Performance Security 47.1 Within twenty-one (21) days of the receipt of Letter of Acceptance from the Procuring Entity, the successful Tenderer, if required, shall furnish the Performance Security in accordance with the GCC 18, using for that purpose the Performance Security Form included in Section X, Contract Forms. If the Performance Security furnished by the successful Tenderer is in the form of a bond, it shall be issued by a bonding or insurance company that has been determined by the successful Tenderer to be acceptable to the Procuring Entity. A foreign institution providing a bond shall have a correspondent financial institution located in Kenya, unless the Procuring Entity has agreed in writing that a correspondent financial institution is not required.
47.2 Failure of the successful Tenderer to submit the above-mentioned Performance Security or sign the Contract shall constitute sufficient grounds for the annulment of the award and forfeiture of the Tender Security. In that event the Procuring Entity may award the Contract to the Tenderer offering the next lowest Evaluated Tender.
47.3 Performance security shall not be required for a contract, if so specified in the TDS.
Performance Bonds Buyer shall have obtained, or caused to be obtained, in the name of Buyer, replacements for Seller’s and/or Seller’s Affiliates’ bonds, letters of credit and guarantees, and such other bonds, letters of credit and guarantees to the extent required by Section 7.05.
Appropriation of Performance Security (i) Upon occurrence of a Contractor’s Default, the Authority shall, without prejudice to its other rights and remedies hereunder or in law, be entitled to encash and appropriate the relevant amounts from the Performance Security as Damages for such Contractor’s Default.
(ii) Upon such encashment and appropriation from the Performance Security, the Contractor shall, within 30 (thirty) days thereof, replenish, in case of partial appropriation, to its original level the Performance Security, and in case of appropriation of the entire Performance Security provide a fresh Performance Security, as the case may be, and the Contractor shall, within the time so granted, replenish or furnish fresh Performance Security as aforesaid failing which the Authority shall be entitled to terminate the Agreement in accordance with Article 23. Upon replenishment or furnishing of a fresh Performance Security, as the case may be, as aforesaid, the Contractor shall be entitled to an additional Cure Period of 30 (thirty) days for remedying the Contractor’s Default, and in the event of the Contractor not curing its default within such Cure Period, the Authority shall be entitled to encash and appropriate such Performance Security as Damages, and to terminate this Agreement in accordance with Article 23.
Release of Performance Security (i) The Authority shall return the Performance Security to the Contractor within 60 (sixty) days of the expiry of the Maintenance Period or the Defects Liability Period, whichever is later, under this Agreement. Notwithstanding the aforesaid, the Parties agree that the Authority shall not be obliged to release the Performance Security until all Defects identified during the Defects Liability Period have been rectified.
(ii) The Authority shall return the Additional Performance Security to the Contractor within 28 (twenty eight) days from the date of issue of Completion Certificate under Article 12 of this Agreement.
(iii) The Authority shall be liable to pay interest @ 9% (nine per cent) per annum for any delay in the return of Performance Security and Additional Performance Security, if any, beyond the period prescribed above for the period of delay.
Performance Assurance Seller agrees to deliver to Buyer Performance Assurance in a form acceptable to Buyer to secure its obligations under this Agreement, which Performance Assurance Seller shall maintain in full force and effect for the period posted with Buyer, as follows:
Performance Bond Unless otherwise prohibited by law, the Department may require the Contractor to furnish, without additional cost to the Department, a performance bond or irrevocable letter of credit or other form of security for the satisfactory performance of work hereunder. The Department shall determine the type and amount of security.
Performance Condition Notwithstanding the vesting schedule stated in the Award Notification, your Restricted Stock Units shall not vest unless the Company achieves positive Adjusted Net Earnings in any fiscal year during the term of the Award. “Adjusted Net Earnings” means net earnings determined in accordance with GAAP as publicly reported by the Company for a fiscal year, adjusted to eliminate the following: (1) the cumulative effect of changes in GAAP; (2) gains and losses from discontinued operations; (3) extraordinary gains or losses; and (4) any other unusual or nonrecurring gains or losses which are separately identified and quantified, including merger related charges.
Performance Requirements A. There is no guaranteed minimum amount of work which will be ordered under this Contract.
B. The total Contract amount will not exceed $4,900,000.
C. This is a Contract for work specified in individual Job Orders. Work ordered prior to but not completed by the expiration of the Contract period, and any additional work required as a result of unforeseen conditions encountered during construction up to six (6) months after the contract expiration date, will be completed with all provisions of this Contract still in force. Performance time for each Job Order issued under this Contract will be determined in accordance with the Contract. This performance time will be determined and agreed upon by both Parties for each individual Job Order. Contractor must self-perform 20% of the Work under this Contract for ‘A’ and ‘B’ licenses. Contractor must self-perform 75% of the Work under this Contract, unless otherwise approved by the County, for ‘C’ licenses.
D. This is an indefinite-quantity Contract for the supplies or services specified and effective for the period stated. Work or performance shall be made only as authorized by Job Orders issued in accordance with the ordering procedures clause. The Contractor agrees to furnish to the County when and if ordered, the supplies or services specified in the Contract up to and including the quantity designated in the Job Orders issued as the maximum designated in the Contract.
Site Security While providing services at a DSHS location, the Contractor, its agents, employees, or Subcontractors shall conform in all respects with physical, fire, or other security regulations specific to the DSHS location.
Performance Conditions The Shares shall be issuable only if (and to the extent) that the Performance Criteria, set forth herein, are satisfied during the Performance Period. The Controller of the Company and the Compensation Committee of the Board of Directors of the Company shall certify whether, and to what extent, the Performance Criteria have been achieved. If the minimum performance is not met, no Shares shall be issued and the Award shall be forfeited.
