Rights in Collateral; Priority of Liens Borrower and each other Loan Party own the property granted by it as Collateral under the Collateral Documents, free and clear of any and all Liens in favor of third parties. Upon the proper filing of UCC financing statements, and the taking of the other actions required by Lender, the Liens granted pursuant to the Collateral Documents will constitute valid and enforceable first, prior and perfected (to the extent that Liens on the Collateral can be perfected by the filing of UCC financing statements) Liens on the Collateral in favor of Lender.
Relative Priorities (a) Notwithstanding the date, time, method, manner or order of grant, attachment or perfection of any Lien on any Shared Collateral securing any Pari Passu Lien Obligation, and notwithstanding any provision of the Uniform Commercial Code of any jurisdiction, any other applicable law or any Secured Credit Document, or any other circumstance whatsoever (but, in each case, subject to Section 2.01(b) and Section 2.02), each Collateral Agent, for itself and on behalf of its Related Secured Parties, agrees that Liens on any Shared Collateral securing Pari Passu Lien Obligations of any Class shall be of equal priority. (b) Each Collateral Agent, for itself and on behalf of its Related Secured Parties, agrees that, notwithstanding (x) any provision of any Secured Credit Document to the contrary (but subject to Section 2.02) and (y) the date, time, method, manner or order of grant, attachment or perfection of any Lien on any Shared Collateral securing any Pari Passu Lien Obligation, and notwithstanding any provision of the Uniform Commercial Code of any jurisdiction, any other applicable law or any Secured Credit Document, or any other circumstance whatsoever (but, in each case, subject to Section 2.02), if an Event of Default has occurred and is continuing and (i) such Collateral Agent or any of its Related Secured Parties takes any action to enforce rights or exercise remedies in respect of any Shared Collateral (including any such action referred to in Section 3.01(a)), (ii) any distribution is made in respect of any Shared Collateral in any Insolvency or Liquidation Proceeding of the Borrower or any other Grantor or (iii) such Collateral Agent or any of its Related Secured Parties receives any payment with respect to any Shared Collateral pursuant to any intercreditor agreement (other than this Agreement), then the proceeds of any sale, collection or other liquidation of any Shared Collateral obtained by such Collateral Agent or any of its Related Secured Parties on account of such enforcement of rights or exercise of remedies, and any such distributions or payments received by such Collateral Agent or any of its Related Secured Parties (all such proceeds, distributions and payments being collectively referred to as “Proceeds”), shall be applied as follows: (i) FIRST, to the payment of all amounts owing to and all costs and expenses incurred by any Collateral Agent, the Credit Agreement Administrative Agent and the Initial Additional Pari Passu Lien Collateral Agent (in their capacities as such), pursuant to the terms of any Secured Credit Document or in connection with any enforcement of rights or exercise of remedies pursuant thereto, including all court costs and the reasonable fees and expenses of agents and legal counsel and, in each case, including all costs and expenses incurred in enforcing its rights to obtain such payment; (ii) SECOND, subject to Section 2.02 to the payment in full of all Pari Passu Lien Obligations of each Class secured by a Lien on such Shared Collateral at the time due and payable (the amounts so applied to be distributed, as among such Classes of Pari Passu Lien Obligations, ratably in accordance with the amounts of the Pari Passu Lien Obligations of each such Class on the date of such application); and
No Construction Loans No Mortgage Loan was made in connection with (i) the construction or rehabilitation of a Mortgage Property or (ii) facilitating the trade-in or exchange of a Mortgaged Property other than a construction-to-permanent loan which has converted to a permanent Mortgage Loan;
Lien Priority Any Lien created hereunder or by any other Loan Document shall at any time fail to constitute a valid and perfected Lien on any of the Collateral purported to be secured thereby, subject to no prior or equal Lien, other than Permitted Liens which are permitted to have priority in accordance with the terms of this Agreement.
Lien Priorities Notwithstanding (a) the date, manner or order of filing, recordation, or perfection of the security interests or liens granted in favor of Moriah and the Notes Collateral Agent, (b) any provisions of the UCC, or any applicable law or decision, (c) the provisions of the Moriah Loan Agreements, Noteholder Agreements or any contract between any of the Creditors on one hand, and the Borrower or any affiliate thereof, on the other hand, or (d) whether either Moriah or the Notes Collateral Agent holds possession of all or any part of the Collateral, the following, as between Moriah and the Notes Collateral Agent, shall be the relative priority of the security interests and liens of Moriah and the Notes Collateral Agent in the Collateral: (a) Moriah shall have a first and prior security interest to the extent set forth herein in all Accounts and Inventory as defined in the Section 9-102 of the UCC. The Notes Collateral Agent shall have a second and subordinate security interest in the foregoing property and interests in such property; provided, that, any amount of the Moriah Claim in excess of the Maximum Moriah Debt at any time outstanding (together with the interest on such excess) shall not be entitled to the benefit of the priority of the security interest of Moriah provided for in this Section 2.1(a). (b) The Notes Collateral Agent shall have a first and prior security interest in the remainder of the Collateral that is the subject of the Noteholder Agreements and Moriah shall have a second and subordinate security interest in such Notes Collateral whether now owned or hereafter created by any Loan Party. Neither Moriah nor the Notes Collateral Agent shall contest the validity, perfection, priority or enforceability of any lien or security interest heretofore granted to the other Party or granted in connection herewith or contemplated hereby. Notwithstanding any failure of a Party to perfect its security interests in any Collateral or any other defect in any security interests or obligations owing to such Party, the priority and rights as between the parties hereto shall be as set forth herein.
Maintenance of Security Interests in Financed Equipment The Servicer shall, in accordance with its customary servicing procedures, take such steps as are necessary to maintain perfection of the security interest created by each Receivable in the related Financed Equipment. The Servicer is hereby authorized to take such steps as are necessary to re-perfect such security interest on behalf of the Issuing Entity and the Indenture Trustee in the event of the relocation of the Financed Equipment or for any other reason.
Preservation of Collateral Following the occurrence of a Default or Event of Default, in addition to the rights and remedies set forth in Section 11.1 hereof, Agent: (a) may at any time take such steps as Agent deems necessary to protect Agent’s interest in and to preserve the Collateral, including the hiring of such security guards or the placing of other security protection measures as Agent may deem appropriate; (b) may employ and maintain at any of any Borrower’s premises a custodian who shall have full authority to do all acts necessary to protect Agent’s interests in the Collateral; (c) may lease warehouse facilities to which Agent may move all or part of the Collateral; (d) may use any Borrower’s owned or leased lifts, hoists, trucks and other facilities or equipment for handling or removing the Collateral; and (e) shall have, and is hereby granted, a right of ingress and egress to the places where the Collateral is located, and may proceed over and through any of Borrowers’ owned or leased property. Each Borrower shall cooperate fully with all of Agent’s efforts to preserve the Collateral and will take such actions to preserve the Collateral as Agent may direct. All of Agent’s expenses of preserving the Collateral, including any expenses relating to the bonding of a custodian, shall be charged to Borrowers’ Account as a Revolving Advance maintained as a Domestic Rate Loan and added to the Obligations.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.
No Waiver of Lien Priorities (a) No right of the First Lien Claimholders, the First Lien Collateral Agent or any of them to enforce any provision of this Agreement or any First Lien Loan Document shall at any time in any way be prejudiced or impaired by any act or failure to act on the part of the Company or any other Grantor or by any act or failure to act by any First Lien Claimholder or the First Lien Collateral Agent, or by any noncompliance by any Person with the terms, provisions and covenants of this Agreement, any of the First Lien Loan Documents or any of the Second Lien Documents, regardless of any knowledge thereof which the First Lien Collateral Agent or any First Lien Claimholder, or any of them, may have or be otherwise charged with. (b) Without in any way limiting the generality of the foregoing paragraph (but subject to the rights of the Company and the other Grantors under the First Lien Loan Documents and subject to the provisions of Section 5.3(a)), the First Lien Claimholders, the First Lien Collateral Agent and any of them may, at any time and from time to time in accordance with the First Lien Loan Documents and/or applicable law, without the consent of, or notice to, the Second Lien Collateral Agents or any other Second Lien Claimholder, without incurring any liabilities to the Second Lien Collateral Agents or any other Second Lien Claimholder and without impairing or releasing the Lien priorities and other benefits provided in this Agreement (even if any right of subrogation or other right or remedy of the Second Lien Collateral Agents or any other Second Lien Claimholder is affected, impaired or extinguished thereby) do any one or more of the following: (1) change the manner, place or terms of payment or change or extend the time of payment of, or amend, renew, exchange, increase or alter, the terms of any of the First Lien Obligations or any Lien on any First Lien Collateral or guaranty of any of the First Lien Obligations or any liability of the Company or any other Grantor, or any liability incurred directly or indirectly in respect thereof (including any increase in or extension of the First Lien Obligations, without any restriction as to the tenor or terms of any such increase or extension) or otherwise amend, renew, exchange, extend, modify or supplement in any manner any Liens held by the First Lien Collateral Agent or any of the other First Lien Claimholders, the First Lien Obligations or any of the First Lien Loan Documents; (2) sell, exchange, release, surrender, realize upon, enforce or otherwise deal with in any manner and in any order any part of the First Lien Collateral or any liability of the Company or any other Grantor to any of the First Lien Claimholders or the First Lien Collateral Agent, or any liability incurred directly or indirectly in respect thereof; (3) settle or compromise any First Lien Obligation or any other liability of the Company or any other Grantor or any security therefor or any liability incurred directly or indirectly in respect thereof and apply any sums by whomsoever paid and however realized to any liability (including the First Lien Obligations) in any manner or order; and (4) exercise or delay in or refrain from exercising any right or remedy against the Company or any other Grantor or any other Person or any security, and elect any remedy and otherwise deal freely with the Company, any other Grantor or any First Lien Collateral and any security and any guarantor or any liability of the Company or any other Grantor to the First Lien Claimholders or any liability incurred directly or indirectly in respect thereof. (c) Except as otherwise expressly provided herein, the Second Lien Collateral Agents, each on behalf of itself and each other applicable Second Lien Claimholder, also agrees that the First Lien Claimholders and the First Lien Collateral Agent shall not have any liability to the Second Lien Collateral Agents or any such Second Lien Claimholders, and the Second Lien Collateral Agents, each on behalf of itself and each other applicable Second Lien Claimholder, hereby waives any claim against any First Lien Claimholder or the First Lien Collateral Agent arising out of any and all actions which the First Lien Claimholders or the First Lien Collateral Agent may take or permit or omit to take with respect to: (1) the First Lien Loan Documents (other than this Agreement); (2) the collection of the First Lien Obligations; or (3) the foreclosure upon, or sale, liquidation or other disposition of, any First Lien Collateral. The Second Lien Collateral Agents, each on behalf of itself and each other applicable Second Lien Claimholder, agree that the First Lien Claimholders and the First Lien Collateral Agent do not have any duty to them in respect of the maintenance or preservation of the First Lien Collateral, the First Lien Obligations or otherwise. (d) Until the Discharge of First Lien Obligations, the Second Lien Collateral Agents, each on behalf of itself and each other applicable Second Lien Claimholder, agree not to assert and hereby waives, to the fullest extent permitted by law, any right to demand, request, plead or otherwise assert or otherwise claim the benefit of any marshaling, appraisal, valuation or other similar right that may otherwise be available under applicable law with respect to the Collateral or any other similar rights a junior secured creditor may have under applicable law.
