HOLD HARMLESS AGREEMENT Concessionaire hereby waives all claims and recourse against the State, including the right to contribution for loss or damage to persons or property arising from, growing out of, or in any way connected with or incident to this Contract, except claims arising from, and to the extent of, the sole gross negligence or willful misconduct of the State, its officers, agents, or employees. Concessionaire shall protect, indemnify, hold harmless, and defend State, its officers, agents, and employees against any and all claims, demands, damages, costs, expenses, attorney fees, expert costs and fees, or liability costs arising out of the development, construction, operation, or maintenance of the Premises property described herein and compliance with all laws, including but not limited to the Americans With Disabilities Act of 1990 as provided for herein, except for liability arising out of, and to the extent of, the sole gross negligence or willful misconduct of State, its officers, agents, or employees or other wrongful acts for which the State is found liable by a court of competent jurisdiction.
Ownership and License in Deliverables Unless otherwise specified in a specific Purchase Order concerning procurement of a SaaS product:
INDEMNIFICATION AND HOLD HARMLESS AGREEMENT With respect to any liability, including but not limited to claims asserted or costs, losses, or payments for injury to any person or property caused or claimed to be caused by the acts or omissions of the Consultant, or Consultant's employees, agents, and officers, arising out of any services performed under this Agreement, the Consultant agrees to defend, indemnify, protect, and hold harmless the City, its agents, officers, and employees from and against all liability. Also covered is liability arising from, connected with, caused by, or claimed to be caused by the passive negligent acts or omissions of the City, its agents, officers, or employees which may be in combination with the active or passive negligent acts or omissions of the Consultant, its employees, agents or officers, or any third party. The Consultant's duty to defend, indemnify, protect and hold harmless shall not include any claims or liabilities arising from the active or sole negligence or sole willful misconduct of the City, its agents, officers or employees.
HOLD HARMLESS AND INDEMNIFICATION AGREEMENT The CONTRACTOR hereby agrees to protect, defend, indemnify, and hold PLACER COUNTY free and harmless from any and all losses, claims, liens, demands, and causes of action of every kind and character including, but not limited to, the amounts of judgments, penalties, interest, court costs, legal fees, and all other expenses incurred by PLACER COUNTY arising in favor of any party, including claims, liens, debts, personal injuries, death, or damages to property (including employees or property of the COUNTY) and without limitation by enumeration, all other claims or demands of every character occurring or in any way incident to, in connection with or arising directly or indirectly out of, the contract or agreement. CONTRACTOR agrees to investigate, handle, respond to, provide defense for, and defend any such claims, demand, or suit at the sole expense of the CONTRACTOR. CONTRACTOR also agrees to bear all other costs and expenses related thereto, even if the claim or claims alleged are groundless, false, or fraudulent. This provision is not intended to create any cause of action in favor of any third party against CONTRACTOR or the COUNTY or to enlarge in any way the CONTRACTOR'S liability but is intended solely to provide for indemnification of PLACER COUNTY from liability for damages or injuries to third persons or property arising from CONTRACTOR'S performance pursuant to this contract or agreement. As used above, the term PLACER COUNTY means Placer County or its officers, agents, employees, and volunteers.
Indemnification by Licensee Licensee shall defend, indemnify and hold harmless Licensor and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensor Parties”) from and against any Action, and any and all direct losses suffered or incurred by Licensor in connection with any third party claims (a) arising out of or resulting from any breach by Licensee of any provision of this Agreement, (b) regarding the Content (other than Licensed Content) of the websites associated with Licensed Domain Names, or (c) regarding any Content that was subject to a request for removal by a Governmental Authority, even if Licensee removes such Content within the time period proscribed by the Governmental Authority, provided that, in all cases, Licensee shall not be liable for any direct losses suffered or incurred by Licensor as a result of Licensor’s failure to provide Licensee with a reasonable period of time to remove Content in cases where (i) the basis or nature of the offense has not previously been identified by any Governmental Authority as offensive or inappropriate and (ii) Licensee has not also received notice from the Governmental Authority. Licensee’s obligation to indemnify Licensor shall be conditioned on (x) Licensor’s provision to Licensee of prompt notice of such an Action (except where any delay does not materially prejudice Licensee); (y) Licensor’s reasonable cooperation with Licensee in the defense and settlement of such an Action at Licensee’s cost; and (z) Licensee having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensee may not settle any Action in a manner that adversely affects Licensor without Licensor’s prior written consent, not to be unreasonably withheld or delayed).
Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.
INDEMNIFICATION RELATING TO THIRD PARTY RIGHTS The Contractor will also indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs that may be finally assessed against the Authorized Users in any action for infringement of a United States Letter Patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims arise from the Authorized Users gross negligence or willful misconduct, provided that the State shall give Contractor: (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. If usage shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue Usage (ii) to modify the service or Product so that Usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace said service or Product or part(s) thereof, as applicable, with non-infringing service or Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided the Authorized User is given a refund for any amounts paid for the period during which Usage was not feasible. The foregoing provisions as to protection from third party rights shall not apply to any infringement occasioned by modification by the Authorized User of any Product without Contractor’s approval. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the service or Product under the Contract infringes any patent, copyright or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract. Contractor shall in such event protect the interests of the Authorized User and secure a continuance to permit the Authorized User to appear and defend its interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
License Fees If so provided in the Prospectus, the Depositor may enter into a Licensing Agreement (the "Agreement") with a licensor (the "Licensor") described in the Prospectus in which the Trust(s), as consideration for the licenses granted by the Licensor for the right to use its trademarks and trade names, intellectual property rights or for the use of databases and research owned by the Licensor, will pay a fee set forth in the Agreement to the applicable Licensor or the Depositor to reimburse the Depositor for payment of the expenses. If the Agreement provides for an annual license fee computed in whole or part by reference to the average daily net asset value of the Trust assets, for purpose of calculating the accrual of estimated expenses such annual fee shall accrue at a daily rate and the Trustee is authorized to compute an estimated license fee payment (i) until the Depositor has informed the Trustee that there will be no further deposits of additional Securities, by reference to an estimate of the average daily net asset value of the Trust assets which the Depositor shall provide the Trustee, (ii) thereafter and during the calendar quarter in which the last business day of the period described in clause (i) occurs, by reference to the net asset value of the Trust assets as of such last business day, and (iii) during each subsequent calendar quarter, by reference to the net asset value of the Trust assets as of the last business day of the preceding calendar quarter. The Trustee shall adjust the net asset value (Trust Fund Evaluation) as of the dates specified in the preceding sentence to account for any variation between accrual of estimated license fee and the license fee payable pursuant to the Agreement, but such adjustment shall not affect calculations made prior thereto and no adjustment shall be made in respect thereof.
WAIVER OF LIABILITY, ASSUMPTION OF RISK, AND INDEMNITY AGREEMENT I, , IN CONSIDERATION of being permitted to participate in any way in the Rocky Mountain Cycling Club 200 km brevet calendared for October 8, 2022 (“Activity”), I hereby acknowledge, agree, attest and represent the following:
Licensee Indemnification Licensee will indemnify, defend and hold harmless UM, its trustees, officers, agents and employees (collectively, the “Indemnified Parties”), from and against any and all liability, loss, damage, action, claim or expense suffered or incurred by the Indemnified Parties which results from or arises out of third party claims in connection with (individually, a “Liability” and collectively, the “Liabilities”):
