COUNTY’S RESPONSIBILITIES A. A County program liaison will monitor the submission of all correspondence required in this Agreement, including, but not limited to: 1. Quarterly Treatment Reports; 2. Financial reports such as annual budgets, cost allocation plans, and cost reports; 3. Incident reports; 4. Outcome data; 5. Monthly XXXXX Reports 6. Other requested reports B. A County program liaison may visit Contractor during the contract term. The visits shall be for the purpose of reviewing any aspect of Contractor’s program operations. The visit may include, but is not limited to: 1. Review all pertinent participant records. 2. Conduct appropriate interviews/discussions with participants served by Contractor. 3. Review and monitor all correspondence and reports submitted by Contractor related to Contractor’s services provided under this Agreement. 4. Meet with appropriate program management and operations staff. 5. Conduct site visit(s) to Contractor’s program(s) at least once during the term of the Agreement to review all aspects of program operations. Site visit(s) may include a review of Contractor’s programmatic and fiscal documentation related to required reports on services specified in the Exhibits. a. Provide a written site review report documenting areas of compliance and any necessary corrective action(s) required. 6. A County program liaison may attend an organized activity of a selected component or selected components of Contractor’s program(s) at least once during the contract term. C. AODS will conduct periodic mandatory treatment provider meetings with representatives of all contracted service providers and appropriate staff. D. Provide ongoing technical assistance as needed. E. AODS shall act as intermediary on behalf of each contracted alcohol and drug service provider in the submission of the California Outcomes Measurement System (CalOMS) data submissions to the State of California. I. GENERAL ADMINISTRATIVE REQUIREMENTS A. Attend each of the following meetings: 1. Contractor shall attend periodic mandatory meetings; and 2. Drug and Alcohol Information System for You (DAISY) User Group meeting. 3. Other meetings as required by the County B. Contractor shall acknowledge the San Mateo County Alcohol and Other Drug Services (AODS) and/or the County of San Mateo as a funding source on newly developed promotional materials. C. Subcontracting requirements: 1. Pursuant to paragraph 12 of the body of this Agreement, Contractor may subcontract for provision of services described in this Agreement with written approval of the Director of the Human Services Agency or her designee. If Contractor subcontracts for any services under this Agreement, Contractor will guarantee that any and all subcontractors have and maintain the same level of insurance coverage required of the Contractor under this Agreement. Contractor and County will be listed as additional insured on all applicable insurance of subcontractor.
Monitoring Responsibilities The Custodian shall furnish annually to the Fund, during the month of June, information concerning the foreign sub-custodians employed by the Custodian. Such information shall be similar in kind and scope to that furnished to the Fund in connection with the initial approval of this Contract. In addition, the Custodian will promptly inform the Fund in the event that the Custodian learns of a material adverse change in the financial condition of a foreign sub-custodian or any material loss of the assets of the Fund or in the case of any foreign sub-custodian not the subject of an exemptive order from the Securities and Exchange Commission is notified by such foreign sub-custodian that there appears to be a substantial likelihood that its shareholders' equity will decline below $200 million (U.S. dollars or the equivalent thereof) or that its shareholders' equity has declined below $200 million (in each case computed in accordance with generally accepted U.S. accounting principles).
CITY’S RESPONSIBILITIES 2.1. The CITY shall designate in writing a project coordinator to act as the CITY's representative with respect to the services to be rendered under this Agreement (the "Project Coordinator"). The Project Coordinator shall have authority to transmit instructions, receive information, interpret and define the CITY's policies and decisions with respect to the CONTRACTOR's services for the Project. However, the Project Coordinator is not authorized to issue any verbal or written orders or instructions to the CONTRACTOR that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: (a) The scope of services to be provided and performed by the CONTRACTOR; (b) The time the CONTRACTOR is obligated to commence and complete all such services; or (c) The amount of compensation the CITY is obligated or committed to pay the CONTRACTOR. 2.2. The Project Coordinator shall: (a) Review and make appropriate recommendations on all requests submitted by the CONTRACTOR for payment for services and work provided and performed in accordance with this Agreement; (b) Arrange for access to and make all provisions for the CONTRACTOR to enter the Project site to perform the services to be provided by the CONTRACTOR under this Agreement; and (c) Provide notice to the CONTRACTOR of any deficiencies or defects discovered by the CITY with respect to the services to be rendered by the CONTRACTOR hereunder. 2.3. The CONTRACTOR acknowledges that access to the Project Site, to be arranged by the CITY for the CONTRACTOR, may be provided during times that are not the normal business hours of the CONTRACTOR. 3.1. Services to be rendered by the CONTRACTOR shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from the CITY for all or any designated portion of the Project and shall be for a period of two (2) years and three (3) month, with the option for two (2) additional one (1) year renewal. Time is of the essence with respect to the performance of this Agreement. 3.2. Should the CONTRACTOR be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of the CONTRACTOR, and not due to its own fault or neglect, including but not restricted to acts of God or of public enemy, acts of government or of the CITY, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then the CONTRACTOR shall notify the CITY in writing within 5 working days after commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which the CONTRACTOR may have had to request a time extension. 3.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the CONTRACTOR's services from any cause whatsoever, including those for which the CITY may be responsible in whole or in part, shall relieve the CONTRACTOR of its duty to perform or give rise to any right to damages or additional compensation from the CITY. The CONTRACTOR's sole remedy against the CITY will be the right to seek an extension of time to its schedule. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. [If Applicable-Provided, however, if through no fault or neglect of the CONTRACTOR, the services to be provided hereunder have not been completed within 18 months of the date hereof, the CONTRACTOR's compensation may be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by the CONTRACTOR after expiration of said 18 month period.] 3.4. Should the CONTRACTOR fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely and reasonable manner, in addition to any other rights or remedies available to the CITY hereunder, the CITY at its sole discretion and option may withhold any and all payments due and owing to the CONTRACTOR until such time as the CONTRACTOR resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the CITY's satisfaction that the CONTRACTOR's performance is or will shortly be back on schedule.
IRO Responsibilities The IRO shall: 1. perform each Claims Review in accordance with the specific requirements of the CIA;
Specific Responsibilities The JDC shall meet at least semi-annually, or as otherwise agreed to by the Parties, and such meetings may be conducted by telephone, video-conference or in person as determined by the JDC members, provided that with respect to in person meetings, unless otherwise agreed the location of such meetings shall alternate between locations designated by Licensor and locations designated by AbbVie. The JDC shall develop the strategies for and oversee the Development of the Licensed Antibodies or Licensed Products in the Territory, and shall serve as a forum for the coordination of Development activities for the Licensed Antibodies or Licensed Products for the Territory. In particular, the JDC shall: (a) periodically (no less often than annually) review and serve as a forum for discussing each Pre Exercise Development Plan and Budget, and review and approve amendments thereto, which approval will be reflected in the applicable minutes of the JDC meeting; *** Certain information in this agreement has been omitted and filed separately with the Securities and Exchange Commission. [***] indicates that text has been omitted and is the subject of a confidential treatment request. (b) serve as a forum for discussing and oversee the conduct of Pre Exercise Development Activities; (c) periodically (no less often than annually) review and approve each Post Exercise Development Plan and Budget, and review and approve amendments thereto, which approval will be reflected in the applicable minutes of the JDC meeting; (d) serve as a forum for discussing the conduct of the applicable Country-Specific Development Activities; (e) serve as a forum for discussing and oversee the conduct of Additional Licensor Development Activities; (f) serve as a forum for reviewing and approving strategies for obtaining Regulatory Approvals including approving use of consultants, key opinion leaders or any other experts to seek advice on strategies for seeking Regulatory Approvals for the Licensed Products in the Territory; (g) establish secure access methods (such as secure databases) for each Party to access Regulatory Documentation and other JDC related Information as contemplated under this Agreement; and (h) perform such other functions as are set forth herein or as the Parties may mutually agree in writing, except where in conflict with any provision of this Agreement.
Contractor’s Responsibilities Unless stated specifically to the contrary in the tender with full supporting explanations, the contractor will be deemed to have concurred as a practical manufacturer with the design and layout of the works as being sufficient to ensure reliability and safety in operation, freedom from undue stresses and satisfactory performance in all other essentials as a working material.
Client’s Responsibilities In addition to other responsibilities herein or imposed by law, the Client shall: (a) Designate in writing a person to act as its representative, such person having complete authority to transmit instructions, receive information, and make or interpret the Client's decisions. (b) Provide all information and criteria as to the Client's requirements, objectives, and expectations for the project and all standards of development, design, or construction. (c) Provide the Consultant all available studies, plans, or other documents pertaining to the project, such as surveys, engineering data, environmental information, etc., all of which the Consultant may rely upon. (d) Arrange for access to the site and other property as required for the Consultant to provide its services. (e) Review all documents or reports presented by the Consultant and communicate decisions pertaining thereto within a reasonable time so as not to delay the Consultant. (f) Furnish approvals and permits from governmental authorities having jurisdiction over the project and approvals and consents from other parties as may be necessary. (g) Obtain any independent accounting, legal, insurance, cost estimating and feasibility services required by Client. (h) Give prompt written notice to the Consultant whenever the Client becomes aware of any development that affects the Consultant's services or any defect or noncompliance in any aspect of the project.
Our Responsibilities This notice describes how medical information about you may be used and disclosed and how you can get access to this information. This notice took effect on September 23, 2013. We are required to maintain the privacy of your protected health information and we will follow the terms of this notice while it is in effect. • Your past, present, or future physical or mental health or condition • Providing you health care • The past, present, or future payment for providing you health care We collect your information as necessary to provide you with health insurance products and services and to administer our business. We may also disclose this information to nonaffiliated third parties as described in this notice. The types of information we may collect and disclose include: • Information you or your employer provide on applications and other forms, such as names, addresses, social security numbers, and dates of birth • Information about your interactions with us or others (such as providers) regarding your medical information or claims • Information you provide in person, by phone, in email, or through visits to our website • You can ask to see or get a copy of your health and claims records and other health information we have about you. • We will provide a copy or a summary of your health and claims records, usually within 30 days of your request. We may charge a reasonable, cost-based fee. • We may ask that you submit your request in writing. Please note, if you want to obtain copies of your medical records, you should contact the practitioner or facility. We do not generate, modify, or maintain complete medical records. • You may also request that we send a copy of your information to a third party. We may ask that you submit a written, signed authorization form permitting us to do so and we may charge a reasonable fee for copying and mailing your personal information. • You can ask us to correct your health and claims records if you think they are incorrect or incomplete. • We may say no to your request, but we’ll tell you why in writing within 60 days. • You can ask us to contact you in a specific way (for example, home or office phone) or to send mail to a different address. • We will consider all reasonable requests, and must say “yes” if you tell us you would be in danger if we do not. • All requests should be made in writing. • It may take a short period of time for us to implement your request. • We will comply with your request if it is reasonable and continues to permit us to collect premiums and pay claims under your policy, including issuing certain explanations of benefits and policy information to the BlueShield of Northeastern New York is a division of HealthNow New York Inc., an independent licensee of the BlueCross BlueShield Association. 15049R_NENY_12_19 f11011 subscriber of the policy. For example, even if you request confidential communications: ο We will mail the check for services you receive from a nonparticipating provider to you but made payable to the subscriber ο Accumulated payment information such as deductibles (in which your information might appear), will continue to appear on explanations of benefits sent to the subscriber ο We may disclose to the subscriber, as the contract holder, policy details such as eligibility status or certificates of coverage • You can ask us not to use or share certain health information for treatment, payment, or our operations. • We are not required to agree to your request, but if we do, we will abide by our agreement (except when necessary for treatment in an emergency). • You have the right to authorize individuals to act on your behalf with respect to your information. You must identify your authorized representatives on a HIPAA-compliant authorization form (available on our website) and explain what type of information they may receive. • You have the right to revoke an authorization except for actions already taken based on your authorization. • You can complain if you feel we have violated your rights by contacting us using the information listed on page 4. • You can file a complaint with the U.S. Department of Health and Human Services Office for Civil Rights. • We will not retaliate against you for filing a complaint. • With your family, close friends, or others involved with your health care or payment for your care when you are present and have given us permission to do so. If you are not present, if it is an emergency, or you are not able to give us permission, we may give your information to a family member, friend, or other person if sharing your information is in your best interest. In these cases, the person requesting your information must accurately verify details about you (e.g., name, identification number, date of birth, etc.) and prove involvement with your health care or payment for your health care by providing details relevant to the information requested. For example, if a family member calls us with prior knowledge of a claim (e.g., provider’s name, date of service, etc.), we may confirm the claim’s status, patient responsibility, etc. We will only disclose information directly relevant to that person’s involvement with your health care or payment for your health care. • In a disaster relief situation. In these cases we never share your information unless you give us written permission: • Marketing purposes • Sale of your information • Disclose your psychotherapy notes • Make certain disclosures of information considered sensitive in nature, such as HIV/AIDS, mental health, alcohol or drug dependency, and sexually transmitted diseases. Certain federal and state laws require that we limit how we disclose this information. In general, unless we obtain your written authorization, we will only disclose such information as provided for in applicable laws. We typically use or share your health information in the following ways: • We can use your health information and share it with professionals who are treating you.
ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Owner Responsibilities Owner shall: A. Provide all documentation, records and disclosures as required by law or required by Xxxxxx to manage and operate the Property, and immediately notify Broker if Owner becomes aware of any change in such documentation, records or disclosures, or any matter affecting the habitability of the Property. X. Xxxxxxxxx, defend and hold harmless Broker, and all persons in Broker's firm, regardless of responsibility, from all costs, expenses, suits, liabilities, damages, attorney fees and claims of every type, including but not limited to those arising out of injury or death of any person, or damage to any real or personal property of any person, including Owner, for: (i) any repairs performed by Owner or by others hired directly by Owner; or (ii) those relating to the management, leasing, rental, security deposits, or operation of the Property by Xxxxxx, or any person in Broker's firm, or the performance or exercise of any of the duties, powers or authorities granted to Broker. C. Maintain the Property in a condition fit for human habitation as required by IC 32-31-8-5. X. Xxxxx and pay for: (i) public and premises liability insurance in an amount of no less than $1,000,000; and (ii) property damage and worker's compensation insurance adequate to protect the interests of Owner and Broker. Broker shall be, and Owner authorizes Broker to be, named as an additional insured party on Owner's policies. E. Pay any late charges, penalties and/or interest imposed by lenders or other parties for failure to make payment to those parties, if the failure is due to insufficient funds in Broker's trust account available for such payment. F. Immediately replace any funds required if there are insufficient funds in Broker's trust account to cover Owner's responsibilities.
