESENT CONDITION, AND BUYER SHALL RELY ON ITS OWN EXAMINATION AND INVESTIGATION THEREOF. EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES CONTAINED IN THIS ARTICLE 6 AND IN ARTICLES 3 AND 4 (FOR WHICH EQUITYHOLDERS HAVE INDEMNIFICATION OBLIGATIONS UNDER ARTICLE 12), EACH EQUITYHOLDER HEREBY DISCLAIMS ALL LIABILITY AND RESPONSIBILITY FOR ANY REPRESENTATION, WARRANTY, STATEMENT, OR INFORMATION MADE, COMMUNICATED, OR FURNISHED (ORALLY OR IN WRITING) TO BUYER OR ITS AFFILIATES OR REPRESENTATIVES (INCLUDING ANY OPINION, INFORMATION, PROJECTION, OR ADVICE THAT THE SERVICES MAY HAVE BEEN OR MAY BE SUBJECT PROVIDED TO LIMITATIONSBUYER BY ANY DIRECTOR, DELAYSMANAGER, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYSOFFICER, DELIVERY FAILURESEMPLOYEE, AGENT, CONSULTANT, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING REPRESENTATIVE OF EITHER OF THE FOREGOING, GIVEX DOES NOT WARRANT COMPANIES OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED CAMDEN OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS THEIR RESPECTIVE AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORS).

Appears in 2 contracts

Samples: Capital Contribution and Partnership Interest and Stock Purchase Agreement, Capital Contribution and Partnership Interest and Stock Purchase Agreement (Landec Corp \Ca\)

No Additional Representations or Warranties. EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES AS OTHERWISE EXPRESSLY SET FORTH IN THIS TERMS AND CONDITIONSARTICLE 4 (AS MODIFIED BY THE CAMDEN DISCLOSURE SCHEDULES), THE PRODUCTS AND SERVICES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY CAMDEN EXPRESSLY DISCLAIMS ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS KIND OR WARRANTIESNATURE, EXPRESS OR IMPLIED, REGARDING AS TO THE PRODUCTSCONDITION, SERVICESVALUE OR QUALITY OF CAMDEN OR ITS ASSETS OR EQUITY INTERESTS, GIVEXPAY SERVICESINCLUDING ANY REPRESENTATION OR WARRANTY OF MERCHANTABILITY, USAGE, SUITABILITY OR FITNESS FOR ANY PARTICULAR PURPOSE WITH RESPECT TO ANY OF CAMDEN’S ASSETS OR EQUITY INTERESTS, OR GIVEX PLAFTORM THE ABSENCE OF ANY DEFECTS THEREIN, WHETHER LATENT OR PATENT, IT BEING UNDERSTOOD THAT, EXCEPT AS OTHERWISE EXPRESSLY SET FORTH IN THIS ARTICLE 4, SUCH SUBJECT ASSETS AND EQUITY INTERESTS ARE BEING ACQUIRED THROUGH THE ACQUISITION “AS IS, WHERE IS” ON THE CLOSING DATE, AND IN THEIR PRESENT CONDITION, AND BUYER SHALL RELY ON ITS OWN EXAMINATION AND INVESTIGATION THEREOF. EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES CONTAINED IN THIS ARTICLE 4 (AS MODIFIED BY THE CAMDEN DISCLOSURE SCHEDULES), CAMDEN HEREBY DISCLAIMS ALL LIABILITY AND RESPONSIBILITY FOR ANY REPRESENTATION, WARRANTY, STATEMENT, OR INFORMATION MADE, COMMUNICATED, OR FURNISHED (ORALLY OR IN WRITING) TO BUYER OR ITS AFFILIATES OR REPRESENTATIVES (INCLUDING ANY OPINION, INFORMATION, PROJECTION, OR ADVICE THAT MAY HAVE BEEN OR MAY BE PROVIDED HEREUNDER TO BUYER BY ANY DIRECTOR, OFFICER, EMPLOYEE, AGENT, CONSULTANT, OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT REPRESENTATIVE OF EITHER OF CAMDEN OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORS).

Appears in 2 contracts

Samples: Capital Contribution and Partnership Interest and Stock Purchase Agreement, Capital Contribution and Partnership Interest and Stock Purchase Agreement (Landec Corp \Ca\)

No Additional Representations or Warranties. NOTWITHSTANDING THE DELIVERY OR DISCLOSURE TO SPAC OR ANY OF ITS REPRESENTATIVES OF ANY DOCUMENTATION OR OTHER INFORMATION (INCLUDING ANY FINANCIAL PROJECTIONS OR OTHER SUPPLEMENTAL DATA), EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES AS OTHERWISE EXPRESSLY SET FORTH IN THIS TERMS AND CONDITIONSARTICLE ‎III (AS MODIFIED BY THE COMPANY DISCLOSURE SCHEDULES), THE PRODUCTS ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, (A) NONE OF THE COMPANY, ANY COMPANY NON-RECOURSE PARTY OR ANY OTHER PERSON MAKES, AND SERVICESTHE COMPANY EXPRESSLY DISCLAIMS AND NEGATES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS KIND OR WARRANTIESNATURE, EXPRESS OR IMPLIED, REGARDING (I) IN CONNECTION WITH THIS AGREEMENT, THE PRODUCTSANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY, SERVICES(II) WITH RESPECT TO THE GROUP COMPANIES, GIVEXPAY SERVICESAND ANY MATTER RELATING TO ANY OF THEM, INCLUDING THEIR AFFAIRS, THE CONDITION, VALUE OR QUALITY OF THE ASSETS, LIABILITIES, FINANCIAL CONDITION OR RESULTS OF OPERATIONS, OR GIVEX PLAFTORM (III) WITH RESPECT TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES ANY STATEMENT OR THE RESULTS MERCHANT MAY OBTAIN BY USING INFORMATION THAT HAVE BEEN MADE AVAILABLE TO SPAC OR ANY OF THESE SERVICES. WITHOUT LIMITING ITS REPRESENTATIVES, INCLUDING THE GENERALITY MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT GROUP COMPANIES OR WARRANT THAT (A) THE OPERATION OR USE ANY PRESENTATION OF THE SERVICES WILL BE TIMELYBUSINESS AND AFFAIRS OF THE GROUP COMPANIES BY THE MANAGEMENT OF THE COMPANY OR OTHERS IN CONNECTION WITH THE TRANSACTIONS CONTEMPLATED HEREBY OR BY THE ANCILLARY AGREEMENTS, UNINTERRUPTED OR ERROR- FREE; OR AND (B) NO STATEMENT OR INFORMATION CONTAINED IN ANY OF SUCH MATERIALS OR MADE IN ANY SUCH PRESENTATION SHALL BE DEEMED A REPRESENTATION OR WARRANTY HEREUNDER OR OTHERWISE OR DEEMED TO BE RELIED UPON BY SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON IN EXECUTING, DELIVERING AND PERFORMING THIS AGREEMENT, THE QUALITY ANCILLARY AGREEMENTS OR THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY. EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE ‎III, THE ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, IT IS UNDERSTOOD THAT ANY COST ESTIMATES, PROJECTIONS, FORECASTS, BUDGETS OR OTHER PREDICTIONS, ANY DATA, ANY FINANCIAL INFORMATION OR ANY MEMORANDA OR OFFERING MATERIALS OR PRESENTATIONS, INCLUDING ANY OFFERING MEMORANDUM OR SIMILAR MATERIALS MADE AVAILABLE BY ANY GROUP COMPANY, ARE NOT AND SHALL NOT BE DEEMED TO BE OR TO INCLUDE REPRESENTATIONS OR WARRANTIES OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRDCOMPANY, ANY COMPANY NON-RECOURSE PARTY PROVIDERS CONTROL OR ANY OTHER PERSON, AND, EXCEPT FOR THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIESREPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE ‎III, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT ANCILLARY AGREEMENTS OR IN THE USE CASE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS FRAUD, ARE NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL AND SHALL NOT BE DEEMED TO BE RELIED UPON BY SPAC, ANY SECURITY BREACHES BY THIRDSPAC NON-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR RECOURSE PARTY OR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES PERSON IN EXECUTING, DELIVERING OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTSPERFORMING THIS AGREEMENT, DELAYS THE ANCILLARY AGREEMENTS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES TRANSACTIONS CONTEMPLATED HEREBY OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTHEREBY.

Appears in 1 contract

Samples: Business Combination Agreement (Bite Acquisition Corp.)

No Additional Representations or Warranties. EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES AS SET FORTH IN THIS TERMS SECTIONS 13.1 (SYMBOTIC REPRESENTATIONS AND CONDITIONSWARRANTIES), THE PRODUCTS 13.2 (SYSTEM WARRANTY) AND SERVICES13.3 (CUSTOMER REPRESENTATIONS AND WARRANTIES), INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, THERE ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR OTHER WARRANTIES, EXPRESS OR IMPLIED, REGARDING INCLUDING, BUT NOT LIMITED TO, THE PRODUCTS, SERVICES, GIVEXPAY SERVICESIMPLIED WARRANTIES OF FITNESS FOR A PARTICULAR PURPOSE, OR GIVEX PLAFTORM MERCHANTABILITY AND INCLUDING WITH RESPECT TO BE PROVIDED HEREUNDER SYMBOTIC PROPERTY OR THEIR THE SERVICES AND/OR DELIVERABLES, EXPRESS OR IMPLIED, STATUTORY OR OTHERWISE, AS TO ANY MATTER WHATSOEVER AND, TO THE MAXIMUM EXTENT PERMITTED BY APPLICABLE LAW, ALL WARRANTIES OF MERCHANTABILITY, DESIGN, CONDITION, MERCHANTABILITYDURABILITY, NON-INFRINGEMENTPERFORMANCE, QUALITY, CAPACITY OR FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR AND NON-INFRINGEMENT OF THIRD PARTY RIGHTS ARE EXPRESSLY EXCLUDED. CUSTOMER ACKNOWLEDGES AND AGREES THAT IT HAS NOT RELIED ON ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS NOT SPECIFICALLY INCLUDED IN THIS ARTICLE XIII (REPRESENTATIONS AND WARRANTIES; WARRANTY; CORRECTION OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIESDEFECTS), INCLUDING THE INTERNETANY SALES PRESENTATIONS, AND THAT THE SERVICES MAY BE SUBJECT DEMOS, REPLIES TO LIMITATIONSRFPS, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURESMANAGEMENT PRESENTATIONS, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOINGCOMMUNICATIONS (COLLECTIVELY, GIVEX DOES “SYMBOTIC INFORMATION”), AND SHALL NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVEREDASSERT, REPORTED OR REMEDIEDAND SHALL CAUSE ITS AFFILIATES AND CUSTOMER PERSONNEL NOT TO ASSERT, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR CLAIM AGAINST SYMBOTIC WITH RESPECT TO THEIR RELIANCE ON ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSSYMBOTIC INFORMATION.

Appears in 1 contract

Samples: Master Services, License and Equipment Agreement (Symbotic Inc.)

No Additional Representations or Warranties. NOTWITHSTANDING THE DELIVERY OR DISCLOSURE TO SPAC OR ANY OF ITS REPRESENTATIVES OF ANY DOCUMENTATION OR OTHER INFORMATION (INCLUDING ANY FINANCIAL PROJECTIONS OR OTHER SUPPLEMENTAL DATA), EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES AS OTHERWISE EXPRESSLY SET FORTH IN THIS TERMS AND CONDITIONSARTICLE III (AS MODIFIED BY THE COMPANY DISCLOSURE SCHEDULES), THE PRODUCTS ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, (A) NONE OF THE COMPANY, ANY COMPANY NON-RECOURSE PARTY OR ANY OTHER PERSON MAKES, AND SERVICESTHE COMPANY EXPRESSLY DISCLAIMS AND NEGATES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS KIND OR WARRANTIESNATURE, EXPRESS OR IMPLIED, REGARDING (I) IN CONNECTION WITH THIS AGREEMENT, THE PRODUCTSANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY, SERVICES(II) WITH RESPECT TO THE GROUP COMPANIES, GIVEXPAY SERVICESAND ANY MATTER RELATING TO ANY OF THEM, INCLUDING THEIR AFFAIRS, THE CONDITION, VALUE OR QUALITY OF THE ASSETS, LIABILITIES, FINANCIAL CONDITION OR RESULTS OF OPERATIONS, OR GIVEX PLAFTORM (III) WITH RESPECT TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES ANY STATEMENT OR THE RESULTS MERCHANT MAY OBTAIN BY USING INFORMATION THAT HAVE BEEN MADE AVAILABLE TO SPAC OR ANY OF THESE SERVICES. WITHOUT LIMITING ITS REPRESENTATIVES, INCLUDING THE GENERALITY MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT GROUP COMPANIES OR WARRANT THAT (A) THE OPERATION OR USE ANY PRESENTATION OF THE SERVICES WILL BE TIMELYBUSINESS AND AFFAIRS OF THE GROUP COMPANIES BY THE MANAGEMENT OF THE COMPANY OR OTHERS IN CONNECTION WITH THE TRANSACTIONS CONTEMPLATED HEREBY OR BY THE ANCILLARY AGREEMENTS, UNINTERRUPTED OR ERROR- FREE; OR AND (B) NO STATEMENT OR INFORMATION CONTAINED IN ANY OF SUCH MATERIALS OR MADE IN ANY SUCH PRESENTATION SHALL BE DEEMED A REPRESENTATION OR WARRANTY HEREUNDER OR OTHERWISE OR DEEMED TO BE RELIED UPON BY SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON IN EXECUTING, DELIVERING AND PERFORMING THIS AGREEMENT, THE QUALITY ANCILLARY AGREEMENTS OR THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY. EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE III, THE ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, IT IS UNDERSTOOD THAT ANY COST ESTIMATES, PROJECTIONS, FORECASTS, BUDGETS OR OTHER PREDICTIONS, ANY DATA, ANY FINANCIAL INFORMATION OR ANY MEMORANDA OR OFFERING MATERIALS OR PRESENTATIONS, INCLUDING ANY OFFERING MEMORANDUM OR SIMILAR MATERIALS MADE AVAILABLE BY ANY GROUP COMPANY, ARE NOT AND SHALL NOT BE DEEMED TO BE OR TO INCLUDE REPRESENTATIONS OR WARRANTIES OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRDCOMPANY, ANY COMPANY NON-RECOURSE PARTY PROVIDERS CONTROL OR ANY OTHER PERSON, AND, EXCEPT FOR THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIESREPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE III, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT ANCILLARY AGREEMENTS OR IN THE USE CASE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS FRAUD, ARE NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL AND SHALL NOT BE DEEMED TO BE RELIED UPON BY SPAC, ANY SECURITY BREACHES BY THIRDSPAC NON-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR RECOURSE PARTY OR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES PERSON IN EXECUTING, DELIVERING OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTSPERFORMING THIS AGREEMENT, DELAYS THE ANCILLARY AGREEMENTS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES TRANSACTIONS CONTEMPLATED HEREBY OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTHEREBY.

Appears in 1 contract

Samples: Business Combination Agreement (Jupiter Acquisition Corp)

No Additional Representations or Warranties. NOTWITHSTANDING THE DELIVERY OR DISCLOSURE TO THE COMPANY OR ANY OF ITS REPRESENTATIVES OF ANY DOCUMENTATION OR OTHER INFORMATION (INCLUDING ANY FINANCIAL PROJECTIONS OR OTHER SUPPLEMENTAL DATA), EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES AS OTHERWISE EXPRESSLY SET FORTH IN THIS TERMS AND CONDITIONSARTICLE ‎IV (AS MODIFIED BY THE SPAC DISCLOSURE SCHEDULES), THE PRODUCTS ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, (A) SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON DO NOT MAKE, AND SERVICESSPAC EXPRESSLY DISCLAIMS AND NEGATES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS KIND OR WARRANTIESNATURE, EXPRESS OR IMPLIED, REGARDING (I) IN CONNECTION WITH THIS AGREEMENT, THE PRODUCTSANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY, SERVICES(II) WITH RESPECT TO SPAC, GIVEXPAY SERVICESINCLUDING ITS AFFAIRS, THE CONDITION, VALUE OR QUALITY OF THE ASSETS, LIABILITIES, FINANCIAL CONDITION OR RESULTS OF OPERATIONS, OR GIVEX PLAFTORM (III) WITH RESPECT TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF ANY STATEMENT OR INFORMATION THAT HAVE BEEN MADE AVAILABLE TO THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES COMPANY OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING ITS REPRESENTATIVES, INCLUDING THE GENERALITY MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF SPAC OR ANY PRESENTATION OF THE FOREGOING, GIVEX BUSINESS AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE AFFAIRS OF THE SERVICES WILL BE TIMELYCOMPANY BY THE MANAGEMENT OF THE COMPANY OR OTHERS IN CONNECTION WITH THE TRANSACTIONS CONTEMPLATED HEREBY OR BY THE ANCILLARY AGREEMENTS, UNINTERRUPTED OR ERROR- FREE; OR AND (B) NO STATEMENT OR INFORMATION CONTAINED IN ANY OF SUCH MATERIALS OR MADE IN ANY SUCH PRESENTATION SHALL BE DEEMED A REPRESENTATION OR WARRANTY HEREUNDER OR OTHERWISE OR DEEMED TO BE RELIED UPON BY THE QUALITY COMPANY, ANY COMPANY NON-RECOURSE PARTY OR ANY OTHER PERSON IN EXECUTING, DELIVERING AND PERFORMING THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY. EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE ‎IV, THE ANCILLARY AGREEMENTS OR IN THE CASE OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES FRAUD, IT IS UNDERSTOOD THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIESANY COST ESTIMATES, PROJECTIONS, FORECASTS, BUDGETS OR OTHER PREDICTIONS, ANY DATA, ANY FINANCIAL INFORMATION OR ANY MEMORANDA OR OFFERING MATERIALS OR PRESENTATIONS, INCLUDING ANY OFFERING MEMORANDUM OR SIMILAR MATERIALS MADE AVAILABLE BY SPAC, ARE NOT AND SHALL NOT BE DEEMED TO BE OR TO INCLUDE REPRESENTATIONS OR WARRANTIES OF SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON, AND, EXCEPT FOR THE INTERNETREPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE ‎IV, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT ANCILLARY AGREEMENTS OR IN THE USE CASE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS FRAUD, ARE NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL AND SHALL NOT BE DEEMED TO BE RELIED UPON BY THE COMPANY, ANY SECURITY BREACHES BY THIRDCOMPANY NON-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR RECOURSE PARTY OR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES PERSON IN EXECUTING, DELIVERING OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTSPERFORMING THIS AGREEMENT, DELAYS THE ANCILLARY AGREEMENTS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES TRANSACTIONS CONTEMPLATED HEREBY OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTHEREBY.

Appears in 1 contract

Samples: Business Combination Agreement (Bite Acquisition Corp.)

No Additional Representations or Warranties. EXCEPT FOR ANY EXPRESS THE REPRESENTATIONS AND WARRANTIES SET FORTH CONTAINED IN THIS TERMS AND CONDITIONSARTICLE III (INCLUDING THE RELATED PORTIONS OF THE DISCLOSURE SCHEDULES) OR IN EACH OTHER TRANSACTION DOCUMENT (COLLECTIVELY, THE PRODUCTS AND SERVICES“EXPRESS REPRESENTATIONS”), NEITHER THE COMPANY NOR ANY OTHER PERSON HAS MADE OR MAKES ANY OTHER EXPRESS OR IMPLIED REPRESENTATION OR WARRANTY, EITHER WRITTEN OR ORAL, ON BEHALF OF THE COMPANY, INCLUDING ANY REPRESENTATION OR WARRANTY AS TO THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE PRODUCTS, SERVICES, GIVEXPAY SERVICES, OR GIVEX PLAFTORM TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF ANY INFORMATION REGARDING THE SERVICESCOMPANY FURNISHED OR MADE AVAILABLE TO THE PURCHASERS AND ITS REPRESENTATIVES (INCLUDING ANY INFORMATION, GIVEXPAY SERVICESDOCUMENTS OR MATERIAL MADE AVAILABLE BY THE COMPANY OR ITS REPRESENTATIVES IN MANAGEMENT PRESENTATIONS OR IN ANY OTHER FORM IN EXPECTATION OF THE TRANSACTIONS CONTEMPLATED HEREBY) OR AS TO THE FUTURE, GIVEX PLATFORMPROJECTED OR ESTIMATED REVENUE, PROCESSING SERVICES PROFITABILITY OR SUCCESS OF THE RESULTS MERCHANT MAY OBTAIN BY USING ANY COMPANY, ITS SUBSIDIARIES AND THE BUSINESS OF THESE SERVICESTHE COMPANY AND ITS SUBSIDIARIES. WITHOUT LIMITING THE GENERALITY OF NOTWITHSTANDING THE FOREGOING, GIVEX NOTHING IN THIS SECTION 3.26 SHALL BE DEEMED TO LIMIT ANY CLAIM BY A PURCHASER WITH RESPECT TO ITS RIGHTS AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT REMEDIES IN THE USE CASE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYSACTUAL FRAUD, DELIVERY FAILURES, GROSS NEGLIGENCE OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSWILLFUL MISCONDUCT.

Appears in 1 contract

Samples: Securities Purchase Agreement (Global Clean Energy Holdings, Inc.)

No Additional Representations or Warranties. NOTWITHSTANDING THE DELIVERY OR DISCLOSURE TO SPAC OR ANY OF ITS REPRESENTATIVES OF ANY DOCUMENTATION OR OTHER INFORMATION (INCLUDING ANY FINANCIAL PROJECTIONS OR OTHER SUPPLEMENTAL DATA), EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES AS OTHERWISE EXPRESSLY SET FORTH IN THIS TERMS AND CONDITIONSARTICLE IV (AS MODIFIED BY THE COMPANY DISCLOSURE SCHEDULES), THE PRODUCTS ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, (A) NONE OF THE COMPANY, ANY COMPANY NON-RECOURSE PARTY OR ANY OTHER PERSON MAKES, AND SERVICESTHE COMPANY EXPRESSLY DISCLAIMS AND NEGATES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS KIND OR WARRANTIESNATURE, EXPRESS OR IMPLIED, REGARDING (I) IN CONNECTION WITH THIS AGREEMENT, THE PRODUCTSANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS, SERVICES(II) WITH RESPECT TO THE GROUP COMPANIES, GIVEXPAY SERVICESAND ANY MATTER RELATING TO ANY OF THEM, INCLUDING THEIR AFFAIRS, THE CONDITION, VALUE OR QUALITY OF THE ASSETS, LIABILITIES, FINANCIAL CONDITION OR RESULTS OF OPERATIONS, OR GIVEX PLAFTORM (III) WITH RESPECT TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES ANY STATEMENT OR THE RESULTS MERCHANT MAY OBTAIN BY USING INFORMATION THAT HAVE BEEN MADE AVAILABLE TO SPAC OR ANY OF THESE SERVICES. WITHOUT LIMITING ITS REPRESENTATIVES, INCLUDING THE GENERALITY MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT GROUP COMPANIES OR WARRANT THAT (A) THE OPERATION OR USE ANY PRESENTATION OF THE SERVICES WILL BE TIMELYBUSINESS AND AFFAIRS OF THE GROUP COMPANIES BY THE MANAGEMENT OF THE COMPANY OR OTHERS IN CONNECTION WITH THE TRANSACTIONS, UNINTERRUPTED OR ERROR- FREE; OR AND (B) NO STATEMENT OR INFORMATION CONTAINED IN ANY OF SUCH MATERIALS OR MADE IN ANY SUCH PRESENTATION SHALL BE DEEMED A REPRESENTATION OR WARRANTY HEREUNDER OR OTHERWISE OR DEEMED TO BE RELIED UPON BY SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON IN EXECUTING, DELIVERING AND PERFORMING THIS AGREEMENT, THE QUALITY ANCILLARY AGREEMENTS OR THE TRANSACTIONS. EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE IV, THE ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, IT IS UNDERSTOOD THAT ANY COST ESTIMATES, PROJECTIONS, FORECASTS, BUDGETS OR OTHER PREDICTIONS, ANY DATA, ANY FINANCIAL INFORMATION OR ANY MEMORANDA OR OFFERING MATERIALS OR PRESENTATIONS, INCLUDING ANY OFFERING MEMORANDUM OR SIMILAR MATERIALS MADE AVAILABLE BY ANY GROUP COMPANY, ARE NOT AND SHALL NOT BE DEEMED TO BE OR TO INCLUDE REPRESENTATIONS OR WARRANTIES OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRDCOMPANY, ANY COMPANY NON-RECOURSE PARTY PROVIDERS CONTROL OR ANY OTHER PERSON, AND, EXCEPT FOR THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIESREPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE IV, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT ANCILLARY AGREEMENTS OR IN THE USE CASE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS FRAUD, ARE NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL AND SHALL NOT BE DEEMED TO BE RELIED UPON BY SPAC, ANY SECURITY BREACHES BY THIRDSPAC NON-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR RECOURSE PARTY OR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES PERSON IN EXECUTING, DELIVERING OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTSPERFORMING THIS AGREEMENT, DELAYS THE ANCILLARY AGREEMENTS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTRANSACTIONS.

Appears in 1 contract

Samples: Business Combination Agreement (Integral Acquisition Corp 1)

No Additional Representations or Warranties. Each of Parent, Merger Sub and Cardo acknowledges that the others have not made any representation, warranty or covenant, express or implied, as to the accuracy or completeness of any information regarding any of them, except as expressly set forth in this Agreement or the Disclosure Schedule. SUBJECT TO ANY RIGHTS ANY PARTY MAY HAVE UNDER LAW OR EQUITY WITH RESPECT TO FRAUD OR WILLFUL CONCEALMENT, EXCEPT FOR ANY EXPRESS THE REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS TERMS AND CONDITIONSAGREEMENT, THE PRODUCTS AND SERVICES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF NO PARTY MAKES ANY KIND. GIVEX MAKES NO REPRESENTATIONS REPRESENTATION OR WARRANTIESWARRANTY, EXPRESS OR IMPLIED, REGARDING THE PRODUCTSAT LAW, SERVICES, GIVEXPAY SERVICESIN EQUITY, OR GIVEX PLAFTORM OTHERWISE, IN RESPECT OF PARENT, MERGER SUB OR ANY ACQUIRED ENTITY, AS APPLICABLE, OR ANY OF THEIR RESPECTIVE ASSETS, LIABILITIES OR OPERATIONS, INCLUDING, WITHOUT LIMITATION, ANY IMPLIED REPRESENTATION OR WARRANTY AS TO BE PROVIDED HEREUNDER OR THEIR THE CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, SUITABILITY OR FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNETPURPOSE, AND THAT EACH SUCH PARTY EXPRESSLY DISCLAIMS ANY SUCH REPRESENTATION OR WARRANTY. ARTICLE VII CONDITIONS PRECEDENT TO THE SERVICES MAY BE SUBJECT TO LIMITATIONSCLOSING 7.1 Conditions Precedent to Each Party’s Obligation to Effect the Merger. The respective obligations of each party to effect the Merger and consummate the other transactions contemplated to occur in connection with the Closing shall be subject to the fulfillment or satisfaction, DELAYSprior to or on the Closing Date, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIESof the following conditions: (a) Governmental Authorities’ Approvals. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYSAll Governmental Authorities’ approvals required for the consummation of the Merger, DELIVERY FAILURESif any, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMSshall have been obtained. WITHOUT LIMITING THE FOREGOING(b) No Injunctions or Restraints. No temporary restraining order, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVEREDpreliminary or permanent injunction or other judgment issued by any court of competent jurisdiction or other legal restraint or prohibition that has the effect of preventing the consummation of the Merger or the Acquisitions shall be in effect, REPORTED OR REMEDIEDno Proceeding shall have been commenced by any Governmental Authority or any other Person for the purpose of obtaining any such injunction, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIESwrit or preliminary restraining order, and no written notice shall have been received by any party hereto from any Governmental Authority indicating an intent to investigate, restrain, prevent, delay or restructure the transactions contemplated by this Agreement. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORS7.2 Conditions Precedent to Obligations of Parent and Merger Sub. Parent’s and Merger Sub’s obligation to effect the Merger and consummate the other transactions contemplated to occur in connection with the Closing is subject to the satisfaction or waiver by Parent and Merger Sub of each condition precedent listed below.

Appears in 1 contract

Samples: Merger Agreement

No Additional Representations or Warranties. EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES SET FORTH AS EXPRESSLY PROVIDED IN THIS TERMS AND CONDITIONSAGREEMENT, THE PRODUCTS TRANSITION SERVICES AGREEMENT OR THE TRANSITION MARKS LICENSE AGREEMENT, NEITHER THE SELLER NOR THE INTERFACEFABRIC COMPANIES NOR THEIR RESPECTIVE AFFILIATES, NOR ANY OF THEIR RESPECTIVE DIRECTORS, OFFICERS, EMPLOYEES, SHAREHOLDERS, PARTNERS, MEMBERS OR REPRESENTATIVES, HAS MADE, OR IS MAKING, ANY REPRESENTATION OR WARRANTY WHATSOEVER TO THE BUYER OR ITS AFFILIATES OR REPRESENTATIVES AND SERVICES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, CONTEMPLATED TRANSACTIONS ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE PRODUCTS, SERVICES, GIVEXPAY SERVICES, OR GIVEX PLAFTORM TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES THE BUYER ACKNOWLEDGES THAT IT, TOGETHER WITH ITS ADVISORS, HAS MADE ITS OWN INVESTIGATION OF THE INTERFACEFABRIC COMPANIES AND IS NOT WARRANT RELYING ON (A) ANY IMPLIED WARRANTIES OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED(B) EXCEPT AS EXPRESSLY PROVIDED IN THIS AGREEMENT, REPORTED THE TRANSITION SERVICES AGREEMENT OR REMEDIEDTHE TRANSITION MARKS LICENSE AGREEMENT, ANY REPRESENTATION OR THAT THERE WILL NOT BE WARRANTY WHATSOEVER AS TO THE PROSPECTS (FINANCIAL OR OTHERWISE) OR THE VIABILITY OR LIKELIHOOD OF SUCCESS OF THE BUSINESS OF THE INTERFACEFABRIC COMPANIES AFTER THE CLOSING, PROVIDED ORALLY OR CONTAINED IN ANY SECURITY BREACHES MATERIALS PROVIDED BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR THE INTERFACEFABRIC COMPANIES OR ANY OTHER PARTY PROVIDING OF THEIR AFFILIATES OR ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTSTHEIR RESPECTIVE DIRECTORS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATESOFFICERS, EMPLOYEES, REPRESENTATIVESSHAREHOLDERS, AGENTS PARTNERS, MEMBERS OR CONTRACTORSREPRESENTATIVES OR OTHERWISE.

Appears in 1 contract

Samples: Stock Purchase Agreement (Interface Inc)

No Additional Representations or Warranties. THE COMPANY ACKNOWLEDGES AND AGREES THAT, NOTWITHSTANDING THE DELIVERY OR DISCLOSURE TO THE COMPANY OR ANY OF ITS AFFILIATES OR REPRESENTATIVES OF ANY DOCUMENTATION OR OTHER INFORMATION (INCLUDING ANY FINANCIAL PROJECTIONS OR OTHER SUPPLEMENTAL DATA), EXCEPT AS OTHERWISE SET FORTH IN ARTICLE IV, ARTICLE V OR THE ANCILLARY AGREEMENTS, (A) (I) NONE OF SPAC, AMALCO OR THEIR RESPECTIVE AFFILIATES OR REPRESENTATIVES OR ANY OTHER PERSON MAKES, AND SPAC AND AMALCO EXPRESSLY DISCLAIM, ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND OR NATURE, EXPRESS OR IMPLIED, IN CONNECTION WITH THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS, INCLUDING AS TO THE MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF SPAC, AMALCO OR ANY OF THEIR RESPECTIVE AFFILIATES OR REPRESENTATIVES OR IN ANY PRESENTATION OF THE BUSINESS AND AFFAIRS OF SPAC OR AMALCO BY THE MANAGEMENT OF SPAC OR OTHERS IN CONNECTION WITH THE TRANSACTIONS, AND (II) NONE OF PUBCO OR ITS AFFILIATES OR REPRESENTATIVES OR ANY OTHER PERSON MAKES, AND PUBCO EXPRESSLY DISCLAIMS, ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND OR NATURE, EXPRESS OR IMPLIED, IN CONNECTION WITH THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS, INCLUDING AS TO THE MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF PUBCO OR ANY OF ITS AFFILIATES OR REPRESENTATIVES OR IN ANY PRESENTATION OF THE BUSINESS AND AFFAIRS OF PUBCO BY THE MANAGEMENT OF PUBCO OR OTHERS IN CONNECTION WITH THE TRANSACTIONS, AND (B) NO STATEMENT CONTAINED IN ANY OF SUCH MATERIALS OR MADE IN ANY SUCH PRESENTATION SHALL BE DEEMED A REPRESENTATION OR WARRANTY HEREUNDER OR OTHERWISE OR DEEMED TO BE RELIED UPON BY THE COMPANY OR ANY OTHER PERSON IN EXECUTING, DELIVERING AND PERFORMING THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR THE TRANSACTIONS. THE COMPANY ACKNOWLEDGES AND AGREES THAT, EXCEPT FOR ANY EXPRESS THE REPRESENTATIONS AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONSARTICLE IV (AS QUALIFIED BY THE SPAC DISCLOSURE SCHEDULES) OR ARTICLE V OR THE ANCILLARY AGREEMENTS, THE PRODUCTS AND SERVICESANY COST ESTIMATES, PROJECTIONS OR OTHER PREDICTIONS, ANY DATA, ANY FINANCIAL INFORMATION OR ANY MEMORANDA OR OFFERING MATERIALS OR PRESENTATIONS, INCLUDING THE GIVEXPAY SERVICES ANY OFFERING MEMORANDUM OR SIMILAR MATERIALS MADE AVAILABLE BY OR ON BEHALF OF SPAC, AMALCO OR PUBCO ARE NOT AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE PRODUCTS, SERVICES, GIVEXPAY SERVICES, OR GIVEX PLAFTORM SHALL NOT BE DEEMED TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO TO INCLUDE REPRESENTATIONS OR WARRANTIES REGARDING OF SPAC, AMALCO, PUBCO OR ANY OTHER PERSON, AND THE RELIABILITYCOMPANY ACKNOWLEDGES AND AGREES THAT, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN ARTICLE IV OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES ARTICLE V OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY ANCILLARY AGREEMENTS, NONE OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES SUCH MATERIALS MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT IN RELIED UPON BY THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, COMPANY OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES PERSON IN EXECUTING, DELIVERING OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTSPERFORMING THIS AGREEMENT, DELAYS THE ANCILLARY AGREEMENTS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTRANSACTIONS.

Appears in 1 contract

Samples: Business Combination Agreement (Plum Acquisition Corp. III)

No Additional Representations or Warranties. EXCEPT FOR (a) BUYER ACKNOWLEDGES THAT NO SELLER PARTY OR ANY EXPRESS REPRESENTATIONS AFFILIATE, EMPLOYEE, AGENT OR OTHER REPRESENTATIVE OF THE SELLER PARTIES HAS MADE OR SHALL BE DEEMED TO HAVE MADE, AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONSTHAT BUYER HAS NOT RELIED ON, THE PRODUCTS AND SERVICES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS REPRESENTATION OR WARRANTIESWARRANTY, EXPRESS OR IMPLIED, REGARDING WITH RESPECT TO THE PRODUCTSSELLER PARTIES, SERVICESTHE INTERESTS, GIVEXPAY SERVICESTHE BUSINESS OR THE TRANSACTIONS CONTEMPLATED HEREUNDER, OTHER THAN THE REPRESENTATIONS AND WARRANTIES THAT ARE EXPRESSLY FORTH IN ARTICLE III OF THIS AGREEMENT. (b) EXCEPT FOR THE EXPRESS REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN ARTICLE IV OF THIS AGREEMENT, BUYER DISCLAIMS ALL LIABILITY AND RESPONSIBILITY FOR ANY REPRESENTATION, WARRANTY, STATEMENT MADE OR INFORMATION COMMUNICATED (WHETHER ORALLY OR IN WRITING) TO ANY SELLER PARTY OR ITS AFFILIATES OR REPRESENTATIVES (INCLUDING ANY OPINION, INFORMATION OR ADVICE WHICH MAY HAVE BEEN PROVIDED TO ANY SELLER PARTY OR ITS AFFILIATES OR REPRESENTATIVES BY ANY PERSON, INCLUDING ANY DIRECTOR, OFFICER, EMPLOYEE, ACCOUNTING FIRM, LEGAL COUNSEL, OR GIVEX PLAFTORM TO BE PROVIDED HEREUNDER OTHER AGENT, CONSULTANT, OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE REPRESENTATIVE OF BUYER OR USE BY MERCHANT OR ANY THIRD-PARTYITS AFFILIATES). GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE BUYER MAKES NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITYTO ANY SELLER PARTY EXCEPT AS EXPRESSLY CONTAINED IN ARTICLE IV OF THIS AGREEMENT, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY AND ANY AND ALL STATEMENTS MADE OR COMPLETENESS INFORMATION COMMUNICATED BY BUYER OR ITS AFFILIATES OR ANY OF THEIR REPRESENTATIVES OUTSIDE OF THIS AGREEMENT (INCLUDING BY WAY OF THE SERVICESDOCUMENTS PROVIDED IN RESPONSE TO ANY SELLER PARTY’S WRITTEN DILIGENCE REQUESTS), GIVEXPAY SERVICESWHETHER VERBALLY OR IN WRITING, GIVEX PLATFORMARE DEEMED TO HAVE BEEN SUPERSEDED BY THIS AGREEMENT, PROCESSING SERVICES IT BEING AGREED THAT NO SUCH PRIOR OR CONTEMPORANEOUS STATEMENTS OR COMMUNICATIONS OUTSIDE OF THIS AGREEMENT SHALL SURVIVE THE RESULTS MERCHANT MAY OBTAIN BY USING EXECUTION AND DELIVERY OF THIS AGREEMENT. (c) NOTWITHSTANDING ANY PROVISION HEREIN TO THE CONTRARY, NOTHING IN THIS SECTION 0 IS INTENDED TO OR IS INTENDED TO PRECLUDE OR OTHERWISE LIMIT ANY CLAIM OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSFRAUD.

Appears in 1 contract

Samples: Membership Interest Purchase Agreement (Assisted 4 Living, Inc.)

No Additional Representations or Warranties. NOTWITHSTANDING THE DELIVERY OR DISCLOSURE TO SPAC OR ANY OF ITS REPRESENTATIVES OF ANY DOCUMENTATION OR OTHER INFORMATION (INCLUDING ANY FINANCIAL PROJECTIONS OR OTHER SUPPLEMENTAL DATA), EXCEPT AS OTHERWISE SET FORTH IN THIS ARTICLE ‎III, THE ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, (A) NONE OF THE COMPANY, ANY COMPANY NON-RECOURSE PARTY OR ANY OTHER PERSON MAKES, AND THE COMPANY EXPRESSLY DISCLAIMS, ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND OR NATURE, EXPRESS OR IMPLIED, IN CONNECTION WITH THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY, INCLUDING AS TO THE MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF THE RUMBLE COMPANIES THAT HAVE BEEN MADE AVAILABLE TO SPAC OR ANY OF ITS REPRESENTATIVES OR IN ANY PRESENTATION OF THE BUSINESS AND AFFAIRS OF THE RUMBLE COMPANIES BY THE MANAGEMENT OF THE COMPANY OR OTHERS IN CONNECTION WITH THE TRANSACTIONS CONTEMPLATED HEREBY OR BY THE ANCILLARY AGREEMENTS, AND (B) NO STATEMENT CONTAINED IN ANY OF SUCH MATERIALS OR MADE IN ANY SUCH PRESENTATION SHALL BE DEEMED A REPRESENTATION OR WARRANTY HEREUNDER OR OTHERWISE OR DEEMED TO BE RELIED UPON BY SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON IN EXECUTING, DELIVERING AND PERFORMING THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY. EXCEPT FOR ANY EXPRESS THE REPRESENTATIONS AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONSARTICLE ‎III, THE PRODUCTS AND SERVICESANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, IT IS UNDERSTOOD THAT ANY COST ESTIMATES, PROJECTIONS OR OTHER PREDICTIONS, ANY DATA, ANY FINANCIAL INFORMATION OR ANY MEMORANDA OR OFFERING MATERIALS OR PRESENTATIONS, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORMANY OFFERING MEMORANDUM OR SIMILAR MATERIALS MADE AVAILABLE BY ANY RUMBLE COMPANY, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE PRODUCTS, SERVICES, GIVEXPAY SERVICES, OR GIVEX PLAFTORM NOT AND SHALL NOT BE DEEMED TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO TO INCLUDE REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICESCOMPANY, GIVEXPAY SERVICESANY COMPANY NON-RECOURSE PARTY OR ANY OTHER PERSON, GIVEX PLATFORMAND, PROCESSING SERVICES EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES SET FORTH IN THIS ARTICLE ‎III, THE ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, ARE NOT AND SHALL NOT BE DEEMED TO BE RELIED UPON BY SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON IN EXECUTING, DELIVERING OR PERFORMING THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT TRANSACTIONS CONTEMPLATED HEREBY OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTHEREBY.

Appears in 1 contract

Samples: Business Combination Agreement (CF Acquisition Corp. VI)

No Additional Representations or Warranties. EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES AS OTHERWISE EXPRESSLY SET FORTH IN THIS TERMS AND CONDITIONSARTICLE III CAMPUS, THE PRODUCTS PROPERTY ENTITIES, THE DEVELOPMENT ENTITIES, CAMPUS DEVELOPER OWNER AND SERVICES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY CAMPUS DEVELOPER EACH EXPRESSLY DISCLAIM ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS AND EVERY KIND OR WARRANTIESNATURE, EXPRESS OR IMPLIED, REGARDING INCLUDING AS TO THE PRODUCTSCONDITION, SERVICESVALUE OR QUALITY OR INCOME OR EXPENSES OF ANY OF THE EXISTING CAMPUS PROPERTIES OR THE CAMPUS DEVELOPMENT PROPERTIES OR ANY OTHER ASSETS OR RIGHTS TO BE TRANSFERRED HEREUNDER OR THE AMOUNTS OF THE REAL ESTATE AND OTHER TAXES TO BE IMPOSED IN RESPECT OF ANY OR ALL SUCH PROVISIONS, GIVEXPAY SERVICESAND CAMPUS, THE PROPERTY ENTITIES, THE DEVELOPMENT ENTITIES, CAMPUS DEVELOPER OWNER AND CAMPUS DEVELOPER EACH SPECIFICALLY DISCLAIM ANY REPRESENTATION OR WARRANTY OF MERCHANTABILITY, USAGE, SUITABILITY OR FITNESS FOR ANY PARTICULAR PURPOSE WITH RESPECT TO THE EXISTING CAMPUS PROPERTIES OR THE CAMPUS DEVELOPMENT PROPERTIES OR ANY OTHER ASSETS OR RIGHTS TO BE TRANSFERRED (DIRECTLY OR INDIRECTLY) HEREUNDER OR AS TO THE PHYSICAL CONDITION OR OTHER ATTRIBUTES THEREOF, OR GIVEX PLAFTORM THE ABSENCE OF ANY DEFECTS THEREIN, WHETHER LATENT OR PATENT, IT BEING UNDERSTOOD THAT, EXCEPT AS SET FORTH IN THIS ARTICLE III, THE EXISTING CAMPUS PROPERTIES, THE CAMPUS DEVELOPMENT PROPERTIES AND THE OTHER ASSETS AND RIGHTS TO BE PROVIDED ACQUIRED BY PURCHASER HEREUNDER OR THEIR CONDITIONARE BEING ACQUIRED “AS IS, MERCHANTABILITYWHERE IS” ON THE INITIAL CLOSING DATE, NON-INFRINGEMENTTHE DEVELOPMENT PROPERTY CLOSING DATE AND THE DEFERRED CLOSING DATE, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNETAS APPLICABLE, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONSPURCHASER, DELAYS, PURCHASER MERGER SUBS AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) PURCHASER OP SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR RELY ON ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSOWN EXAMINATION AND INVESTIGATION THEREOF.

Appears in 1 contract

Samples: Merger Agreement (American Campus Communities Operating Partnership LP)

No Additional Representations or Warranties. EXCEPT FOR (a) NO SELLER PARTY NOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONS, THE PRODUCTS AND SERVICES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ITS RESPECTIVE REPRESENTATIVES HAS MADE ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING OF ANY NATURE WHATSOEVER RELATING TO THE PRODUCTSACQUIRED EQUITY, SERVICESTHE TARGET COMPANIES OR THE BUSINESS OR OTHERWISE IN CONNECTION WITH THE TRANSACTIONS CONTEMPLATED HEREBY, GIVEXPAY SERVICES, OR GIVEX PLAFTORM TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OTHER THAN THOSE REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS SECTION 3 AND SECTION 4 OR ANY THIRD-PARTYOTHER TRANSACTION DOCUMENT. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. (b) WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX NEITHER SUCH SELLER PARTY NOR ANY REPRESENTATIVE OF SUCH SELLER PARTY, NOR (AS APPLICABLE) ANY OF THEIR RESPECTIVE EMPLOYEES, OFFICERS, DIRECTORS OR EQUITYHOLDERS, HAS MADE, AND ITS THIRD-PARTY PROVIDERS DO SHALL NOT REPRESENT BE DEEMED TO HAVE MADE, ANY REPRESENTATIONS OR WARRANT THAT (A) WARRANTIES IN THE OPERATION MATERIALS RELATING TO THE BUSINESS MADE AVAILABLE OR USE DELIVERED TO THE BUYER, INCLUDING DUE DILIGENCE MATERIALS, OR IN ANY PRESENTATION OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY BUSINESS OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL TARGET COMPANIES BY MANAGEMENT OF THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, TARGET COMPANIES OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORS.OTHERS

Appears in 1 contract

Samples: Equity Purchase Agreement (Granite Construction Inc)

AutoNDA by SimpleDocs

No Additional Representations or Warranties. EXCEPT FOR ANY EXPRESS REPRESENTATIONS OF SELLER AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONS, THE PRODUCTS AND SERVICES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT SALE: BUYER(S) ACKNOWLEDGE AND AGREE THAT SELLERS HAVE NOT MADE, AND SELLERS HEREBY SPECIFICALLY DISCLAIM, ANY REPRESENTATION OR WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS , ORAL OR WARRANTIESWRITTEN, EXPRESS EXPRESSED OR IMPLIED, REGARDING OR ARISING BY OPERATION OF LAW, WITH RESPECT TO THE PRODUCTSPROPERTY, SERVICESINCLUDING, GIVEXPAY SERVICESBUT NOT LIMITED TO, ANY WARRANTIES OR GIVEX PLAFTORM REPRESENTATIONS AS TO BE PROVIDED HEREUNDER OR THEIR CONDITIONHABITABILITY, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE PURPOSE, TITLE, ZONING, TAX CONSEQUENCES, PHYSICAL OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING ENVIRONMENTAL CONDITIONS, UTILITIES, FLOOD PLAIN COMPLIANCE, VALUATION, GOVERNMENTAL APPROVALS, THE RELIABILITYCOMPLIANCE OF THE PROPERTY WITH GOVERNMENTAL LAWS, AVAILABILITY, TIMELINESS, SUITABILITYTHE TRUTH, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES ANY INFORMATION PROVIDED BY OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY ON BEHALF OF THESE SERVICESSELLERS TO BUYER(S). WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (ABUYER(S) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND AGREE THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONSPROPERTY IS BEING SOLD ON AN “AS IS, DELAYSWHERE IS AND WITH ALL FAULTS” BASIS. UPON CLOSING, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICESBUYER(S) SHALL BE RESPONSIBLE FOR RELEASE AND WAIVE ANY FAULTSCLAIMS BUYER(S) MAY HAVE AGAINST XXXXXXX AND SHALL DEFEND, DELAYS INDEMNIFY AND HOLD SELLERS HARMLESS FROM ANY CLAIMS, DEMANDS OR INTERRUPTIONS IN CAUSES OF ACTION RELATING TO THE GIVEXPAY SERVICES ABOVE. BUYER(S) ACKNOWLEDGE THE PROPERTY HAS FOUR INCHES (4") OR PROCESSING SERVICES THAT ARE A RESULT MORE OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT TOPSOIL AT TIME OF ANY MISUSE CLOSING. THE PROVISIONS OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTHIS SECTION SHALL SURVIVE THE CLOSING HEREUNDER.

Appears in 1 contract

Samples: Purchase Agreement

No Additional Representations or Warranties. NOTWITHSTANDING THE DELIVERY OR DISCLOSURE TO THE COMPANY OR ANY OF ITS REPRESENTATIVES OF ANY DOCUMENTATION OR OTHER INFORMATION (INCLUDING ANY FINANCIAL PROJECTIONS OR OTHER SUPPLEMENTAL DATA), EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES AS OTHERWISE EXPRESSLY SET FORTH IN THIS TERMS AND CONDITIONSARTICLE IV (AS MODIFIED BY THE SPAC DISCLOSURE SCHEDULES), THE PRODUCTS ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, (A) SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON DO NOT MAKE, AND SERVICESSPAC EXPRESSLY DISCLAIMS AND NEGATES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS KIND OR WARRANTIESNATURE, EXPRESS OR IMPLIED, REGARDING (I) IN CONNECTION WITH THIS AGREEMENT, THE PRODUCTSANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY, SERVICES(II) WITH RESPECT TO SPAC, GIVEXPAY SERVICESINCLUDING ITS AFFAIRS, THE CONDITION, VALUE OR QUALITY OF THE ASSETS, LIABILITIES, FINANCIAL CONDITION OR RESULTS OF OPERATIONS, OR GIVEX PLAFTORM (III) WITH RESPECT TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF ANY STATEMENT OR INFORMATION THAT HAVE BEEN MADE AVAILABLE TO THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES COMPANY OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING ITS REPRESENTATIVES, INCLUDING THE GENERALITY MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF SPAC OR ANY PRESENTATION OF THE FOREGOING, GIVEX BUSINESS AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE AFFAIRS OF THE SERVICES WILL BE TIMELYCOMPANY BY THE MANAGEMENT OF THE COMPANY OR OTHERS IN CONNECTION WITH THE TRANSACTIONS CONTEMPLATED HEREBY OR BY THE ANCILLARY AGREEMENTS, UNINTERRUPTED OR ERROR- FREE; OR AND (B) NO STATEMENT OR INFORMATION CONTAINED IN ANY OF SUCH MATERIALS OR MADE IN ANY SUCH PRESENTATION SHALL BE DEEMED A REPRESENTATION OR WARRANTY HEREUNDER OR OTHERWISE OR DEEMED TO BE RELIED UPON BY THE QUALITY COMPANY, ANY COMPANY NON-RECOURSE PARTY OR ANY OTHER PERSON IN EXECUTING, DELIVERING AND PERFORMING THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY. EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE IV, THE ANCILLARY AGREEMENTS OR IN THE CASE OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES FRAUD, IT IS UNDERSTOOD THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIESANY COST ESTIMATES, PROJECTIONS, FORECASTS, BUDGETS OR OTHER PREDICTIONS, ANY DATA, ANY FINANCIAL INFORMATION OR ANY MEMORANDA OR OFFERING MATERIALS OR PRESENTATIONS, INCLUDING ANY OFFERING MEMORANDUM OR SIMILAR MATERIALS MADE AVAILABLE BY SPAC, ARE NOT AND SHALL NOT BE DEEMED TO BE OR TO INCLUDE REPRESENTATIONS OR WARRANTIES OF SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON, AND, EXCEPT FOR THE INTERNETREPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE IV, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT ANCILLARY AGREEMENTS OR IN THE USE CASE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS FRAUD, ARE NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL AND SHALL NOT BE DEEMED TO BE RELIED UPON BY THE COMPANY, ANY SECURITY BREACHES BY THIRDCOMPANY NON-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR RECOURSE PARTY OR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES PERSON IN EXECUTING, DELIVERING OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTSPERFORMING THIS AGREEMENT, DELAYS THE ANCILLARY AGREEMENTS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES TRANSACTIONS CONTEMPLATED HEREBY OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTHEREBY.

Appears in 1 contract

Samples: Business Combination Agreement (Jupiter Acquisition Corp)

No Additional Representations or Warranties. EXCEPT FOR AS EXPRESSLY PROVIDED IN ARTICLE III AND THIS ARTICLE IV, IN THE RELATED AGREEMENTS AND IN ANY EXPRESS REPRESENTATIONS AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONSCERTIFICATE DELIVERED HEREUNDER OR THEREUNDER, NONE OF THE SELLERS, THE PRODUCTS AND SERVICESCOMPANY NOR THE SUBSIDIARIES OR ANY OF THEIR AFFILIATES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORMNOR ANY OF THEIR RESPECTIVE DIRECTORS, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OFFICERS, EMPLOYEES, SHAREHOLDERS, PARTNERS, MEMBERS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE PRODUCTS, SERVICES, GIVEXPAY SERVICESREPRESENTATIVES HAS MADE, OR GIVEX PLAFTORM IS MAKING, ANY REPRESENTATION OR WARRANTY WHATSOEVER TO BE BUYER OR ITS AFFILIATES WITH REGARD TO THIS AGREEMENT, THE RELATED AGREEMENTS, AND THE TRANSACTIONS CONTEMPLATED HEREBY AND THEREBY AND, EXCEPT AS EXPRESSLY PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT UNDER THIS AGREEMENT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-RELATED AGREEMENT, NO SUCH PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING SHALL BE LIABLE IN RESPECT OF THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF ANY INFORMATION PROVIDED TO BUYER OR ITS AFFILIATES WITH REGARD TO THIS AGREEMENT, THE SERVICESRELATED AGREEMENTS, GIVEXPAY SERVICESAND THE TRANSACTIONS CONTEMPLATED HEREBY AND THEREBY. FOR THE PURPOSES HEREIN, GIVEX PLATFORMANY INFORMATION PROVIDED TO, PROCESSING SERVICES OR MADE AVAILABLE TO, BUYER BY OR ON BEHALF OF ANY OF SELLERS, THE COMPANY OR THE RESULTS MERCHANT MAY OBTAIN BY USING SUBSIDIARIES SHALL INCLUDE ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT ALL INFORMATION THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT CONTAINED OR POSTED IN ANY ELECTRONIC DATA ROOM ESTABLISHED BY SELLERS OR THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING SELLERS’ REPRESENTATIVE IN CONNECTION WITH THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES TRANSACTIONS CONTEMPLATED BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTHIS AGREEMENT.

Appears in 1 contract

Samples: Share Purchase Agreement (Emergent BioSolutions Inc.)

No Additional Representations or Warranties. NOTWITHSTANDING THE DELIVERY OR DISCLOSURE TO THE COMPANY, THE SELLERS OR ANY OF THEIR REPRESENTATIVES OF ANY DOCUMENTATION OR OTHER INFORMATION (INCLUDING ANY FINANCIAL PROJECTIONS OR OTHER SUPPLEMENTAL DATA), EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES AS OTHERWISE EXPRESSLY SET FORTH IN THIS TERMS AND CONDITIONSARTICLE V (AS MODIFIED BY THE SPAC DISCLOSURE SCHEDULES), THE PRODUCTS ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, (A) SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON DO NOT MAKE, AND SERVICESSPAC EXPRESSLY DISCLAIMS AND NEGATES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS KIND OR WARRANTIESNATURE, EXPRESS OR IMPLIED, REGARDING (I) IN CONNECTION WITH THIS AGREEMENT, THE PRODUCTSANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS, SERVICES(II) WITH RESPECT TO SPAC, GIVEXPAY SERVICESINCLUDING ITS AFFAIRS, THE CONDITION, VALUE OR QUALITY OF THE ASSETS, LIABILITIES, FINANCIAL CONDITION OR RESULTS OF OPERATIONS, OR GIVEX PLAFTORM (III) WITH RESPECT TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF ANY STATEMENT OR INFORMATION THAT HAVE BEEN MADE AVAILABLE TO THE SERVICESCOMPANY, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES THE SELLERS OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THEIR REPRESENTATIVES, INCLUDING THE GENERALITY MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF SPAC OR ANY PRESENTATION OF THE FOREGOING, GIVEX BUSINESS AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE AFFAIRS OF THE SERVICES WILL BE TIMELYCOMPANY BY THE MANAGEMENT OF THE COMPANY OR OTHERS IN CONNECTION WITH THE TRANSACTIONS, UNINTERRUPTED OR ERROR- FREE; OR AND (B) NO STATEMENT OR INFORMATION CONTAINED IN ANY OF SUCH MATERIALS OR MADE IN ANY SUCH PRESENTATION SHALL BE DEEMED A REPRESENTATION OR WARRANTY HEREUNDER OR OTHERWISE OR DEEMED TO BE RELIED UPON BY THE QUALITY COMPANY, THE SELLERS, ANY COMPANY NON-RECOURSE PARTY OR ANY OTHER PERSON IN EXECUTING, DELIVERING AND PERFORMING THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR THE TRANSACTIONS. EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE V, THE ANCILLARY AGREEMENTS OR IN THE CASE OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES FRAUD, IT IS UNDERSTOOD THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIESANY COST ESTIMATES, PROJECTIONS, FORECASTS, BUDGETS OR OTHER PREDICTIONS, ANY DATA, ANY FINANCIAL INFORMATION OR ANY MEMORANDA OR OFFERING MATERIALS OR PRESENTATIONS, INCLUDING ANY OFFERING MEMORANDUM OR SIMILAR MATERIALS MADE AVAILABLE BY SPAC, ARE NOT AND SHALL NOT BE DEEMED TO BE OR TO INCLUDE REPRESENTATIONS OR WARRANTIES OF SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON, AND, EXCEPT FOR THE INTERNETREPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE V, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT ANCILLARY AGREEMENTS OR IN THE USE CASE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS FRAUD, ARE NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL AND SHALL NOT BE DEEMED TO BE RELIED UPON BY THE COMPANY, THE SELLERS ANY SECURITY BREACHES BY THIRDCOMPANY NON-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR RECOURSE PARTY OR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES PERSON IN EXECUTING, DELIVERING OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTSPERFORMING THIS AGREEMENT, DELAYS THE ANCILLARY AGREEMENTS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTRANSACTIONS.

Appears in 1 contract

Samples: Business Combination Agreement (Integral Acquisition Corp 1)

No Additional Representations or Warranties. EXCEPT FOR (a) BUYER ACKNOWLEDGES THAT NO SELLER PARTY OR ANY EXPRESS REPRESENTATIONS AFFILIATE, EMPLOYEE, AGENT OR OTHER REPRESENTATIVE OF THE SELLER PARTIES HAS MADE OR SHALL BE DEEMED TO HAVE MADE, AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONSTHAT BUYER HAS NOT RELIED ON, THE PRODUCTS AND SERVICES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS REPRESENTATION OR WARRANTIESWARRANTY, EXPRESS OR IMPLIED, REGARDING WITH RESPECT TO THE PRODUCTSSELLER PARTIES, SERVICESTHE INTERESTS, GIVEXPAY SERVICESTHE BUSINESS OR THE TRANSACTIONS CONTEMPLATED HEREUNDER, OTHER THAN THE REPRESENTATIONS AND WARRANTIES THAT ARE EXPRESSLY FORTH IN ARTICLE III OF THIS AGREEMENT. (b) EXCEPT FOR THE EXPRESS REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN ARTICLE IV OF THIS AGREEMENT, BUYER DISCLAIMS ALL LIABILITY AND RESPONSIBILITY FOR ANY REPRESENTATION, WARRANTY, STATEMENT MADE OR INFORMATION COMMUNICATED (WHETHER ORALLY OR IN WRITING) TO ANY SELLER PARTY OR ITS AFFILIATES OR REPRESENTATIVES (INCLUDING ANY OPINION, INFORMATION OR ADVICE WHICH MAY HAVE BEEN PROVIDED TO ANY SELLER PARTY OR ITS AFFILIATES OR REPRESENTATIVES BY ANY PERSON, INCLUDING ANY DIRECTOR, OFFICER, EMPLOYEE, ACCOUNTING FIRM, LEGAL COUNSEL, OR GIVEX PLAFTORM TO BE PROVIDED HEREUNDER OTHER AGENT, CONSULTANT, OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE REPRESENTATIVE OF BUYER OR USE BY MERCHANT OR ANY THIRD-PARTYITS AFFILIATES). GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE BUYER MAKES NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITYTO ANY SELLER PARTY EXCEPT AS EXPRESSLY CONTAINED IN ARTICLE IV OF THIS AGREEMENT, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY AND ANY AND ALL STATEMENTS MADE OR COMPLETENESS INFORMATION COMMUNICATED BY BUYER OR ITS AFFILIATES OR ANY OF THEIR REPRESENTATIVES OUTSIDE OF THIS AGREEMENT (INCLUDING BY WAY OF THE SERVICESDOCUMENTS PROVIDED IN RESPONSE TO ANY SELLER PARTY’S WRITTEN DILIGENCE REQUESTS), GIVEXPAY SERVICESWHETHER VERBALLY OR IN WRITING, GIVEX PLATFORMARE DEEMED TO HAVE BEEN SUPERSEDED BY THIS AGREEMENT, PROCESSING SERVICES IT BEING AGREED THAT NO SUCH PRIOR OR CONTEMPORANEOUS STATEMENTS OR COMMUNICATIONS OUTSIDE OF THIS AGREEMENT SHALL SURVIVE THE RESULTS MERCHANT MAY OBTAIN BY USING EXECUTION AND DELIVERY OF THIS AGREEMENT. (c) NOTWITHSTANDING ANY PROVISION HEREIN TO THE CONTRARY, NOTHING IN THIS SECTION 4.7 IS INTENDED TO OR IS INTENDED TO PRECLUDE OR OTHERWISE LIMIT ANY CLAIM OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSFRAUD.

Appears in 1 contract

Samples: Membership Interest Purchase Agreement (Assisted 4 Living, Inc.)

No Additional Representations or Warranties. EACH OF SPAC AND AMALCO ACKNOWLEDGES AND AGREES THAT, NOTWITHSTANDING THE DELIVERY OR DISCLOSURE TO SPAC, AMALCO OR ANY OF THEIR RESPECTIVE AFFILIATES OR REPRESENTATIVES OF ANY DOCUMENTATION OR OTHER INFORMATION (INCLUDING ANY FINANCIAL PROJECTIONS OR OTHER SUPPLEMENTAL DATA), EXCEPT AS OTHERWISE SET FORTH IN ARTICLE III, ARTICLE V OR THE ANCILLARY AGREEMENTS, (A) (I) NONE OF THE COMPANY, ITS AFFILIATES OR REPRESENTATIVES OR ANY OTHER PERSON MAKES, AND THE COMPANY EXPRESSLY DISCLAIMS, ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND OR NATURE, EXPRESS OR IMPLIED, IN CONNECTION WITH THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS, INCLUDING AS TO THE MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF THE COMPANY OR ANY OF ITS AFFILIATES OR REPRESENTATIVES OR IN ANY PRESENTATION OF THE BUSINESS AND AFFAIRS OF THE COMPANY BY THE MANAGEMENT OF THE COMPANY OR OTHERS IN CONNECTION WITH THE TRANSACTIONS, AND (II) NONE OF PUBCO OR ITS AFFILIATES OR REPRESENTATIVES OR ANY OTHER PERSON MAKES, AND PUBCO EXPRESSLY DISCLAIMS, ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND OR NATURE, EXPRESS OR IMPLIED, IN CONNECTION WITH THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS, INCLUDING AS TO THE MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF PUBCO OR ANY OF ITS AFFILIATES OR REPRESENTATIVES OR IN ANY PRESENTATION OF THE BUSINESS AND AFFAIRS OF PUBCO BY THE MANAGEMENT OF PUBCO OR OTHERS IN CONNECTION WITH THE TRANSACTIONS, AND (B) NO STATEMENT CONTAINED IN ANY OF SUCH MATERIALS OR MADE IN ANY SUCH PRESENTATION SHALL BE DEEMED A REPRESENTATION OR WARRANTY HEREUNDER OR OTHERWISE OR DEEMED TO BE RELIED UPON BY SPAC, AMALCO OR ANY OTHER PERSON IN EXECUTING, DELIVERING AND PERFORMING THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR THE TRANSACTIONS. EACH OF SPAC AND AMALCO ACKNOWLEDGES AND AGREES THAT, EXCEPT FOR ANY EXPRESS THE REPRESENTATIONS AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONSARTICLE III (AS QUALIFIED BY THE COMPANY DISCLOSURE SCHEDULES) OR ARTICLE V OR THE ANCILLARY AGREEMENTS, THE PRODUCTS AND SERVICESANY COST ESTIMATES, PROJECTIONS OR OTHER PREDICTIONS, ANY DATA, ANY FINANCIAL INFORMATION OR ANY MEMORANDA OR OFFERING MATERIALS OR PRESENTATIONS, INCLUDING ANY OFFERING MEMORANDUM OR SIMILAR MATERIALS MADE AVAILABLE BY OR ON BEHALF OF THE GIVEXPAY SERVICES COMPANY OR PUBCO ARE NOT AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE PRODUCTS, SERVICES, GIVEXPAY SERVICES, OR GIVEX PLAFTORM SHALL NOT BE DEEMED TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO TO INCLUDE REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICESCOMPANY, GIVEXPAY SERVICESPUBCO OR ANY OTHER PERSON, GIVEX PLATFORMAND EACH OF SPAC AND AMALCO ACKNOWLEDGES AND AGREES THAT, PROCESSING SERVICES EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN ARTICLE III OR ARTICLE V OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY ANCILLARY AGREEMENTS, NONE OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES SUCH MATERIALS MAY BE SUBJECT TO LIMITATIONSRELIED UPON BY SPAC, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, AMALCO OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES PERSON IN EXECUTING, DELIVERING OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTSPERFORMING THIS AGREEMENT, DELAYS THE ANCILLARY AGREEMENTS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTRANSACTIONS.

Appears in 1 contract

Samples: Business Combination Agreement (Plum Acquisition Corp. III)

No Additional Representations or Warranties. PUBCO ACKNOWLEDGES AND AGREES THAT, NOTWITHSTANDING THE DELIVERY OR DISCLOSURE TO PUBCO OR ANY OF ITS AFFILIATES OR REPRESENTATIVES OF ANY DOCUMENTATION OR OTHER INFORMATION (INCLUDING ANY FINANCIAL PROJECTIONS OR OTHER SUPPLEMENTAL DATA), EXCEPT AS OTHERWISE SET FORTH IN ARTICLE III, ARTICLE IV OR THE ANCILLARY AGREEMENTS, (A) (I) NONE OF THE COMPANY, ITS AFFILIATES OR REPRESENTATIVES OR ANY OTHER PERSON MAKES, AND THE COMPANY EXPRESSLY DISCLAIMS, ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND OR NATURE, EXPRESS OR IMPLIED, IN CONNECTION WITH THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS, INCLUDING AS TO THE MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF THE COMPANY OR ANY OF ITS AFFILIATES OR REPRESENTATIVES OR IN ANY PRESENTATION OF THE BUSINESS AND AFFAIRS OF THE COMPANY BY THE MANAGEMENT OF THE COMPANY OR OTHERS IN CONNECTION WITH THE TRANSACTIONS, AND (II) NONE OF SPAC, AMALCO OR THEIR RESPECTIVE AFFILIATES OR REPRESENTATIVES OR ANY OTHER PERSON MAKES, AND SPAC AND AMALCO EXPRESSLY DISCLAIM, ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND OR NATURE, EXPRESS OR IMPLIED, IN CONNECTION WITH THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS, INCLUDING AS TO THE MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF SPAC AND AMALCO OR ANY OF THEIR RESPECTIVE AFFILIATES OR REPRESENTATIVES OR IN ANY PRESENTATION OF THE BUSINESS AND AFFAIRS OF SPAC OR AMALCO BY THE MANAGEMENT OF SPAC OR OTHERS IN CONNECTION WITH THE TRANSACTIONS, AND (B) NO STATEMENT CONTAINED IN ANY OF SUCH MATERIALS OR MADE IN ANY SUCH PRESENTATION SHALL BE DEEMED A REPRESENTATION OR WARRANTY HEREUNDER OR OTHERWISE OR DEEMED TO BE RELIED UPON BY PUBCO OR ANY OTHER PERSON IN EXECUTING, DELIVERING AND PERFORMING THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR THE TRANSACTIONS. PUBCO ACKNOWLEDGES AND AGREES THAT, EXCEPT FOR ANY EXPRESS THE REPRESENTATIONS AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONSARTICLE III (AS QUALIFIED BY THE COMPANY DISCLOSURE SCHEDULES) OR ARTICLE IV (AS QUALIFED BY THE SPAC DISCLOSURE SCHEDULES) OR THE ANCILLARY AGREEMENTS, THE PRODUCTS AND SERVICESANY COST ESTIMATES, PROJECTIONS OR OTHER PREDICTIONS, ANY DATA, ANY FINANCIAL INFORMATION OR ANY MEMORANDA OR OFFERING MATERIALS OR PRESENTATIONS, INCLUDING ANY OFFERING MEMORANDUM OR SIMILAR MATERIALS MADE AVAILABLE BY OR ON BEHALF OF THE GIVEXPAY SERVICES COMPANY, SPAC OR AMALCO ARE NOT AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE PRODUCTS, SERVICES, GIVEXPAY SERVICES, OR GIVEX PLAFTORM SHALL NOT BE DEEMED TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO TO INCLUDE REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICESCOMPANY, GIVEXPAY SERVICESSPAC, GIVEX PLATFORMAMALCO OR ANY OTHER PERSON, PROCESSING SERVICES AND PUBCO ACKNOWLEDGES AND AGREES THAT, EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN ARTICLE III OR ARTICLE IV OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY ANCILLARY AGREEMENTS, NONE OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES SUCH MATERIALS MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, RELIED UPON BY PUBCO OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES PERSON IN EXECUTING, DELIVERING OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTSPERFORMING THIS AGREEMENT, DELAYS THE ANCILLARY AGREEMENTS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTRANSACTIONS.

Appears in 1 contract

Samples: Business Combination Agreement (Plum Acquisition Corp. III)

No Additional Representations or Warranties. NOTWITHSTANDING THE DELIVERY OR DISCLOSURE TO THE COMPANY OR ANY OF ITS REPRESENTATIVES OF ANY DOCUMENTATION OR OTHER INFORMATION (INCLUDING ANY FINANCIAL PROJECTIONS OR OTHER SUPPLEMENTAL DATA), EXCEPT AS OTHERWISE SET FORTH IN THIS ARTICLE ‎IV, THE ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, (A) NONE OF SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON MAKES, AND SPAC EXPRESSLY DISCLAIMS, ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND OR NATURE, EXPRESS OR IMPLIED, IN CONNECTION WITH THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY, INCLUDING AS TO THE MATERIALS RELATING TO THE BUSINESS AND AFFAIRS OR HOLDINGS OF SPAC THAT HAVE BEEN MADE AVAILABLE TO THE COMPANY OR ANY OF ITS REPRESENTATIVES OR IN ANY PRESENTATION OF THE BUSINESS AND AFFAIRS OF THE COMPANY BY THE MANAGEMENT OF THE COMPANY OR OTHERS IN CONNECTION WITH THE TRANSACTIONS CONTEMPLATED HEREBY OR BY THE ANCILLARY AGREEMENTS, AND (B) NO STATEMENT CONTAINED IN ANY OF SUCH MATERIALS OR MADE IN ANY SUCH PRESENTATION SHALL BE DEEMED A REPRESENTATION OR WARRANTY HEREUNDER OR OTHERWISE OR DEEMED TO BE RELIED UPON BY THE COMPANY, ANY COMPANY NON-RECOURSE PARTY OR ANY OTHER PERSON IN EXECUTING, DELIVERING AND PERFORMING THIS AGREEMENT, THE ANCILLARY AGREEMENTS OR THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY. EXCEPT FOR ANY EXPRESS THE REPRESENTATIONS AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONSARTICLE ‎IV, THE PRODUCTS AND SERVICESANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, IT IS UNDERSTOOD THAT ANY COST ESTIMATES, PROJECTIONS OR OTHER PREDICTIONS, ANY DATA, ANY FINANCIAL INFORMATION OR ANY MEMORANDA OR OFFERING MATERIALS OR PRESENTATIONS, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORMANY OFFERING MEMORANDUM OR SIMILAR MATERIALS MADE AVAILABLE BY SPAC, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE PRODUCTS, SERVICES, GIVEXPAY SERVICES, OR GIVEX PLAFTORM NOT AND SHALL NOT BE DEEMED TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO TO INCLUDE REPRESENTATIONS OR WARRANTIES REGARDING OF SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON, AND, EXCEPT FOR THE RELIABILITYREPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE ‎IV, AVAILABILITYTHE ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, TIMELINESSARE NOT AND SHALL NOT BE DEEMED TO BE RELIED UPON BY THE COMPANY, SUITABILITYANY COMPANY NON-RECOURSE PARTY OR ANY OTHER PERSON IN EXECUTING, ACCURACY DELIVERING OR COMPLETENESS OF PERFORMING THIS AGREEMENT, THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES ANCILLARY AGREEMENTS OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT TRANSACTIONS CONTEMPLATED HEREBY OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTHEREBY.

Appears in 1 contract

Samples: Business Combination Agreement (CF Acquisition Corp. VI)

No Additional Representations or Warranties. EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONS, THE PRODUCTS AND SERVICES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE PRODUCTS, SERVICES, GIVEXPAY SERVICES, OR GIVEX PLAFTORM TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES OR THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- ERROR FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORS.DELIVERY

Appears in 1 contract

Samples: Merchant Agreement

No Additional Representations or Warranties. SPAC AGREES AND REPRESENTS THAT: EXCEPT FOR ANY EXPRESS AS PROVIDED IN ARTICLE IV (AS QUALIFIED BY THE COMPANY DISCLOSURE LETTER AND THE DOCUMENTS REFERRED TO THEREIN) AND THE REPRESENTATIONS AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONSTHE TRANSACTION AGREEMENTS, NONE OF THE PRODUCTS AND SERVICESCOMPANY, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORMMERGER SUB OR ANY OF THEIR RESPECTIVE AFFILIATES, ARE PROVIDED “AS IS” WITHOUT NOR ANY OF THEIR RESPECTIVE DIRECTORS, MANAGERS, OFFICERS, EMPLOYEES, EQUITYHOLDERS, PARTNERS, MEMBERS OR REPRESENTATIVES HAS MADE, IS MAKING, OR WILL DEEMED TO HAVE MADE ANY REPRESENTATION OR WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR WARRANTIESWHATSOEVER, EXPRESS OR IMPLIED, REGARDING THE PRODUCTSAT LAW OR IN EQUITY, SERVICESTO SPAC, GIVEXPAY SERVICESSPONSOR OR THEIR AFFILIATES OR REPRESENTATIVES, OR GIVEX PLAFTORM ANY OTHER PERSON, WITH RESPECT TO BE PROVIDED HEREUNDER THE COMPANY, ANY OF ITS SUBSIDIARIES, OR ANY OF THEIR CONDITIONBUSINESSES, ASSETS OR PROPERTIES, OR OTHERWISE, INCLUDING: (A) ANY REPRESENTATION OR WARRANTY AS TO MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE PURPOSE, FUTURE RESULTS, PROPOSED BUSINESSES OR USE FUTURE PLANS, AND (B) ANY REPRESENTATION OR WARRANTY REGARDING: (1) THE INFORMATION DISTRIBUTED OR MADE AVAILABLE TO SPAC, SPONSOR OR THEIR AFFILIATES OR REPRESENTATIVES BY MERCHANT OR ON BEHALF OF THE COMPANY AND MERGER SUB IN CONNECTION WITH THIS AGREEMENT AND THE OTHER TRANSACTION AGREEMENTS AND THE TRANSACTIONS CONTEMPLATED HEREBY AND THEREBY; (2) ANY MANAGEMENT PRESENTATION, CONFIDENTIAL INFORMATION MEMORANDUM OR SIMILAR DOCUMENT; OR (3) ANY FINANCIAL PROJECTION, FORECAST, ESTIMATE, BUDGET OR SIMILAR FORWARD-LOOKING ITEM RELATING TO THE COMPANY, MERGER SUB, ANY OF THE COMPANY’S SUBSIDIARIES AND/OR THE BUSINESS, ASSETS, LIABILITIES, PROPERTIES, FINANCIAL CONDITION, RESULTS OF OPERATIONS AND PROJECTED OPERATIONS OF THE FOREGOING, AND NONE OF THE COMPANY, MERGER SUB OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OF THEIR RESPECTIVE AFFILIATES, NOR ANY OF THEIR RESPECTIVE DIRECTORS, MANAGERS, OFFICERS, EMPLOYEES, EQUITYHOLDERS, PARTNERS, MEMBERS OR WARRANTIES REGARDING REPRESENTATIVES, SHALL BE LIABLE IN RESPECT OF THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF ANY INFORMATION PROVIDED TO SPAC, SPONSOR, THEIR AFFILIATES, THEIR REPRESENTATIVES OR ANY OTHER PERSON. SPAC HEREBY ACKNOWLEDGES THAT IT HAS NOT RELIED ON ANY REPRESENTATION OR WARRANTY THAT IS NOT EXPRESSLY SET FORTH IN ARTICLE IV (AS QUALIFIED BY THE SERVICESCOMPANY DISCLOSURE LETTER AND THE DOCUMENTS REFERRED TO THEREIN) AND THE REPRESENTATIONS AND WARRANTIES OF THE COMPANY IN THE TRANSACTION AGREEMENTS. SPAC ACKNOWLEDGES THAT IT HAS CONDUCTED, GIVEXPAY SERVICESTO ITS SATISFACTION, GIVEX PLATFORMAN INDEPENDENT INVESTIGATION AND VERIFICATION OF THE COMPANY, PROCESSING SERVICES OR THE COMPANY’S SUBSIDIARIES AND THEIR BUSINESS, ASSETS, LIABILITIES, PROPERTIES, FINANCIAL CONDITION, RESULTS OF OPERATIONS AND PROJECTED OPERATIONS OF THE FOREGOING AND, IN MAKING ITS DETERMINATION TO PROCEED WITH THE TRANSACTIONS, SPAC HAS RELIED ON THE RESULTS MERCHANT MAY OBTAIN BY USING ANY OF THESE SERVICES. WITHOUT LIMITING ITS OWN INDEPENDENT INVESTIGATION AND VERIFICATION, IN ADDITION TO THE GENERALITY REPRESENTATIONS AND WARRANTIES OF THE FOREGOING, GIVEX COMPANY EXPRESSLY AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT SPECIFICALLY SET FORTH IN ARTICLE IV (AAS QUALIFIED BY THE COMPANY DISCLOSURE LETTER AND THE DOCUMENTS REFERRED TO THEREIN) AND THE OPERATION OR USE REPRESENTATIONS AND WARRANTIES OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT COMPANY IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTRANSACTION AGREEMENTS.

Appears in 1 contract

Samples: Business Combination Agreement (TWC Tech Holdings II Corp.)

No Additional Representations or Warranties. NOTWITHSTANDING THE DELIVERY OR DISCLOSURE TO SPAC OR ANY OF ITS REPRESENTATIVES OF ANY DOCUMENTATION OR OTHER INFORMATION (INCLUDING ANY FINANCIAL PROJECTIONS OR OTHER SUPPLEMENTAL DATA), EXCEPT FOR ANY EXPRESS REPRESENTATIONS AND WARRANTIES AS OTHERWISE EXPRESSLY SET FORTH IN THIS TERMS AND CONDITIONSArticle VII (AS MODIFIED BY THE COMPANY DISCLOSURE SCHEDULES), THE PRODUCTS ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, (A) NONE OF THE SIGNING SELLERS MAKES, AND SERVICESSUCH SIGNING SELLER EXPRESSLY DISCLAIMS AND NEGATES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORM, ARE PROVIDED “AS IS” WITHOUT WARRANTY ANY REPRESENTATIONS OR WARRANTIES OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS KIND OR WARRANTIESNATURE, EXPRESS OR IMPLIED, REGARDING (I) IN CONNECTION WITH THIS AGREEMENT, THE PRODUCTSANCILLARY AGREEMENTS OR ANY OF THE TRANSACTIONS, SERVICES(II) WITH RESPECT TO SUCH SIGNING SELLER, GIVEXPAY SERVICESAND ANY MATTER RELATING TO ANY OF THEM, INCLUDING THEIR AFFAIRS, THE CONDITION, VALUE OR QUALITY OF THE ASSETS, LIABILITIES, FINANCIAL CONDITION OR RESULTS OF OPERATIONS, OR GIVEX PLAFTORM (III) WITH RESPECT TO BE PROVIDED HEREUNDER OR THEIR CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX AND ITS THIRD-PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF THE SERVICES, GIVEXPAY SERVICES, GIVEX PLATFORM, PROCESSING SERVICES ANY STATEMENT OR THE RESULTS MERCHANT MAY OBTAIN BY USING INFORMATION THAT HAVE BEEN MADE AVAILABLE TO SPAC OR ANY OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOINGITS REPRESENTATIVES, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) NO STATEMENT OR INFORMATION CONTAINED IN ANY OF SUCH MATERIALS OR MADE IN ANY SUCH PRESENTATION SHALL BE DEEMED A REPRESENTATION OR WARRANTY HEREUNDER OR OTHERWISE OR DEEMED TO BE RELIED UPON BY SPAC, ANY SPAC NON-RECOURSE PARTY OR ANY OTHER PERSON IN EXECUTING, DELIVERING AND PERFORMING THIS AGREEMENT, THE QUALITY ANCILLARY AGREEMENTS OR THE TRANSACTIONS. EXCEPT FOR THE REPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS ARTICLE VII, THE ANCILLARY AGREEMENTS OR IN THE CASE OF FRAUD, IT IS UNDERSTOOD THAT ANY COST ESTIMATES, PROJECTIONS, FORECASTS, BUDGETS OR OTHER PREDICTIONS, ANY DATA, ANY FINANCIAL INFORMATION OR ANY MEMORANDA OR OFFERING MATERIALS OR PRESENTATIONS, INCLUDING ANY OFFERING MEMORANDUM OR SIMILAR MATERIALS MADE AVAILABLE BY ANY GROUP COMPANY, ARE NOT AND SHALL NOT BE DEEMED TO BE OR TO INCLUDE REPRESENTATIONS OR WARRANTIES OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRDCOMPANY, ANY COMPANY NON-RECOURSE PARTY PROVIDERS CONTROL OR ANY OTHER PERSON, AND, EXCEPT FOR THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIESREPRESENTATIONS AND WARRANTIES EXPRESSLY SET FORTH IN THIS Article VII, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT ANCILLARY AGREEMENTS OR IN THE USE CASE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS FRAUD, ARE NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL AND SHALL NOT BE DEEMED TO BE RELIED UPON BY SPAC, ANY SECURITY BREACHES BY THIRDSPAC NON-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR RECOURSE PARTY OR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES PERSON IN EXECUTING, DELIVERING OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTSPERFORMING THIS AGREEMENT, DELAYS THE ANCILLARY AGREEMENTS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTRANSACTIONS.

Appears in 1 contract

Samples: Business Combination Agreement (Integral Acquisition Corp 1)

No Additional Representations or Warranties. THE COMPANY REPRESENTS AND ACKNOWLEDGES THAT: EXCEPT FOR ANY EXPRESS AS PROVIDED IN ARTICLE V (AS QUALIFIED BY THE SPAC DISCLOSURE LETTER AND THE DOCUMENTS REFERRED TO THEREIN), AND THE REPRESENTATIONS AND WARRANTIES SET FORTH IN THIS TERMS AND CONDITIONSTHE TRANSACTION AGREEMENTS, THE PRODUCTS AND SERVICESNEITHER SPAC NOR TRUE WIND CAPITAL NOR THEIR RESPECTIVE AFFILIATES, INCLUDING THE GIVEXPAY SERVICES AND GIVEX PLATFORMNOR ANY OF THEIR RESPECTIVE DIRECTORS, ARE PROVIDED “AS IS” WITHOUT MANAGERS, OFFICERS, EMPLOYEES, EQUITYHOLDERS, PARTNERS, MEMBERS OR REPRESENTATIVES HAS MADE, IS MAKING, OR WILL DEEMED TO HAVE MADE ANY REPRESENTATION OR WARRANTY OF ANY KIND. GIVEX MAKES NO REPRESENTATIONS OR WARRANTIESWHATSOEVER, EXPRESS OR IMPLIED, REGARDING AT LAW OR IN EQUITY, TO THE PRODUCTSCOMPANY, SERVICES, GIVEXPAY SERVICES, OR GIVEX PLAFTORM TO BE PROVIDED HEREUNDER MERGER SUB OR THEIR RESPECTIVE AFFILIATES, INCLUDING WITH RESPECT TO: (1) THE INFORMATION DISTRIBUTED OR MADE AVAILABLE TO THE COMPANY, MERGER SUB AND THEIR RESPECTIVE AFFILIATES AND REPRESENTATIVES BY OR ON BEHALF OF SPAC IN CONNECTION WITH THIS AGREEMENT AND THE TRANSACTIONS CONTEMPLATED HEREBY; (2) ANY MANAGEMENT PRESENTATION, CONFIDENTIAL INFORMATION MEMORANDUM OR SIMILAR DOCUMENT; OR (3) ANY FINANCIAL PROJECTION, FORECAST, ESTIMATE, BUDGET OR SIMILAR FORWARD-LOOKING ITEM RELATING TO SPAC AND/OR THE BUSINESS, ASSETS, LIABILITIES, PROPERTIES, FINANCIAL CONDITION, MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE OR USE BY MERCHANT OR ANY THIRD-PARTY. GIVEX RESULTS OF OPERATIONS AND ITS THIRD-PROJECTED OPERATIONS OF THE FOREGOING AND NO SUCH PARTY PROVIDERS MAKE NO REPRESENTATIONS OR WARRANTIES REGARDING SHALL BE LIABLE IN RESPECT OF THE RELIABILITY, AVAILABILITY, TIMELINESS, SUITABILITY, ACCURACY OR COMPLETENESS OF ANY INFORMATION PROVIDED TO THE SERVICESCOMPANY, GIVEXPAY SERVICESMERGER SUB OR THEIR RESPECTIVE AFFILIATES OR REPRESENTATIVES EXCEPT TO THE EXTENT INCLUDED IN THIS AGREEMENT (AS QUALIFIED BY THE SPAC DISCLOSURE LETTER AND THE DOCUMENTS REFERRED TO THEREIN), GIVEX PLATFORMAND THE REPRESENTATIONS AND WARRANTIES IN THE TRANSACTION AGREEMENTS. THE COMPANY HEREBY ACKNOWLEDGES THAT IT HAS NOT RELIED ON ANY REPRESENTATION OR WARRANTY THAT IS NOT EXPRESSLY SET FORTH IN ARTICLE V (AS QUALIFIED BY THE SPAC DISCLOSURE LETTER AND THE DOCUMENTS REFERRED TO THEREIN), PROCESSING SERVICES OR AND THE REPRESENTATIONS AND WARRANTIES IN THE TRANSACTION AGREEMENTS. THE COMPANY ACKNOWLEDGES THAT IT HAS CONDUCTED, TO ITS SATISFACTION, AN INDEPENDENT INVESTIGATION AND VERIFICATION OF SPAC AND THE BUSINESS, ASSETS, LIABILITIES, PROPERTIES, FINANCIAL CONDITION, RESULTS OF OPERATIONS AND PROJECTED OPERATIONS OF THE FOREGOING AND, IN MAKING ITS DETERMINATION TO PROCEED WITH THE TRANSACTIONS, THE COMPANY HAS RELIED ON THE RESULTS MERCHANT MAY OBTAIN OF ITS OWN INDEPENDENT INVESTIGATION AND VERIFICATION, IN ADDITION TO THE REPRESENTATIONS AND WARRANTIES OF SPAC EXPRESSLY AND SPECIFICALLY SET FORTH IN ARTICLE V (AS QUALIFIED BY USING ANY THE SPAC DISCLOSURE LETTER AND THE DOCUMENTS REFERRED TO THEREIN) AND THE REPRESENTATIONS AND WARRANTIES OF THESE SERVICES. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, GIVEX AND ITS THIRD-PARTY PROVIDERS DO NOT REPRESENT OR WARRANT THAT (A) THE OPERATION OR USE OF THE SERVICES WILL BE TIMELY, UNINTERRUPTED OR ERROR- FREE; OR (B) THE QUALITY OF THE SERVICES WILL MEET MERCHANT'S REQUIREMENTS. MERCHANT ACKNOWLEDGES THAT NEITHER GIVEX NOR ITS THIRD-PARTY PROVIDERS CONTROL THE TRANSFER OF DATA OVER COMMUNICATIONS FACILITIES, INCLUDING THE INTERNET, AND THAT THE SERVICES MAY BE SUBJECT TO LIMITATIONS, DELAYS, AND OTHER PROBLEMS INHERENT SPAC IN THE USE OF SUCH COMMUNICATIONS FACILITIES. GIVEX IS NOT RESPONSIBLE FOR ANY DELAYS, DELIVERY FAILURES, OR OTHER DAMAGE RESULTING FROM SUCH PROBLEMS. WITHOUT LIMITING THE FOREGOING, GIVEX DOES NOT WARRANT OR GUARANTEE THAT ALL SECURITY ATTACKS WILL BE DISCOVERED, REPORTED OR REMEDIED, OR THAT THERE WILL NOT BE ANY SECURITY BREACHES BY THIRD-PARTIES. NEITHER GIVEX NOR PROCESSOR (NOR ANY OTHER PARTY PROVIDING ANY PORTION OF GIVEXPAY SERVICES OR PROCESSING SERVICES) SHALL BE RESPONSIBLE FOR ANY FAULTS, DELAYS OR INTERRUPTIONS IN THE GIVEXPAY SERVICES OR PROCESSING SERVICES THAT ARE A RESULT OF RESTRICTIONS IMPOSED BY ANY GOVERNMENT OR TELECOMMUNICATIONS SERVICE OPERATORS, OR AS RESULT OF ANY MISUSE OF THESE SERVICES BY MERCHANT OR ITS AFFILIATES, EMPLOYEES, REPRESENTATIVES, AGENTS OR CONTRACTORSTRANSACTION AGREEMENTS.

Appears in 1 contract

Samples: Business Combination Agreement (TWC Tech Holdings II Corp.)

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!