Other Architects and Engineers. Except in respect of the Design Architect (which shall be approved in accordance with Section 6.1(d)(i) hereof), the Production Architect and each other architect and engineer proposed to be engaged in respect to any Construction Work (other than Interior Construction Work or demolition work (other than the Demolition Work)) (A) governed by any element of the DUO, (B) affecting a Structural Component (other than by having a Nonadverse Structural Effect), or (C) of a value of greater than $1,000,000 (which amount shall be Adjusted for Inflation from the Substantial Completion Date), shall be approved by Landlord: (1) in respect of any Construction Work subject to clause (A) of this Section 6.1(d)(ii), in Landlord’s sole discretion; and (2) in respect of Construction Work subject only to clause (B) or (C) of this Section 6.1(d)(ii), in Landlord’s approval not to be unreasonably withheld. Each such Architect shall have substantial experience in construction projects that are comparable in scope to such architect’s intended work at the Project and shall not be a Prohibited Person. Each such Engineer shall (x) be of recognized standing among its peers, (y) have at least ten (10) years experience in providing engineering services in respect of highrise buildings in urban centers and (z) not be a Prohibited Person. If Landlord fails to approve or reject any architect nominated by Tenant to be an Architect (other than the Design Architect), or engineer nominated by Tenant to be an Engineer, as the case may be, within sixteen (16) Business Days after the written submission to Landlord of such architect’s name and other information (including adequate portfolio information) sufficiently detailed to permit Landlord to make a reasoned judgment of the appropriateness of the proposed architect or engineer, as the case may be, for the 00xx Xxxxxx Project, or Landlord fails to make reasonable requests for additional information related thereto within such time period and thereafter to approve or reject such architect or engineers, as the case may be within eleven (11) Business Days after written submission of such additional information as Landlord shall have reasonably requested, Tenant shall have the right to give Landlord a reminder notice, which reminder notice shall contain the following caption in bold and capitalized type: YOUR APPROVAL OF AS AN ARCHITECT/ENGINEER SHALL BE DEEMED GIVEN IF YOU FAIL TO APPROVE OR REJECT SUCH PERSON WITHIN FIVE (5) BUSINESS DAYS FROM THE DATE OF YOUR RECEIPT OF THIS NOTICE. If Landlord fails to approve or reject the proposed architect or engineers, as the case may be, within five (5) Business Days after its receipt of such reminder notice, such architect or engineer, as the came may be, shall be deemed approved by Landlord. Any rejection of an architect or engineer, as the case may be, by Landlord shall be accompanied by specific reasons setting forth in reasonable detail the basis for such rejection.
Appears in 2 contracts
Samples: Agreement of Sublease (New York Times Co), Agreement (New York Times Co)
Other Architects and Engineers. Except in respect of the Design Architect (which shall be approved in accordance with Section 6.1(d)(i9.6(a)(i) hereof), the Production Architect and each other architect and engineer proposed to be engaged in respect to any Construction Work Alteration (other than Interior Construction Work or demolition work (other than the Demolition Work)work) (A) governed by any element of the DUO, (B) affecting a Structural Component (other than by having a Nonadverse Structural Effect), or (C) of a value of greater than $1,000,000 (which amount shall be Adjusted for Inflation from the Substantial Completion Date), shall be approved by Landlord: (1) in respect of any Construction Work Alteration subject to clause (A) of this Section 6.1(d)(ii9.6(a)(ii), in Landlord’s sole discretion; and (2) in respect of Construction Work any Alteration subject only to clause (B) or (C) of this Section 6.1(d)(ii9.6(a)(ii), in Landlord’s approval approval, not to be unreasonably withheld. Each such Architect shall have substantial experience in construction projects that are comparable in scope to such architect’s intended work at the Project Improvements and shall not be a Prohibited Person. Each such Engineer shall (x) be of recognized standing among its peers, (y) have at least ten (10) years experience in providing engineering services in respect of highrise buildings in urban centers and (z) not be a Prohibited Person. If Landlord fails to approve or reject any architect nominated by Tenant to be an Architect (other than the Design Architect), or engineer nominated by Tenant to be an Engineer, as the case may be, within sixteen (16) Business Days after the written submission to Landlord of such architect’s name and other information (including adequate portfolio information) sufficiently detailed to permit Landlord to make a reasoned judgment of the appropriateness of the proposed architect or engineer, as the case may be, for the 00xx Xxxxxx Project, or Landlord fails to make reasonable requests for additional information related thereto within such time period and thereafter to approve or reject such architect or engineers, as the case may be within eleven (11) Business Days after written submission of such additional information as Landlord shall have reasonably requested, Tenant shall have the right to give Landlord a reminder notice, which reminder notice shall contain the following caption in bold and capitalized type: YOUR APPROVAL OF AS AN ARCHITECT/ENGINEER SHALL BE DEEMED GIVEN IF YOU FAIL TO APPROVE OR REJECT SUCH PERSON WITHIN FIVE (5) BUSINESS DAYS FROM THE DATE OF YOUR RECEIPT OF THIS NOTICE. If Landlord fails to approve or reject the proposed architect or engineers, as the case may be, within five (5) Business Days after its receipt of such reminder notice, such architect or engineer, as the came may be, shall be deemed approved by Landlord. Any rejection of an architect or engineer, as the case may be, by Landlord shall be accompanied by specific reasons setting forth in reasonable detail the basis for such rejection.
Appears in 2 contracts
Samples: Agreement of Sublease (New York Times Co), Memorandum of Agreement (New York Times Co)
Other Architects and Engineers. Except in respect of the Design Architect (which shall be approved in accordance with Section 6.1(d)(i) hereof), the Production Architect and each other architect and engineer proposed to be engaged in respect to any Construction Work (other than Interior Construction Work or demolition work (other than the Demolition Work)) (A) governed by any element of the DUO, (B) affecting a Structural Component (other than by having a Nonadverse Structural Effect), or (C) of a value of greater than $1,000,000 (which amount shall be Adjusted for Inflation from the Substantial Completion Date), shall be approved by Landlord: (1) in respect of any Construction Work subject to clause (A) of this Section SECTION 6.1(d)(ii), in Landlord’s 's sole discretion; and (2) in respect of Construction Work subject only to clause (B) or (C) of this Section SECTION 6.1(d)(ii), in Landlord’s 's approval not to be unreasonably withheld. Each such Architect shall have substantial experience in construction projects that are comparable in scope to such architect’s 's intended work at the Project and shall not be a Prohibited Person. Each such Engineer shall (x) be of recognized standing among its peers, (y) have at least ten (10) years experience in providing engineering services in respect of highrise buildings in urban centers and (z) not be a Prohibited Person. If Landlord fails to approve or reject any architect nominated by Tenant to be an Architect (other than the Design Architect), or engineer nominated by Tenant to be an Engineer, as the case may be, within sixteen (16) Business Days after the written submission to Landlord of such architect’s 's name and other information (including adequate portfolio information) sufficiently detailed to permit Landlord to make a reasoned judgment of the appropriateness of the proposed architect or engineer, as the case may be, for the 00xx Xxxxxx 42nd Street Project, or Landlord fails to make reasonable requests for additional fxx xxxxxxxxal information related thereto within such time period and thereafter to approve or reject such architect or engineers, as the case may be within eleven (11) Business Days after written submission of such additional information as Landlord shall have reasonably requested, Tenant shall have the right to give Landlord a reminder notice, which reminder notice shall contain the following caption in bold and capitalized type: YOUR APPROVAL OF ______ AS AN ARCHITECT/ENGINEER SHALL BE DEEMED GIVEN IF YOU FAIL TO APPROVE OR REJECT SUCH PERSON WITHIN FIVE (5) BUSINESS DAYS FROM THE DATE OF YOUR RECEIPT OF THIS NOTICE. If Landlord fails to approve or reject the proposed architect or engineers, as the case may be, within five (5) Business Days after its receipt of such reminder notice, such architect or engineer, as the came may be, shall be deemed approved by Landlord. Any rejection of an architect or engineer, as 60 the case may be, by Landlord shall be accompanied by specific reasons setting forth in reasonable detail the basis for such rejection.
Appears in 1 contract
