Orders Prices Terms Delivery Forecast and Inventory
Orders Prices Terms Delivery Forecast and Inventory Sample Clauses
Related to Orders Prices Terms Delivery Forecast and Inventory
Packing Specifications 7.3.1 A pack will contain a minimum of one message record or a maximum of 99,999 message records plus a pack header record and a pack trailer record. One transmission can contain a maximum of 99 packs and a minimum of one pack.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
ODUF Packing Specifications 6.3.1 A pack will contain a minimum of one message record or a maximum of 99,999 message records plus a pack header record and a pack trailer record. One transmission can contain a maximum of 99 packs and a minimum of one pack.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
As to Equipment and Inventory Grantor hereby agrees that it shall: (a) keep all the Equipment and Inventory (other than Inventory in transit and Inventory sold in the ordinary course of business) at the places therefor specified in Section 3.1.1 or, upon 30 days' prior written notice to Agent, at such other places in a jurisdiction where all representations and warranties set forth in Article III (including Section 3.1.6) shall be true and correct, and all action required pursuant to the first sentence of Section 4.1.7 shall have been taken with respect to the Equipment and Inventory; (b) with respect to any Equipment or Inventory in the possession or control of any Third Party or any of Grantor's agents, notify such Third Party or agent of Agent's security interest in such Equipment or Inventory and, upon Agent's request following the occurrence and during the continuance of an Event of Default, direct such Third Party or agent to hold all such Equipment or Inventory for Agent's account and subject to Agent's instructions; (c) cause the Equipment to be maintained and preserved in the same condition, repair and working order as when new, ordinary wear and tear excepted, and in accordance with any manufacturer's manual; and forthwith, or in the case of any material loss or damage to any of the Equipment, as quickly as practicable after the occurrence thereof, make or cause to be made all repairs, replacements, and other improvements in connection therewith which are necessary or desirable to such end; and promptly furnish to Agent a statement respecting any loss or damage to any of the Equipment within ten (10) business days after Grantor obtains knowledge of any such loss or damage; and (d) pay promptly when due all property and other taxes, assessments and governmental charges or levies imposed upon, and all claims (including claims for labor, materials and supplies) against, the Equipment and Inventory, except to the extent the validity thereof is being contested in good faith by appropriate proceedings and for which adequate reserves in accordance with Generally Accepted Accounting Principles have been set aside.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Delivery Schedule The Goods specified in the List of Goods are required to be delivered within the acceptable time range (after the earliest and before the final date, both dates inclusive) specified in Section V, Schedule of Requirements. No credit will be given to deliveries before the earliest date, and Tenders offering delivery after the final date shall be treated as non-responsive. Within this acceptable period, an adjustment of [insert the adjustment factor], will be added, for evaluation purposes only, to the Tender price of Tenders offering deliveries later than the “Earliest Delivery Date” specified in Section V, Schedule of Requirements.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
NASPO ValuePoint Summary and Detailed Usage Reports In addition to other reports that may be required by this solicitation, the Contractor shall provide the following NASPO ValuePoint reports.
Equipment Specifications All equipment must meet the contract specifications and all federal and State safety codes and regulations in effect at the date of manufacture. All equipment must be Original Equipment Manufacturer (OEM) equipment unless otherwise stated in the contract. All products, materials, supplies, replacement parts, and equipment offered and furnished must be new, of current manufacturer production, and must have been formally announced by the manufacturer as being commercially available, unless otherwise stated in this Contract.
