Initiation of Appeal Following the entry of the Arbitration Award, either party (the “Appellant”) shall have a period of thirty (30) calendar days in which to notify the other party (the “Appellee”), in writing, that the Appellant elects to appeal (the “Appeal”) the Arbitration Award (such notice, an “Appeal Notice”) to a panel of arbitrators as provided in Paragraph 5.2 below. The date the Appellant delivers an Appeal Notice to the Appellee is referred to herein as the “Appeal Date”. The Appeal Notice must be delivered to the Appellee in accordance with the provisions of Paragraph 4.1 above with respect to delivery of an Arbitration Notice. In addition, together with delivery of the Appeal Notice to the Appellee, the Appellant must also pay for (and provide proof of such payment to the Appellee together with delivery of the Appeal Notice) a bond in the amount of 110% of the sum the Appellant owes to the Appellee as a result of the Arbitration Award the Appellant is appealing. In the event an Appellant delivers an Appeal Notice to the Appellee (together with proof of payment of the applicable bond) in compliance with the provisions of this Paragraph 5.1, the Appeal will occur as a matter of right and, except as specifically set forth herein, will not be further conditioned. In the event a party does not deliver an Appeal Notice (along with proof of payment of the applicable bond) to the other party within the deadline prescribed in this Paragraph 5.1, such party shall lose its right to appeal the Arbitration Award. If no party delivers an Appeal Notice (along with proof of payment of the applicable bond) to the other party within the deadline described in this Paragraph 5.1, the Arbitration Award shall be final. The parties acknowledge and agree that any Appeal shall be deemed part of the parties’ agreement to arbitrate for purposes of these Arbitration Provisions and the Arbitration Act.
Tax Appeals Purchaser acknowledges that certain of the Sellers, as identified on the Seller Information Schedule (the “Tax Appeal Sellers”) have filed appeals (each, an “Appeal”) with respect to real estate ad valorem or other similar property taxes applicable to the Tax Appeal Properties (the “Property Taxes”).
Error Period An Error Period comprises those days during which the circumstances causing an NAV Error exist prior to correction.
Selection and Payment of Appeal Panel In the event an Appellant delivers an Appeal Notice to the Appellee (together with proof of payment of the applicable bond) in compliance with the provisions of Paragraph 5.1 above, the Appeal will be heard by a three (3) person arbitration panel (the “Appeal Panel”).
Purchaser's Election to Commence Foreclosure Proceedings (a) In connection with any Mortgage Loan identified in a report under Section 2.01(a)(i)(B), the Purchaser may elect to instruct the Company to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to proceed with the Commencement of Foreclosure as soon as practicable. Such election must be evidenced by written notice received by the Company by 5:00 p.m., New York City time, on the third Business Day following the delivery of such report under Section 2.01(a)(i).
Lien and Judgment Searches The Administrative Agent shall have received the results of recent lien and judgment searches in each of the jurisdictions contemplated by the Perfection Certificate, and such search shall reveal no material judgments and no liens on any of the assets of the Loan Parties except for Permitted Liens or Liens discharged on or prior to the Closing Date pursuant to a pay-off letter or other documentation reasonably satisfactory to the Administrative Agent.
Adjustment of Commencement Date; Possession 3.01 If Landlord is required to perform Landlord Work prior to the Commencement Date: (a) the date set forth in Section 1.06 as the Commencement Date shall instead be defined as the “Target Commencement Date”; (b) the actual Commencement Date shall be the date on which the Landlord Work is Substantially Complete (defined below); and (c) the Termination Date will the last day of the Term as determined based upon the actual Commencement Date. Landlord’s failure to Substantially Complete the Landlord Work by the Target Commencement Date shall not be a default by Landlord or otherwise render Landlord liable for damages. Promptly after the determination of the Commencement Date, Landlord and Tenant shall enter into a commencement letter agreement in the form attached as Exhibit D. If the Termination Date does not fall on the last day of a calendar month, Landlord and Tenant may elect to adjust the Termination Date to the last day of the calendar month in which Termination Date occurs by the mutual execution of a commencement letter agreement setting forth such adjusted date. The Landlord Work shall be deemed to be “Substantially Complete” on the date that all Landlord Work has been performed, other than any details of construction, mechanical adjustment or any other similar matter, the non-completion of which does not materially interfere with Tenant’s use of the Premises. If Landlord is delayed in the performance of the Landlord Work as a result of the acts or omissions of Tenant, the Tenant Related Parties (defined in Section 13) or their respective contractors or vendors, including, without limitation, changes requested by Tenant to approved plans, Tenant’s failure to comply with any of its obligations under this Lease, or the specification of any materials or equipment with long lead times (a “Tenant Delay”), the Landlord Work shall be deemed to be Substantially Complete on the date that Landlord could reasonably have been expected to Substantially Complete the Landlord Work absent any Tenant Delay.
Litigation and Unilateral Commencement of Arbitration Notwithstanding the foregoing provisions of this Article VII, (a) a Party may seek preliminary provisional or injunctive judicial relief with respect to a Dispute without first complying with the procedures set forth in Section 7.1, Section 7.2 and Section 7.3 if such action is reasonably necessary to avoid irreparable damage and (b) either Party may initiate arbitration before the expiration of the periods specified in Section 7.2 and Section 7.3 if (i) such Party has submitted a Mediation Request or Arbitration Request, as applicable, and the other party has failed, within the applicable periods set forth in Section 7.3, to agree upon a date for the first mediation session to take place within thirty (30) days after the appointment of such mediator or such longer period as the Parties may agree to in writing or (ii) such Party has failed to comply with Section 7.3 in good faith with respect to commencement and engagement in arbitration. In such event, the other Party may commence and prosecute such arbitration unilaterally in accordance with the CPR Arbitration Procedure.
Notice of Change of Beneficiary Immediately prior to any transfer of Stock to a Management Stockholder’s Trust, the Management Stockholder shall provide the Company with a copy of the instruments creating the Management Stockholder’s Trust and with the identity of the beneficiaries of the Management Stockholder’s Trust. The Management Stockholder shall notify the Company as soon as practicable prior to any change in the identity of any beneficiary of the Management Stockholder’s Trust.
Appeals If the forum selected in accordance with Section 8.4 hereof is not a court, then after the final decision of such forum is rendered, the Company or the Indemnitee shall have the right to apply to a court of Nevada, the court in which the proceeding giving rise to the Indemnitee’s claim for indemnification is or was pending, or any other court of competent jurisdiction, for the purpose of appealing the decision of such forum, provided that such right is executed within sixty (60) days after the final decision of such forum is rendered. If the forum selected in accordance with Section 8.4 hereof is a court, then the rights of the Company or the Indemnitee to appeal any decision of such court shall be governed by the applicable laws and rules governing appeals of the decision of such court.
