Reimbursement of Eligible Costs To be eligible for reimbursement, the Engineer's costs must (1) be incurred in accordance with the terms of a valid work authorization; (2) be in accordance with Attachment E, Fee Schedule; and (3) comply with cost principles set forth at 48 CFR Part 31, Federal Acquisition Regulation (FAR 31). Satisfactory progress of work shall be maintained as a condition of payment.
Reimbursement Amount Except for the metropolitan areas listed below, the maximum reimbursement for meals including tax and gratuity, shall be: Breakfast $ 9.00 Lunch $11.00 Dinner $16.00 For the following metropolitan areas the maximum reimbursement shall be: Breakfast $11.00 Lunch $13.00 Dinner $20.00 The metropolitan areas are: Atlanta Boston Cleveland Denver Hartford Kansas City Miami New York City Portland, OR San Francisco St. Louis Baltimore Chicago Dallas/Fort Worth Detroit Houston Los Angeles New Orleans Philadelphia San Diego Seattle Washington D.C. See Appendix L for details related to the boundaries of the above-mentioned metropolitan areas. The metropolitan areas also include any location outside the forty-eight (48) contiguous United States. Employees who meet the eligibility requirements for two (2) or more consecutive meals shall be reimbursed for the actual costs of the meals up to the combined maximum reimbursement amount for the eligible meals.
Adjustments to Required Subordinated Percentages and Amount (a) On any date, the Issuer may, at the direction of the Beneficiary, change the Required Subordinated Percentage of Class B Notes, the Required Subordinated Percentage of Class C Notes or the Required Subordinated Percentage of Class D Notes, in each case for the Class A(2016-4) Notes, without the consent of any Noteholders; provided that the Issuer has received written confirmation from each applicable Note Rating Agency that the change in such percentage will not result in a Ratings Effect for any Tranche of Outstanding DiscoverSeries Notes. (b) On any date, the Issuer may, at the direction of the Beneficiary, replace all or a portion of the Required Subordinated Amount of Class B Notes, the Required Subordinated Amount of Class C Notes or the Required Subordinated Amount of Class D Notes, in each case for the Class A(2016-4) Notes with a different form of credit enhancement (including, without limitation, a cash collateral account, a letter of credit, a reserve account, a surety bond, an insurance policy or a collateral interest, or any combination thereof) and may add such definitions and other terms and make such additional amendments to this Terms Document as shall be necessary for such replacement without the consent of any Noteholders, provided that the Issuer has received written confirmation from each applicable Note Rating Agency that such replacement and such other amendments will not result in a Ratings Effect for any Tranche of Outstanding DiscoverSeries Notes.
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Additional Fee on Late Payments For any payments thirty (30) calendar days or more overdue under this Agreement, Registry Operator shall pay an additional fee on late payments at the rate of 1.5% per month or, if less, the maximum rate permitted by applicable law.
Eligible Costs II.14.1 Eligible costs of the action are costs actually incurred by a beneficiary, which meet the following criteria: – they are incurred during the duration of the action as specified in Article I.2.2 of the agreement, with the exception of costs relating to final reports and certificates on the action’s financial statements and underlying accounts; – they are connected with the subject of the agreement and they are indicated in the estimated overall budget of the action; – they are necessary for the implementation of the action which is the subject of the grant; – they are identifiable and verifiable, in particular being recorded in the accounting records of a beneficiary and determined according to the applicable accounting standards of the country where the beneficiary is established and according to the usual cost-accounting practices of the beneficiary; – they comply with the requirements of applicable tax and social legislation; – they are reasonable, justified, and comply with the requirements of sound financial management, in particular regarding economy and efficiency. The beneficiaries’ accounting and internal auditing procedures must permit direct reconciliation of the costs and revenue declared in respect of the action with the corresponding accounting statements and supporting documents. II.14.2 The eligible direct costs for the action are those costs which, with due regard for the conditions of eligibility set out in Article II.14.1, are identifiable as specific costs directly linked to the performance of the action and which can therefore be booked to it direct. In particular, the following direct costs are eligible provided that they satisfy the criteria set out in the previous paragraph: – the cost of staff assigned to the action, comprising actual salaries plus social security charges and other statutory costs included in the remuneration, provided that this does not exceed the average rates corresponding to the beneficiary’s usual policy on remuneration. The corresponding salary costs of personnel of national administrations are eligible to the extent that they relate to the cost of activities which the relevant public authority would not carry out if the project concerned were not undertaken; – travel and subsistence allowances for staff taking part in the action, provided that they are in line with the beneficiary’s usual practices on travel costs or do not exceed the scales approved annually by the Commission; – the purchase cost of equipment (new or second-hand), provided that it is written off in accordance with the tax and accounting rules applicable to the beneficiary and generally accepted for items of the same kind. Only the portion of the equipment's depreciation corresponding to the duration of the action and the rate of actual use for the purposes of the action may be taken into account by the Commission, except where the nature and/or the context of its use justifies different treatment by the Commission; – costs of consumables and supplies, provided that they are identifiable and assigned to the action; – costs entailed by other contracts awarded by a beneficiary for the purposes of carrying out the action, provided that the conditions laid down in Article II.9 are met; – costs arising directly from requirements imposed by the agreement (dissemination of information, specific evaluation of the action, audits, translations, reproduction, etc.), including the costs of any financial services (especially the cost of financial guarantees). Such costs may also include specific costs incurred by the co-ordinator for fulfilling his responsibilities in his capability of the body responsible for the overall management of the action and the co-ordination of the beneficiaries. II.14.3 The eligible indirect costs for the action are those costs which, with due regard for the conditions of eligibility described in Article II.14.1, are not identifiable as specific costs directly linked to performance of the action which can be booked to it direct, but which can be identified and justified by the co-ordinator or a co- beneficiary using their accounting system as having been incurred in connection with the eligible direct costs for the action. They may not include any eligible direct costs. By way of derogation from Article II.14.1, the indirect costs incurred in carrying out the action may be eligible for flat-rate funding fixed at not more than 7% of the total eligible direct costs. If provision is made in Article I.4.2 for flat-rate funding in respect of indirect costs, they need not be supported by accounting documents. II.14.4 The following costs shall not be considered eligible: • return on capital; • debt and debt service charges; • provisions for losses or potential future liabilities; • interest owed; • doubtful debts; • exchange losses; • VAT, unless the beneficiary can show that he is unable to recover it according to the applicable national legislation. VAT paid by public bodies is not an eligible cost; • costs declared by a beneficiary and covered by another action or work programme receiving a Union grant; • excessive or reckless expenditure. II.14.5 Contributions in kind shall not constitute eligible costs. However, the Commission can accept, if considered necessary or appropriate, that the co- financing of the action referred to in Article I.4.3 should be made up entirely or in part of contributions in kind. In this case, the value calculated for such contributions must not exceed: • the costs actually borne and duly supported by accounting documents of the third parties who made these contributions to the beneficiary free of charge but bear the corresponding costs; • the costs generally accepted on the market in question for the type of contribution concerned when no costs are borne. Contributions involving buildings shall not be covered by this possibility. In the case of co-financing in kind, a financial value shall be placed on the contributions and the same amount will be included in the costs of the action as ineligible costs and in receipts from the action as co-financing in kind. The beneficiaries shall undertake to obtain these contributions as provided for in the agreement. II.14.6 By way of derogation from paragraph 3, indirect costs shall not be eligible under a grant for an action awarded to a beneficiary who already receives an operating grant from the Commission during the period in question.
Severability; Maximum Payment Amounts If any provision of this Agreement is prohibited by law or otherwise determined to be invalid or unenforceable by a court of competent jurisdiction, the provision that would otherwise be prohibited, invalid or unenforceable shall be deemed amended to apply to the broadest extent that it would be valid and enforceable, and the invalidity or unenforceability of such provision shall not affect the validity of the remaining provisions of this Agreement so long as this Agreement as so modified continues to express, without material change, the original intentions of the parties as to the subject matter hereof and the prohibited nature, invalidity or unenforceability of the provision(s) in question does not substantially impair the respective expectations or reciprocal obligations of the parties or the practical realization of the benefits that would otherwise be conferred upon the parties. The parties will endeavor in good faith negotiations to replace the prohibited, invalid or unenforceable provision(s) with a valid provision(s), the effect of which comes as close as possible to that of the prohibited, invalid or unenforceable provision(s). Notwithstanding anything to the contrary contained in this Agreement or any other Transaction Document (and without implication that the following is required or applicable), it is the intention of the parties that in no event shall amounts and value paid by the Company and/or any of its Subsidiaries (as the case may be), or payable to or received by any of the Buyers, under the Transaction Documents (including without limitation, any amounts that would be characterized as “interest” under applicable law) exceed amounts permitted under any applicable law. Accordingly, if any obligation to pay, payment made to any Buyer, or collection by any Buyer pursuant the Transaction Documents is finally judicially determined to be contrary to any such applicable law, such obligation to pay, payment or collection shall be deemed to have been made by mutual mistake of such Buyer, the Company and its Subsidiaries and such amount shall be deemed to have been adjusted with retroactive effect to the maximum amount or rate of interest, as the case may be, as would not be so prohibited by the applicable law. Such adjustment shall be effected, to the extent necessary, by reducing or refunding, at the option of such Buyer, the amount of interest or any other amounts which would constitute unlawful amounts required to be paid or actually paid to such Buyer under the Transaction Documents. For greater certainty, to the extent that any interest, charges, fees, expenses or other amounts required to be paid to or received by such Buyer under any of the Transaction Documents or related thereto are held to be within the meaning of “interest” or another applicable term to otherwise be violative of applicable law, such amounts shall be pro-rated over the period of time to which they relate.
Allocations During the Early Amortization Period During the Early Amortization Period, an amount equal to the product of (A) the Principal Allocation Percentage and (B) the Series 1997-1 Allocation Percentage and (C) the aggregate amount of Collections of Principal Receivables deposited in the Collection Account on such Deposit Date, shall be allocated to the Series 1997-1 Certificateholders and retained in the Collection Account until applied as provided herein; provided, however, that after the date on which an amount of such Collections equal to the Adjusted Invested Amount has been deposited into the Collection Account and allocated to the Series 1997-1 Certificateholders, such amount shall be first, if any other Principal Sharing Series is outstanding and in its amortization period or accumulation period, retained in the Collection Account for application, to the extent necessary, as Shared Principal Collections on the related Distribution Date, and second paid to the Holders of the Transferor Certificates only if the Transferor Amount on such date is greater than the Required Transferor Amount (after giving effect to all Principal Receivables transferred to the Trust on such day) and otherwise shall be deposited in the Special Funding Account.
Returned Payment Fee If your account is subject to a Returned Payment Fee, the fee will be charged to your account when a payment is returned for any reason.
Payment of Settlement Amount (1) Within thirty (30) days of the Execution Date, the Settling Defendants shall pay the Settlement Amount to Siskinds LLP for deposit into the Trust Account. The Settlement Amount shall be converted into Canadian currency upon deposit into the Trust Account. (2) The Settling Defendants shall deposit the Settlement Amount into the Trust Account by wire transfer. Siskinds LLP shall provide the necessary wire transfer information to Counsel for the Settling Defendants with reasonable advance notice so that the Settling Defendants have a reasonable period of time to comply with section 3.1(1) of this Settlement Agreement. (3) The Settlement Amount and other consideration to be provided in accordance with the terms of this Settlement Agreement shall be provided in full satisfaction of the Released Claims against the Releasees. (4) The Settlement Amount shall be all-inclusive of all amounts, including without limitation, interest, costs, Class Counsel Fees and Class Counsel Disbursements. (5) The Releasees shall have no obligation to pay any amount in addition to the Settlement Amount, for any reason, pursuant to or in furtherance of this Settlement Agreement or the Proceedings or any Other Actions. (6) Once a Claims Administrator has been appointed, Siskinds LLP shall transfer control of the Trust Account to the Claims Administrator. (7) Siskinds LLP and the Claims Administrator shall maintain the Trust Account as provided for in this Settlement Agreement. While in control of the Trust Account, Siskinds LLP and the Claims Administrator shall not pay out all or part of the monies in the Trust Account, except in accordance with this Settlement Agreement, or in accordance with an order of the Courts obtained after notice to the Parties.
