Transportation of Accident Victims Transportation to the nearest physician or hospital for employees requiring medical care as a result of an on-the-job accident shall be at the expense of the Employer.
ACCIDENT PREVENTION T h i s p r o v i s i o n i s applicable to all Federal-aid construction contracts and to all related subcontracts.
1. In the performance of this contract the contractor shall comply with all applicable Federal, State, and local laws governing safety, health, and sanitation (23 CFR 635). The contractor shall provide all safeguards, safety devices and protective equipment and take any other needed actions as it determines, or as the contracting officer may determine, to be reasonably necessary to protect the life and health of employees on the job and the safety of the public and to protect property in connection with the performance of the work covered by the contract.
2. It is a condition of this contract, and shall be made a condition of each subcontract, which the contractor enters into pursuant to this contract, that the contractor and any subcontractor shall not permit any employee, in performance of the contract, to work in surroundings or under conditions which are unsanitary, hazardous or dangerous to his/her health or safety, as determined under construction safety and health standards (29 CFR 1926) promulgated by the Secretary of Labor, in accordance with Section 107 of the Contract Work Hours and Safety Standards Act (40 U.S.C. 3704).
3. Pursuant to 29 CFR 1926.3, it is a condition of this contract that the Secretary of Labor or authorized representative thereof, shall have right of entry to any site of contract performance to inspect or investigate the matter of compliance with the construction safety and health standards and to carry out the duties of the Secretary under Section 107 of the Contract Work Hours and Safety Standards Act (40 U.S.C.3704).
Accident INVESTIGATIONS Whenever an accident occurs involving the equipment or personnel of a Supporting Party, the Protecting Party shall take immediate steps to notify the Supporting Party that an accident has occurred. As soon as practical, the Protecting Party shall initiate an investigation of the accident. A team made up of appropriate representatives from all affected agencies shall conduct the investigation. Costs for investigation personnel are Party-specific and will be borne by the sending Party. Other accident or incident investigation costs are the fiscal responsibility of the Party (ies) that has jurisdiction and/or investigative responsibility. The sharing of information between Parties on accident investigations and their findings and probable causes is a valuable tool for safety and must be encouraged.
Post-Accident Testing All Employees Post-accident drug and alcohol testing may be conducted by the Employer for any employee when a work-related incident has occurred involving death, serious bodily injury or significant property/environmental damage, or the potential for death, serious bodily injury, or significant property/environmental damage, and when the employee’s action(s) or inaction(s) either contributed to the incident or cannot be completely discounted as a contributing factor. Referral for post-accident testing will be made in accordance with Subsection 22.5 C, above.
Accidents If a death, serious personal injury or substantial property damage occurs in connection with CONTRACTOR’s performance of this Agreement, CONTRACTOR shall immediately notify Mendocino County Risk Manager's Office by telephone. CONTRACTOR shall promptly submit to COUNTY a written report, in such form as may be required by COUNTY of all accidents which occur in connection with this Agreement. This report must include the following information: (1) name and address of the injured or deceased person(s); (2) name and address of CONTRACTOR's sub-contractor, if any; (3) name and address of CONTRACTOR's liability insurance carrier; and (4) a detailed description of the accident and whether any of COUNTY's equipment, tools, material, or staff were involved.
Accident Insurance It is highly recommended that either the Sending Institution or the Receiving Organisation/Enterprise provide insurance coverage to the trainee, and fill in the information in Table B or C accordingly. The trainee must be covered at least by an accident insurance (damages caused to the trainee at the workplace) and by a liability insurance (damages caused by the trainee at the workplace).
ACCIDENT PAY The company shall pay accident pay as defined in the award, during the incapacity of their employee/s arising from any one injury, for a total of fifty-two (52) weeks - irrespective of whether such incapacity is in one continuous period or not.
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or
b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
Accident Prevention Health and Safety Committee (a) The Employer and the Union agree that they mutually desire to maintain standards of safety and health in the workplace in order to prevent accidents, injury and illness.
(b) Recognizing its responsibilities under the applicable legislation, the Employer agrees to accept as a member of its Accident Prevention – Health & Safety Committee at least three (3) representatives, one from each base, selected or appointed by the Union from amongst bargaining unit employees. At any time where a vote is required, an equal number of representatives from each side shall be entitled to vote.
(c) Such Committee shall identify potential dangers and hazards, institute means of improving health and safety programs and recommend actions to be taken to improve conditions related to safety and health.
(d) The Employee agrees to co-operate reasonably in providing necessary information to enable the Committee to fulfill its functions.
(e) Meetings shall be held quarterly or more frequently at the call of the Chair if required. The Committee shall maintain minutes of all meetings and make the same available for review.
(f) Any representative appointed or select in accordance with (b) hereof shall serve a term of one (1) calendar year from the date of appointment which may be renewed for further periods of one (1) year. The Union will encourage its representative(s) to serve at least one (1) year. Time off for such representative(s) to attend meetings of the Accident Prevention – Health & Safety Committee in accordance with the foregoing shall be granted and time so spent attending such meetings shall be deemed to be work time for which the representative(s) shall be paid by the Employer at his regular or premium rate as may be applicable.
(g) The Union agrees to endeavour to obtain the full co-operation of its membership in the observation of all safety rules and practices.
(h) Pregnant employees may request to be transferred from their current duties if, in the professional opinion of the employee’s physician, the pregnancy may be at risk. If such a transfer is not feasible, the pregnant employee, if she so requests, will be granted an unpaid leave of absence before commencement of the maternity leave referred to in Article 16.04
Disaster Services In the event of a local, state, or federal emergency, including natural, man-made, criminal, terrorist, and/or bioterrorism events, declared as a state disaster by the Governor, or a federal disaster declared by the appropriate federal official, Grantee may be called upon to assist the System Agency in providing the following services:
i. Community evacuation;
ii. Health and medical assistance;
iii. Assessment of health and medical needs;
iv. Health surveillance;
v. Medical care personnel;
vi. Health and medical equipment and supplies;
vii. Patient evacuation;
viii. In-hospital care and hospital facility status;
ix. Food, drug and medical device safety;
x. Worker health and safety;
xi. Mental health and substance abuse;
xii. Public health information;
xiii. Vector control and veterinary services; and
xiv. Victim identification and mortuary services.
