Payment Does Not Constitute Acceptance Sample Clauses

Payment Does Not Constitute Acceptance. Payment does not constitute acceptance, but all materials, merchandise or services are subject to Purchaser’s/Contractor’s inspection and rejection: defective material or merchandise or service not per the specifications will be held for Seller’s/Subcontractor’s instruction and at Seller’s/Subcontractor’s risk. No goods returned as defective shall be replaced without an order. No statement, condition or agreement, and no representation or guarantee has been made by any agent, officer or employee of Purchaser/Contractor in any way affecting the terms hereof. No alteration or modification of this order is varied unless in writing, signed by an authorized executive of Purchaser. Sellers/Subcontractor agrees that it will not assign Seller’s/Subcontractor’s Work or any aspect of this Agreement, or any of the monies due it, or become due hereunder, nor sublet any portion of the work without first obtaining written consent of the Purchaser/Contractor. Should Purchaser/Contractor consent to Seller/Subcontractor request to issue a Tiered‐Subcontract or assign a portion of this scope of work, Seller/Subcontractor agrees to bind all Tiered‐Subcontractors to the scope, terms, conditions and obligations of this purchase order/subcontract and all referenced documents herein. All work performed or all material furnished by Seller/Subcontractor and/or Tiered‐Subcontractors shall be in strict accordance with all applicable plans, general conditions, specifications, and addenda as incorporated herein and Tiered‐Subcontractor(s) are bound by all provisions of these documents, and all other documents to which the Purchaser/Contractor as named herein is bound, and to the same extent. This Agreement’s references to Seller/Subcontractor shall also refer to any Tiered‐Subcontractor, such that any and all requirements and obligations of Seller/Subcontractor are the same for Tiered‐Subcontractors. Compliance With All Rules and Regulations of the Governing Authorities and Agencies: Seller/Subcontractor further agrees to comply with all existing safety and health requirements of local, state and federal regulatory agencies and to provide the required S.D.S. sheets to comply with O.S.H.A. Hazard Communication requirements. Seller/Subcontractor shall pay all contributions, taxes or premiums which may be payable under Federal or State Unemployment Insurance law or the Federal Social Security Act and all Sales, Use or other Taxes arising out of the performance of this purchase order/cont...
Sample 1Sample 2
AutoNDA by SimpleDocs
Payment Does Not Constitute Acceptance. No payment by Owner of any Application for Payment shall constitute acceptance by Owner of Work completed or of materials stored that are not in conformity with the Contract Documents, and no such payment shall be construed as a waiver of any right or claim by Owner in connection with such Work or stored material.
Sample 1Sample 2
Payment Does Not Constitute Acceptance. Payment shall not constitute acceptance of Products and shall be subject to adjustment for errors, shortage, defects in Products or other failure of PIC to comply with the terms of this Agreement. Acceptance shall be deemed to have taken place as set forth in Section 4.2.
Sample 1

Related to Payment Does Not Constitute Acceptance

  • Payment Does Not Imply Acceptance of Work The granting of any payment by City, or the receipt thereof by Contractor, shall in no way lessen the liability of Contractor to replace unsatisfactory work, equipment, or materials, although the unsatisfactory character of such work, equipment or materials may not have been apparent or detected at the time such payment was made. Materials, equipment, components, or workmanship that do not conform to the requirements of this Agreement may be rejected by City and in such case must be replaced by Contractor without delay.

  • Payment Not Acceptance Payment of any progress payment or final payment shall not constitute acceptance of Work that is defective or otherwise fails to conform to the Agreement, or a waiver of any rights or remedies the Department may have with respect to defective or nonconforming Work.

  • Required Acceptance of Daily Load Deliveries and Notification If the State is harmed by purchaser’s refusal to accept up to 10 truck deliveries of any one sort per day, Purchaser will be in breach of contract and subject to damages as per the D-026.2 and D-027.2 clauses. A truck delivery is all the wood delivered including sorts on super trucks, mule trains and pups brought to the delivery point by a single truck. The Purchaser shall notify the Contract Administrator at least 48 hours in advance if: 1. Purchaser intends to limit the number of truck deliveries accepted on any day to less than that listed above, or 2. Purchaser intends to limit the number of truck deliveries accepted on any day to the number listed above.

  • Acceptance of Services Not a Waiver The City’s acceptance of any service or deliverable is not a waiver or release of any professional duty of care applicable to such service or deliverable, or of any right of indemnification, any insurance requirements, or any other term or condition of this Master Agreement.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Agreement Not Evidence (1) The Parties agree that, whether or not it is finally approved, is terminated, or otherwise fails to take effect for any reason, this Settlement Agreement and anything contained herein, and any and all negotiations, documents, discussions and proceedings associated with this Settlement Agreement, and any action taken to carry out this Settlement Agreement, shall not be referred to, offered as evidence or received in evidence in any pending or future civil, criminal or administrative action or proceeding, except in a proceeding to approve and/or enforce this Settlement Agreement, to defend against the assertion of Released Claims, as necessary in any insurance-related proceeding, or as otherwise required by law.

  • Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. 2

  • ACCEPTANCE OF CONTRACT/TERMS AND CONDITIONS (a) This Contract integrates, merges, and supersedes any prior offers, negotiations, and agreements concerning the subject matter hereof and constitutes the entire agreement between the parties. (b) SELLER's acknowledgment, acceptance of payment, or commencement of performance, shall constitute SELLER's unqualified acceptance of this Contract. (c) Unless expressly accepted in writing by LOCKHEED XXXXXX, additional or differing terms or conditions proposed by SELLER or included in SELLER's acknowledgment are objected to by LOCKHEED XXXXXX and have no effect. (d) The headings used in this Contract are inserted for the convenience of the parties and shall not define, limit, or describe the scope or the intent of the provisions of this Contract.

  • Additional Wet Weather Procedure 14.15.1 Remaining On Site a) for more than an accumulated total of four hours of ordinary time in any one day; or b) after the meal break, as provided for in clause 17.1 of the Award, for more than an accumulated total of 50% of the normal afternoon work time; or c) during the final two hours of the normal work day for more than an accumulated total of one hour, the Enterprise will not be entitled to require the employees to remain on site beyond the expiration of any of the above circumstances.

  • Conditions of Acceptance The insurance maintained by the Company must conform at all times with the Authority’s Standard Procedure S250.06, Contractual Insurance Terms and Conditions, which may be amended from time to time, and is posted on the Authority website at xxx.XxxxxXxxxxxx.xxx > Learn about TPA > Airport Business > Procurement > Additional Supplier Resources – Contractual Insurance Terms and Conditions.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!