Perform to Schedule Sample Clauses

Perform to Schedule. (a) The Parties shall adhere to the schedule of milestones set forth in Annex 6.1 or to any amendment or replacement thereof as well as to the schedule of milestones set forth in each Order Document (each, as applicable, the "TIME SCHEDULE") for performance of their respective responsibilities set forth in the Responsibility Matrix and shall use reasonable commercial efforts to minimize all delays. Except as specifically provided herein, in no event shall the date for any Provisional Acceptance specified on the version of the Time Schedule attached hereto as Annex 6.1 be changed in any version/revision of the Time Schedule accompanying any Order Document without the consent of both Parties. Notwithstanding the foregoing, Supplier shall not be in breach of its obligations with respect to any milestone on the Time Schedule nor be responsible for any Megatel Delays or other delays or damages to the extent that such delays or damages arise from Megatel Delays or directly from the exercise by Megatel of any discretionary right under this Agreement (other than as provided in Section 9.3(h)) in a manner that impedes, prevents or burdens Supplier's ability to conform to the Time Schedule. In the event that Megatel's exercise of such rights unduly impedes, prevents, or burdens Supplier's ability to conform to the Time Schedule, then the time of performance of any of Supplier's obligations hereunder, including the obligation to meet each of the milestones under the Time Schedule, shall be extended by a mutually agreed upon length of time but in no event less than the actual time of delay caused by such event, unless the Parties otherwise agree. (b) The Time Schedule (which, unless otherwise agreed, shall be created using "Microsoft Project" software) will indicate the relevant time periods for the engineering, manufacture, shipment, Delivery and receipt of the Equipment and the provision of the Installation, testing, Commissioning, Provisional Acceptance, Final Acceptance and all other Services.
Sample 1
AutoNDA by SimpleDocs
Perform to Schedule. Telemig Celular shall negotiate in good faith the Implementation Schedule for each Phase and shall adhere to the Implementation Schedule for performance of its responsibilities set forth therein and use reasonable efforts to minimize all delays.
Sample 1
Perform to Schedule. XXXXXX shall adhere to the schedule for the performance of its responsibilities set forth herein, except as impacted by TELIGENT's failure to adhere to the schedule for performing TELIGENT's responsibilities hereunder.
Sample 1
Perform to Schedule. Nortel shall negotiate in good faith the Implementation Schedule and adhere to the Implementation Schedule for performance of its responsibilities set forth therein.
Sample 1

Related to Perform to Schedule

  • Updates to Schedules Should any of the information or disclosures provided on any of the Schedules attached hereto become outdated or incorrect in any material respect, the Borrower shall promptly provide the Agent in writing with such revisions or updates to such Schedule as may be necessary or appropriate to update or correct same; provided, however, that no Schedule shall be deemed to have been amended, modified or superseded by any such correction or update, nor shall any breach of warranty or representation resulting from the inaccuracy or incompleteness of any such Schedule be deemed to have been cured thereby, unless and until the Required Banks, in their sole and absolute discretion, shall have accepted in writing such revisions or updates to such Schedule.

  • Supplements to Schedules Pending Closing, Seller may supplement or correct the Schedules to this Agreement as necessary to insure their completeness and accuracy. No supplement or correction to any Schedule or Schedules to this Agreement shall be effective, however, to cure any breach or inaccuracy in any of the representations and warranties; but if TJC does not exercise its right to terminate this Agreement under Section 12 and closes the transaction, the supplement or correction shall constitute an amendment of the Schedule or Schedules to which it relates for all purposes of this Agreement.

  • Amendments to Schedules The Schedules to this Agreement form an integral part of this Agreement. The Schedules may be amended or replaced from time to time by the parties who will evidence their approval thereof by initialing a new Schedule dated as of the effective date of such amendment or replacements.

  • Amendment to Schedule The Grantor authorizes the Collateral Agent to modify this Agreement and the Assignments of Trademarks, without the necessity of such Grantor’s further approval or signature, by amending Schedule A hereto and the Annex to each Assignment of Trademarks to include any future or other Trademarks, Trademark Licenses, Trade Secrets or Trade Secret Licenses that become part of the Trademark Collateral under Section 2 or Section 3.1.

  • Amendment to Schedules Schedule 2.01 of the Credit Agreement shall be and it hereby is amended in its entirety by substituting Schedule 2.01 attached hereto.

  • Payments to Subcontractors Develop and implement a procedure for the review, processing and payment of applications by subcontractors for progress and final payments.

  • APPLICABILITY TO SUBCONTRACTORS Respondent agrees that all contracts it awards pursuant to the contract awarded as a result of this Agreement will be bound by the foregoing terms and conditions.

  • Changes to Specifications All Specifications and any changes thereto agreed to by the parties from time to time shall be in writing, dated and signed by the parties. Any change to the Process shall be deemed a Specification change. No change in the Specifications shall be implemented by Catalent, whether requested by Client or requested or required by any Regulatory Authority, until the parties have agreed in writing to such change, the implementation date of such change, and any increase or decrease in costs, expenses or fees associated with such change (including any change to Unit Pricing). Catalent shall respond promptly to any request made by Client for a change in the Specifications, and both parties shall use commercially reasonable, good faith efforts to agree to the terms of such change in a timely manner. As soon as possible after a request is made for any change in Specifications, Catalent shall notify Client of the costs associated with such change and shall provide such supporting documentation as Client may reasonably require. Client shall pay all costs associated with such agreed upon changes. If there is a conflict between the terms of this Agreement and the terms of the Specifications, this Agreement shall control. Catalent reserves the right to postpone effecting changes to the Specifications until such time as the parties agree to and execute the required written amendment.

  • Annexes, Appendices and Footnotes The annexes, appendices and footnotes to this Agreement constitute an integral part of this Agreement.

  • Amendments to Schedule of Receivables If the Servicer, during a Collection Period, assigns to a Receivable an account number that differs from the original account number identifying such Receivable on the Schedule of Receivables, the Servicer shall deliver to the Issuer, the Owner Trustee and the Indenture Trustee, on or before the Payment Date relating to such Collection Period, an amendment to the Schedule of Receivables reporting the newly assigned account number, together with the old account number of each such Receivable. The first such delivery of amendments to the Schedule of Receivables shall include monthly amendments reporting account numbers appearing on the Schedule of Receivables with the new account numbers assigned to such Receivables during any prior Collection Period.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!