Performance Excused Continued performance of a Service may be suspended immediately to the extent caused by any event or condition beyond the reasonable control of the Party suspending such performance including, but not limited to, any act of God, fire, labor or trade disturbance, war, civil commotion, compliance in good faith with any law, unavailability of materials or other event or condition whether similar or dissimilar to the foregoing (each, a “Force Majeure Event”).
Delay of the Substantial Completion of the Premises Except as provided in this Section 5.2, the Lease Commencement Date shall occur as set forth in the Lease and Section 5.1, above. If there shall be a delay or there are delays in the Substantial Completion of the Premises or in the occurrence of any of the other conditions precedent to the Lease Commencement Date, as set forth in the Lease, as a direct, indirect, partial, or total result of:
Project Management With respect to each Project Plan, each party will appoint a project manager who will be the party responsible for overseeing the Project Plan.
Commercial Diligence Upon execution of this Agreement, Licensee shall diligently proceed with Commercially Diligent Efforts to develop, manufacture, practice, sell and use the Licensed Products in order to make them readily available to the general public as soon as possible on commercially reasonable terms. Licensee shall continue active, diligent Commercially Diligent Efforts for one or more Licensed Product(s) throughout the term of this Agreement (“Actively Commercializing”). In addition, Licensee shall perform at least the following obligations as part of its due diligence activities hereunder:
Landlord’s Repair Obligations If this Lease does not terminate with respect to the entire Premises under Section 12.1, and if the Taking includes a portion of the Premises, then this Lease shall automatically terminate as to the portion of the Premises taken as of the date the Condemning Authority takes possession of the portion taken and Landlord will, at its sole cost and expense, restore the remaining portion of the Premises to a complete architectural unit with all commercially reasonable diligence and speed and will reduce the Basic Rent for the period after the date the Condemning Authority takes possession of the portion of the Premises taken to a sum equal to the product of the Basic Rent provided for in this Lease multiplied by a fraction, the numerator of which is the rentable area of the Premises after the Taking and after Landlord restores the Premises to a complete architectural unit, and the denominator of which is the rentable area of the Premises prior to the Taking. Landlord will also equitably adjust Tenant's Share of Expenses Percentage for the same period, subject to Section 3.7, to account for the reduction in the rentable area of the Premises or the Building resulting from the Taking. Tenant's obligation to pay Basic Rent and Tenant's Share of Expenses will xxxxx on a proportionate basis with respect to that portion of the Premises remaining after the Taking that Tenant is unable to use during Landlord's restoration for the period of time that Tenant is unable to use such portion of the Premises.
Development Diligence Pfizer will use its Commercially Reasonable Efforts to Develop and seek Regulatory Approval for [ * ] Product [ * ] in the Field [ * ]. Pfizer will [ * ] with respect to the Development or Regulatory Approval of Products under this Agreement.
Root Cause Analysis Upon Vendor's failure to provide the Services in accordance with the applicable Service Levels (for any reason other than a Force Majeure Event) Vendor will promptly (a) perform a root-cause analysis to identify the cause of such failure, (b) provide Prudential with a report detailing the cause of, and procedure for correcting, such failure, (c) obtain Prudential's written approval of the proposed procedure for correcting such failure, (d) correct such failure in accordance with the approved procedure, (e) provide weekly (or more frequent, if appropriate) reports on the status of the correction efforts, and (f) provide Prudential with assurances satisfactory to Prudential that such failure has been corrected and will not recur.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Acceptance of Employment; Standard of Performance The Subadviser accepts its employment as a discretionary series adviser of the Designated Series and agrees to use its best professional judgment to make investment decisions for the Designated Series in accordance with the provisions of this Agreement and as set forth in Schedule D attached hereto and made a part hereof.
Premises Parking and Common Areas 2.1 Letting Lessor hereby leases to Lessee, and Lessee hereby leases from Lessor, the Premises, for the term, at the rental, and upon all of the terms covenants and conditions set forth in this Lease. Unless otherwise provided herein, any statement of square footage set forth in this Lease, or that may have been used in calculating rental and/or Common Area Operating Expenses, is an approximation which Lessor and Lessee agree is reasonable and the rental and Lessee's Share (as defined in Paragraph 1.6(b)) based thereon is not subject to revision whether or not the actual square footage is more or less.
