Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.
Indemnity Obligations An Indemnified Party seeking indemnification under this Agreement must notify Customer promptly of any event requiring indemnification. However, an Indemnified Party’s failure to notify will not relieve Customer from its indemnification obligations, except to the extent that the failure to notify materially prejudices Customer. Customer may assume the defense of any proceeding requiring indemnification unless assuming the defense would result in potential conflicting interests as determined by the Indemnified Party in good faith. An Indemnified Party may, at Customer’s expense, defend itself until Customer’s counsel has initiated a defense of the Indemnified Party. Even after Customer assumes the defense, the Indemnified Party may participate in any proceeding using counsel of its own choice and at its own expense. Customer may not settle any proceeding related to this Agreement unless the settlement also includes an unconditional release of liability for all Indemnified Parties. Customer’s indemnification obligations are not the sole remedy for Customer’s breach of this Agreement and are in addition to any other remedies available. Customer’s indemnification obligations hereunder are not an Indemnified Party’s sole remedy for events giving rise to indemnity by Customer hereunder, and are in addition to any other remedies an Indemnified Party may have against Customer under this Agreement.
Accountholder’s Indemnification Obligation You understand and agree that you are required to indemnify us and hold us harmless against any and all claims, actions, damages, liabilities, costs and expenses, including reasonable attorneys’ fees and expenses, arising out of your use of the Services and/or breach of this Agreement. You understand and agree that this paragraph shall survive termination of this Agreement.
Claims Payment The Reinsurer will be liable to the Company for its share of the benefits owed under the express contractual terms of the Reinsured Policies and as specified under the terms of this Agreement. The Reinsurer will not participate in any ex gratia payments made by the Company (i.e., payments the Company is not required to make under the Reinsured Policy terms.) The payment of death benefits by the Reinsurer will be in one lump sum regardless of the mode of settlement under the Reinsured Policy. Benefit payments from the Reinsurer will be due within 30 days of the claim satisfying the requirements established under this Agreement. The Reinsurer’s share of any interest payable under the terms of a Reinsured Policy or applicable law which is based on the death benefits paid by the Company, will be payable provided that the Reinsurer will not be liable for interest accruing on or after the date of the Company’s payment of benefits. The Reinsurer will make payment to the Company for each such claim. For Waiver of Premium claims, the Company will continue to pay premiums for reinsurance, except premiums for disability reinsurance. The Reinsurer will pay its proportionate share of the gross premium waived by the Company on the Reinsured Policy, including its share of the premiums for benefits that remain in effect during disability. For claims on Accelerated Benefit riders reinsured under this Agreement, the benefit amount payable by the Reinsurer will be calculated by multiplying the total accelerated death benefit rider payout by the ratio of the reinsured Net Amount at Risk, as defined in Exhibit C-1, to the face amount of the Reinsured Policy.
Expenses Indemnity Damage Waiver (a) The Borrower shall pay (i) all reasonable out-of-pocket expenses incurred by the Administrative Agent and its Affiliates, including the reasonable fees, charges and disbursements of counsel for the Administrative Agent, in connection with the syndication and distribution (including, without limitation, via the internet or through a service such as Intralinks) of the credit facilities provided for herein, the preparation and administration of this Agreement and the other Loan Documents or any amendments, modifications or waivers of the provisions hereof or thereof (whether or not the transactions contemplated hereby or thereby shall be consummated), (ii) all reasonable out-of-pocket expenses incurred by the Issuing Bank in connection with the issuance, amendment, renewal or extension of any Letter of Credit or any demand for payment thereunder and (iii) all out-of-pocket expenses incurred by the Administrative Agent, the Issuing Bank or any Lender, including the fees, charges and disbursements of any counsel for the Administrative Agent, the Issuing Bank or any Lender, in connection with the enforcement or protection of its rights in connection with this Agreement and any other Loan Document, including its rights under this Section, or in connection with the Loans made or Letters of Credit issued hereunder, including all such out-of-pocket expenses incurred during any workout, restructuring or negotiations in respect of such Loans or Letters of Credit.
Indemnifiable Losses 14.3.1 Where an Indemnified Party is entitled to Indemnifiable Losses from the Indemnifying Party pursuant to Article 14.1.1(b) or 14.1.2(b), the Indemnified Party shall promptly notify the Indemnifying Party of the Indemnifiable Losses actually incurred by the Indemnified Party. The Indemnifiable Losses shall be reimbursed by the Indemnifying Party within thirty (30) days of receipt of the notice seeking Indemnifiable Losses by the Indemnified Party. In case of nonpayment of such losses after a valid notice under this Article 14.3, such event shall constitute a payment default under Article 13.
Your Indemnity Obligations You hereby agree to indemnify, defend and hold Provider harmless from and against any and a l liability, losses, costs, and expenses (including attorneys’ fees) incurred by Provider, or any one of them, in connection with any claim, arising out of your use of the O ferings, Your Content, any violation of this XXXX, including any supplemental term, and/or your violation of the rights of any other party, including the Provider, or any one of them. Notwithstanding the foregoing, we may assume the defense and control of any indemnifiable claim, for which you agree to provide your cooperation and to assume the costs thereof.
Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.
Infringement Indemnification If notified promptly in writing of any judicial action brought against City based on an allegation that City’s use of the Licensed Software infringes a patent, copyright, or any right of a third party or constitutes misuse or misappropriation of a trade secret or any other right in intellectual property (Infringement), Contractor will hold City harmless and defend such action at its own expense. Contractor will pay the costs and damages awarded in any such action or the cost of settling such action, provided that Contractor shall have sole control of the defense of any such action and all negotiations or its settlement or compromise. If notified promptly in writing of any informal claim (other than a judicial action) brought against City based on an allegation that City’s use of the Licensed Software constitutes Infringement, Contractor will pay the costs associated with resolving such claim and will pay the settlement amount (if any), provided that Contractor shall have sole control of the resolution of any such claim and all negotiations for its settlement. In the event a final injunction is obtained against City’s use of the Licensed Software by reason of Infringement, or in Contractor’s opinion City’s use of the Licensed Software is likely to become the subject of Infringement, Contractor may at its option and expense: (a) procure for City the right to continue to use the Licensed Software as contemplated hereunder, (b) replace the Licensed Software with a non-infringing, functionally equivalent substitute Licensed Software, or (c) suitably modify the Licensed Software to make its use hereunder non-infringing while retaining functional equivalency to the unmodified version of the Licensed Software. If none of these options is reasonably available to Contractor, then the Agreement may be terminated at the option of either Party hereto and Contractor shall refund to City all amounts paid under this Agreement for the license of such infringing Licensed Software. Any unauthorized modification or attempted modification of the Licensed Software by City or any failure by City to implement any improvements or updates to the Licensed Software, as supplied by Contractor, shall void this indemnity unless City has obtained prior written authorization from Contractor permitting such modification, attempted modification or failure to implement. Contractor shall have no liability for any claim of Infringement based on City’s use or combination of the Licensed Software with products or data of the type for which the Licensed Software was neither designed nor intended to be used.
Self-Insured Retention/Deductibles Certificates of Insurance must indicate the applicable deductibles/self-insured retentions for each listed policy. Deductibles or self-insured retentions above $100,000.00 are subject to approval from OGS. Such approval shall not be unreasonably withheld, conditioned or delayed. The Contractor shall be solely responsible for all claim expenses and loss payments within the deductibles or self-insured retentions. If the Contractor is providing the required insurance through self-insurance, evidence of the financial capacity to support the self-insurance program along with a description of that program, including, but not limited to, information regarding the use of a third-party administrator shall be provided upon request.
