Third Party Infringement Claims In the event any claim or action for infringement of any patent, trademark, or other intellectual property right shall be made or brought by a third party against Seller, Purchaser or any of their respective Affiliates because of, or in anticipation of, the manufacture and supply of Product by Seller to Purchaser hereunder, or the marketing, sale or distribution of such Product to Purchaser Customers in the Territory by Purchaser hereunder (a “Third Party Infringement Claim”), the party first receiving such notice of the Third Party Infringement Claim shall promptly notify the other party. With respect to the Third Party Infringement Claim, Seller and Purchaser each hereby agrees that all Damages arising from or related to the Third Party Infringement Claim (including any legal fees and associated costs incurred in defending the Third Party Infringement Claim and any fees, royalties or other amounts paid in settlement or upon judgment) shall be shared as follows:
(a) Except as provided in clause (b) below, Seller shall be 100% responsible for all Damages arising from any Third Party Infringement Claim, including any fees, royalties or other amounts agreed to be paid in settlement or upon judgment of the Lawsuit or otherwise; and
(b) Purchaser shall be 100% responsible for all Damages arising from any Third Party Infringement Claim with respect to the use of Purchaser Trademarks. Each party agrees to indemnify the other party to ensure that Damages arising from any Third Party Infringement Claim are allocated in accordance with clauses (a) and (b) above. Unless otherwise agreed to by the parties, Seller shall control the defense any Third Party Infringement Claim described in clause (a) above and Purchaser shall control the defense of any Third Party Infringement Claim described in clause (b) above. The party controlling the defense of any Third Party Infringement Claim shall have the sole right to defend or settle any such Third Party Infringement Claim; provided, however, that such settlement does not impose any obligation or burden on the other party without the prior written consent of the other party (which consent shall not be unreasonably withheld). The party controlling the defense of any Third Party Infringement Claim shall keep the other party, at its request, materially informed of the status and progress of the defense of the Third Party Infringement Claim. No Third Party Infringement Claim shall be settled by the party who is not controlling the defense of such Third Party Infringement Claim without the prior written consent of the party controlling such defense. The non-controlling party, its employees, agents and Affiliates shall reasonably cooperate with the party (and its legal representatives) controlling the defense of any Third Party Infringement Claim in the investigation and defense of such Third Party Infringement Claim. Notwithstanding the above, and by way of clarification, neither party shall be obligated to indemnify the other party hereunder for modification or misuse of the Product by the other party or by wholesalers or the customers of either party. The provisions of this Section 17.4 shall be notwithstanding any conflicting provisions set forth in this Agreement, including Sections 17.1, 17.2 and 17.3.
Third Party Infringement (a) In the event that either ALGORX or BRIDGE becomes aware of any product made, used, imported, offered for sale or sold in the Territory in the Field which it believes to infringe a BRIDGE Patent Right or constitute a misappropriation of BRIDGE Know-How in the Field, such Party (the "Notifying Party") shall promptly advise the other Party of all the relevant facts and circumstances known by the Notifying Party in connection with the infringement or misappropriation.
(b) The Parties agree that ALGORX shall have the first right, at its own expense, but not the obligation, to enforce any BRIDGE Patent Rights or BRIDGE Know-How against such infringement or misappropriation. BRIDGE shall fully cooperate with ALGORX with respect to the investigation and prosecution of such alleged infringement or misappropriation including consenting to the joining of BRIDGE, at ALGORX expense, as a party to such action, as ALGORX deems necessary or appropriate.
(c) BRIDGE shall have the right (at its own expense), but not the obligation, to enforce, and ALGORX does hereby grant to BRIDGE the right to enforce, any BRIDGE Patent Rights or BRIDGE Know-How against such infringement or misappropriation, and ALGORX shall fully cooperate with BRIDGE with respect to the investigation and prosecution of such alleged infringement or misappropriation including consenting to the joining of BRIDGE, at BRIDGE expense, as a Party to such action, if necessary. BRIDGE may, in its sole discretion, exercise this right if:
(i) ALGORX shall fail, within six (6) months after notifying BRIDGE or receiving notice from BRIDGE of the infringement, to institute an action or take other substantial measures to axxxx such alleged infringement, or
(ii) ALGORX earlier notifies BRIDGE in writing that ALGORX does not plan to terminate such infringement or institute such action.
(d) The Party prosecuting such infringement action shall have the right to control such litigation and shall bear all legal expenses (including court costs and legal fees and expenses), including settlement thereof; provided, however that no settlement or consent judgment or other voluntary final disposition of any infringement action brought by a Party pursuant to this Article 9.2 may be entered into without the prior written consent of the other Party if such settlement would require the other Party to be subject to an injunction or to make a monetary payment or would restrict the claims in or admit any invalidity of any of the BRIDGE Patent Rights.
(e) Any damages or costs recovered by a Party in connection with any action filed by it as permitted hereunder shall be allocated as follows: (i) first, to reimburse the prosecuting Party for its own costs and expenses incurred in prosecuting such action (including reasonable attorneys' fees), (ii) second, to reimburse the other Party for its out-of-pocket costs and expenses reasonably incurred (including reasonable attorneys' fees) by it in assisting such Party in that action, and then (iii) sharing the remainder as follows:
(1) if ALGORX is prosecuting the action, BRIDGE shall be entitled to a royalty on the defendant's infringing sales under BRIDGE's patent rights, as specified in column A of the table in Article 5.1 (or, if the claim is for misappropriation of BRIDGE Know-How, the royalty specified in column B of that table), and ALGORX shall retain the balance; and (2) if BRIDGE is prosecuting the action, ALGORX shall be entitled to that portion allocable to its lost profits or defendant's profits, whichever is less, from the defendant's infringing sales and Bridge shall retain the balance. In the event that the Parties agree to prosecute such infringement jointly, the Parties will split all damages or costs recovered equally, after first reimbursing each Party pari passu for any out-of-pocket expenses hereunder.
Infringement Claims by Third Parties If the Exploitation of a Licensed Product in the Territory pursuant to this Agreement results in, or is reasonably expected to result in, any claim, suit or proceeding by a Third Party alleging infringement by Licensee or any of its Affiliates or its or their Sublicensees, (a “Third Party Infringement Claim”), including any defense or counterclaim in connection with an Infringement action initiated pursuant to Section 6.3.2, the Party first becoming aware of such alleged infringement shall promptly notify the other Party thereof in writing. As between the Parties, Licensee shall be responsible for defending any such claim, suit or proceeding, at its sole cost and expense using counsel of Licensee’s choice, in relation to technology licensed under any Exclusive Licensed Technology, and MedImmune shall be responsible for defending any such claim, suit or proceeding at proceeding at its sole cost and expense, using counsel of MedImmune’s choice in relation to technology licensed under any Non-Exclusive Licensed Technology. MedImmune shall, and shall cause its Affiliates to, assist and cooperate with Licensee, as Licensee may reasonably request from time to time, in connection with its activities set out in this Section 6.4, including where necessary, furnishing a power of attorney solely for such purpose or joining in, or being named as a necessary party to, such action, providing access to relevant documents and other evidence and making its employees available at reasonable business hours; provided that Licensee shall reimburse MedImmune for its reasonable and verifiable out-of-pocket costs and expenses incurred in connection therewith. Licensee shall keep MedImmune reasonably informed of all material developments in connection with any such claim, suit or proceeding. Licensee agrees to provide MedImmune with copies of all material pleadings filed in such action and to allow MedImmune reasonable opportunity to participate in the defense of the claims. Any damages, or awards, including royalties incurred or awarded in connection with any Third Party Infringement Claim defended under this Section 6.4 shall be [***].
Infringement Claims You may submit an infringement claim notice to us at our Contact Formavailable here if you have a good faith belief that Your Content has been copied and made accessible through the Services (including as a part of the Service Content or Third Party Content) in violation of your Inte lectual Property Rights. A copyright infringement claims notice must include at (i) the identification of such a legedly infringing materials, including information su ficient for us to locate it within our Services, ( i) a demand that such a legedly infringing materials be removed or access disabled, ( i) a statement that you have a good faith belief that use of the material in the manner complained of is not authorized by the copyright owner, its agent, or the law; (iv) a statement that the information in the notification is accurate, and under penalty of perjury, that you are authorized to act on behalf of the owner of an exclusive right that is a legedly infringed; (v) contact information for you, such as address, phone number, and, if available, an email address; and (vi) must be signed by you or the person authorized to act on behalf of the owner of the a legedly infringed work (the “Notice Requirements”). Pursuant to 17 U.S.C. 512(c)(3), if the above Notice Requirements are not met, we may disregard the notice. Pursuant 17 U.S.C. 512(f), be advised that knowingly making a material misrepresentation that online material or activity is infringing or that material or activity was removed or disabled by mistake or misidentification, may subject you to heavy civil penalties. These penalties include monetary damages, including costs and attorneys' fees, incurred by the a leged infringer, by any copyright owner or copyright owner's authorized licensee, or by a service provider who is injured by your misrepresentation. If we make a decision to remove Your Content in response to a complaint, we may notify you and provide you with contact information for the complaining party. You may also object to such determination by writing to our designated agent, which must contain the fo lowing information pursuant to 17 U.S.C. 512(g)(3), (i) your physical or electronic signature; ( i) identification of the material that has been removed or to which access has been disabled and the location at which the material appeared before it was removed or access to it was disabled; ( i) a statement under penalty of perjury that the you have a good faith belief that the material was removed or disabled as a result of mistake or misidentification of the material to be removed or disabled; and (iv) your name, address, phone number, and a statement that you consent to the jurisdiction of Federal District Court for the judicial district in which the address is located, or if you are located outside of the United States, for any judicial district in which the service provider may be found, and that you wil accept service of process from the person who provided notification under subsection 17 U.S.C. 512(c)(1)(C) or an agent of such person.
Non-Third Party Claims Upon discovery of any claim for which Buyer has an indemnification obligation under the terms of Section 12.1 which does not involve a claim by a third party against the Indemnitee, the Indemnitee shall give prompt notice to Buyer of such claim and, in any case, shall give Buyer such notice within 30 days of such discovery. A failure by Indemnitee to timely give the foregoing notice to Buyer shall not excuse Buyer from any indemnification liability except to the extent that Buyer is materially and adversely prejudiced by such failure.
Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.
1.2 Our obligations under this Section G(1) will not apply to the extent the claim or adverse final judgment is based on your use of the Tyler Software in contradiction of this Agreement, including with non-licensed third parties, or your willful infringement.
1.3 If we receive information concerning an infringement or misappropriation claim related to the Tyler Software, we may, at our expense and without obligation to do so, either: (a) procure for you the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent, in which case you will stop running the allegedly infringing Tyler Software immediately. Alternatively, we may decide to litigate the claim to judgment, in which case you may continue to use the Tyler Software consistent with the terms of this Agreement.
1.4 If an infringement or misappropriation claim is fully litigated and your use of the Tyler Software is enjoined by a court of competent jurisdiction, in addition to paying any adverse final judgment (or settlement to which we consent), we will, at our option, either: (a) procure the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent. This section provides your exclusive remedy for third party copyright, patent, or trademark infringement and trade secret misappropriation claims.
Non-Infringement To the Company’s Knowledge, there is no unauthorized use, unauthorized disclosure, infringement, misappropriation or other violation of any Company-Owned Intellectual Property by any third party, and neither the Company nor any Subsidiary has brought any Action or sent any notices to any third party regarding the foregoing. Neither the Company nor any Subsidiary has any Liability for infringement, misappropriation, or other violation of any Third-Party Intellectual Property. The operation of the Company’s business, including (i) the design, development, manufacturing, reproduction, marketing, licensing, sale, offer for sale, importation, distribution, provision or use of any Company Product or Company-Owned Intellectual Property and (ii) the Company’s use of any product, device, process or service used in the Company’s business as previously conducted, currently conducted and as proposed to be conducted by the Company, has not, does not and will not infringe (directly or indirectly, including via contribution or inducement), misappropriate or otherwise violate any Third-Party Intellectual Property, breach any terms of service, click-through agreement or any other agreement or rules, policies or guidelines applicable to use of such Third-Party Intellectual Property, and does not constitute unfair competition or unfair trade practices under the Law of any jurisdiction in which Company conducts its business or in which Company Products are manufactured, marketed, distributed, licensed or sold (and there is no basis for any such claim). Neither the Company nor any Subsidiary has been sued in any Action or received any written communications (including any third-party reports by users) alleging that the Company or any Subsidiary has infringed, misappropriated, or otherwise violated or, by conducting its business, would infringe, misappropriate, or otherwise violate any Intellectual Property of any other Person or entity. No Company Intellectual Property or Company Product is subject to any Action, Order, settlement agreement or right that restricts in any manner the use, transfer or licensing thereof by the Company, any Subsidiary, or that may affect the validity, use or enforceability of any Company Intellectual Property.
Third Party Patent Rights If either Party desires to bring an opposition, action for declaratory judgment, nullity action, interference, declaration for non-infringement, reexamination or other attack upon the validity, title or enforceability of a Patent Right owned or controlled by a Third Party and having one or more claims that Cover the Compound or Product, or the use, sale, offer for sale or importation of the Compound or Product (except insofar as such action is a counterclaim to or defense of, or accompanies a defense of, a Third Party’s claim or assertion of infringement under Section 7.6, in which case the provisions of Section 7.6 shall govern), such Party shall so notify the other Party and the Parties shall promptly confer to determine whether to bring such action or the manner in which to settle such action. Provention shall have the exclusive right, but not the obligation, to bring, at its own expense and in its sole control, such action in the Territory. If Provention does not bring such an action in the Territory, within ninety (90) days of notification thereof pursuant to this Section 7.7(a) (or earlier, if required by the nature of the proceeding), MacroGenics shall have the right, but not the obligation, to bring, at MacroGenics’ own expense, such action. The Party not bringing an action under this Section 7.7(a) shall be entitled to separate representation in such proceeding by counsel of its own choice and at its own expense, and shall cooperate fully with the Party bringing such action. Any awards or amounts received in bringing any such action shall be first allocated to reimburse the initiating Party’s expenses in such action, and any remaining amounts shall be allocated between the Parties as provided in Section 7.5(e).
Third Party Claims The obligation of an indemnifying party to ------------------ indemnify another party to this Agreement under the provisions of this Article with respect to claims resulting from the assertion of liability by Persons not parties to this Agreement (including governmental claims for penalties, fines and assessments) shall be subject to the following terms and conditions:
(a) The indemnified party shall give prompt written notice to the indemnifying party of any assertion of liability by a third party which might give rise to a claim for indemnification, which notice shall state the nature and basis of the assertion and the amount thereof, to the extent known, provided, however, that no delay on the part of the indemnified party in giving notice shall relieve the indemnifying party of any obligation to indemnify unless (and then solely to the extent that) the indemnifying party is prejudiced by such delay.
(b) If any action, suit or proceeding (a "Legal Action") is brought against an indemnified party with respect to which the indemnifying party may have an obligation to indemnify, the Legal Action shall be defended by the indemnifying party and such defense shall include all proceedings and appeals which counsel for the indemnified party shall reasonably deem appropriate.
(c) Notwithstanding the provisions of the previous subsection of this Article, until the indemnifying party shall have assumed the defense of any such Legal Action, the defense shall be handled by the indemnified party. Furthermore, (i) if the indemnified party shall have reasonably concluded that there are likely to be defenses available to the indemnified party that are different from or in addition to those available to the indemnifying party; (ii) if the indemnifying party fails to provide the indemnified party with evidence reasonably acceptable to the indemnified party that the indemnifying party has sufficient financial resources to defend and fulfill its indemnification obligation with respect to the Legal Action; (iii if the Legal Action involves other than money damages and seeks injunctive or other equitable relief; or (iv) if a judgment against the indemnified party will, in the good faith opinion of the indemnified party, establish a custom or precedent which will be materially adverse to the best interests of its continuing business, the indemnifying party shall not be entitled to assume the defense of the Legal Action and the defense shall be handled by the indemnified party. If the defense of the Legal Action is handled by the indemnified party under the provisions of this subsection, the indemnifying party shall pay all legal and other expenses reasonably incurred by the indemnified party in conducting such defense.
(d) In any Legal Action initiated by a third party and defended by the indemnifying party (i) the indemnified party shall have the right to be represented by advisory counsel and accountants, at its own expense, (ii) the indemnifying party shall keep the indemnified party fully informed as to the status of such Legal Action at all stages thereof, whether or not the indemnified party is represented by its own counsel, (iii) the indemnifying party shall make available to the indemnified party, and its attorneys, accountants and other representatives, all books and records of the indemnifying party relating to such Legal Action and (iv) the parties shall render to each other such assistance as may be reasonably required in order to ensure the proper and adequate defense of the Legal Action.
(e) In any Legal Action initiated by a third party and defended by the indemnifying party, the indemnifying party shall not make any settlement of any claim without the written consent of the indemnified party, which consent shall not be unreasonably withheld. Without limiting the generality of the foregoing, it shall not be deemed unreasonable to withhold consent to a settlement involving injunctive or other equitable relief against the indemnified party or its assets, employees or business, or relief which the indemnified party reasonably believes could establish a custom or precedent which will be adverse to the best interests of its continuing business.
INDEMNIFICATION RELATING TO THIRD PARTY RIGHTS The Contractor will also indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs that may be finally assessed against the Authorized Users in any action for infringement of a United States Letter Patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims arise from the Authorized Users gross negligence or willful misconduct, provided that the State shall give Contractor: (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. If usage shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue Usage (ii) to modify the service or Product so that Usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace said service or Product or part(s) thereof, as applicable, with non-infringing service or Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided the Authorized User is given a refund for any amounts paid for the period during which Usage was not feasible. The foregoing provisions as to protection from third party rights shall not apply to any infringement occasioned by modification by the Authorized User of any Product without Contractor’s approval. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the service or Product under the Contract infringes any patent, copyright or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract. Contractor shall in such event protect the interests of the Authorized User and secure a continuance to permit the Authorized User to appear and defend its interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
