TOTAL OR PARTIAL FAILURE TO PERFORM 20.1 In the case of Goods to be specially manufactured for it, if Transnet at any time ascertains that:
a) no manufacturing of the Goods specified in a Purchase Order has commenced and there is little or no prospect, in Transnet’s opinion, that manufacturing will commence within a reasonable time; or
b) delivery of any of the Goods is being or is likely to be delayed beyond the promised delivery date(s), and there is little or no prospect of the Purchase Order(s) being carried out within reasonable adherence to the promised delivery rate(s) or time(s), then Transnet may, irrespective of the cause of the delay, by notice to the Supplier, cancel as from a future date specified in such notice the whole or any part of this Agreement or Purchase Order in respect of which the Goods to be supplied have not been completed by that date, without incurring any liability by reason of such cancellation except as provided in this clause.
20.2 The Supplier/Service Provider shall thereupon, as soon as possible after such date, deliver to Transnet the Goods/Services [if any] already completed, and payment for the part performance shall be made on a pro rata basis, provided the uncompleted part is not an integral or essential part of the completed Goods/Services. Where an integral or essential part of the work has not been completed, the amount to be paid to the Supplier/Service Provider will be calculated on the basis of Transnet’s enrichment. The Supplier/Service Provider shall, wherever practicable, supply Transnet with the necessary drawings and/or specifications to enable it to complete the work.
20.3 Whenever, in any case not covered by clause 20.1 above, the Supplier fails or neglects to execute the work or to deliver any portion of the Goods/Services as required by the terms of this Agreement or Purchase Order, or if any Goods/Services are rejected on any of the grounds mentioned in clause Error! Reference source not found. [Defective Goods], Transnet may cancel this Agreement or Purchase Order in so far as it relates to the unexecuted work or the undelivered or rejected portion of the Goods/Services, and in such event, the supply of the remaining portion shall remain subject in all respects to these conditions.
Material Breach A material breach for purposes of this Agreement shall include, but not be limited to:
(a) Failure to timely furnish the documents described in Section 6 or the information requested by GO-Biz or the FTB relating to Taxpayer’s compliance with this Agreement.
(b) Material misstatements in any information provided to GO-Biz as part of the application process and/or after this Agreement is signed.
(c) Failure to materially satisfy applicable Milestones as set forth in Exhibit A, materiality of which shall be determined by GO-Biz, by the end of the last taxable year identified in Exhibit A.
(d) Failure to maintain one or more Milestones for a minimum of three (3) subsequent taxable years after achieving the Milestone(s).
Breach A breach of the contract clauses above may be grounds for termination of the contract, and for debarment as a contractor and subcontractor as provided in 29 C.F.R. § 5.12.
BREACH; TERMINATION Customer/Project Sponsor may terminate this Agreement at any time in its sole discretion by providing notice to the Company not less than one hundred and eighty (180) days before such termination. In the event of breach of any material terms or conditions of this Agreement, if the breach has not been remedied within 30 days following receipt of written notice thereof from the other Party (provided that, if the breaching Party has commenced and is diligently pursuing efforts to cure such breach, then such 30-day period shall be extended until the earlier of (i) 30 additional days or (ii) end of diligent efforts to cure the breach), then the non-breaching party may terminate this Agreement by written notice at any time until cure of such breach occurs. In the event of any proceedings by or against either Party in bankruptcy, insolvency or for appointment of any receiver or trustee or any general assignment for the benefit of creditors (excluding, for the avoidance of doubt, an assignment in accordance with Article XI or other collateral assignment to obtain project financing), the other Party may terminate this Agreement. If the Customer/Project Sponsor increases the capability or the capacity of the Facility to exceed 4.999 MW, this Agreement shall immediately terminate. The Company shall not be liable to the Customer/Project Sponsor for damages resulting from a termination pursuant to this paragraph. If the Customer/Project Sponsor's generating equipment produces zero (0) kilowatt- hours during any period of twelve (12) consecutive Billing Periods after the Commercial Operation Date [Effective Date for existing resources] for a reason other than a force majeure event, the Company may terminate this Agreement.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.