Periodic Progress Reports. Contractor shall furnish to Owner periodic progress reports on the Work of this Project as mutually agreed but not less than monthly, including information on the status of materials and equipment which may be in the course of preparation, manufacture or transit.
Periodic Progress Reports. Demolition Contractor shall furnish to Owner periodic progress reports on the Demolition Work of this Demolition Project as mutually agreed but not less than weekly.
Periodic Progress Reports. ETRX shall provide periodic progress reports as agreed in any applicable Delivery Order accepted by ETRX.
Periodic Progress Reports. During the Remediation Phase, Credit Union will provide Claimants’ Counsel a brief progress report in letter format every four (4) months commencing as of October 31, 2016 until the Web Accessibility Consultant confirms that the Remediation Plan is complete pursuant to Section 3.3.4. Each Periodic Progress Reports shall contain the following information:
(a) Work that has been completed (since the last report),
(b) Work that is anticipated to be completed (before the next report),
(c) Problems or bugs that create nonconformance with WCAG 2.0 AA that Credit Union has encountered and whether they affect the Remediation Timeline or completion of the Remediation Plan,
(d) The tentative date of completion of the Remediation Plan (but only if the timeline has changed from the date of the prior progress report),
(e) A statement from the Web Accessibility Consultant regarding the results and recommendations of the periodic testing pursuant to section 3.2.1(c). In the event any progress report provided pursuant to this Section 3.3.2 identified problems or bugs that create nonconformance with WCAG 2.0 AA in the Website, the online banking services or related mobile applications, the Parties agree that Credit Union and Q2, if applicable, will cause said problems or bugs to be remedied with the same level of priority (e.g., speed, resources used to remediate) as any other equivalent loss of function for individuals without disabilities.
Periodic Progress Reports. TRX shall provide periodic progress reports as required in any applicable Delivery Order.
Periodic Progress Reports. (JUL 1998) (CONTRACT INFORMATION BULLETIN [CIB] 98-21, ISSUED AUGUST 12, 1998)
(a) The contractor shall prepare and submit progress reports as specified in the Schedule of this contract. These reports are separate from the interim and final performance evaluation reports prepared by USAID in accordance with (48 CFR) FAR 42.15 and internal Agency procedures, but they may be used by USAID personnel or their authorized representatives when evaluating the contractor's performance.
(b) During any delay in furnishing a progress report required under this contract, the contracting officer may withhold from payment an amount not to exceed US$25,000 (or local currency equivalent) or 5 percent of the amount of this contract, whichever is less, until such time as the contracting officer determines that the delay no longer has a detrimental effect on the Government's ability to monitor the contractor's progress.
Periodic Progress Reports. 4.2.1 TDT shall provide periodic progress reports as agreed and assigned in any Delivery Order.
Periodic Progress Reports. CDC shall provide to USAID, in form and substance satisfactory to USAID, bi-annual reports on progress toward achieving Program objectives and implementing approved workplans. These reports are due April 30 (mid-year) and October 31 (annual report) of each year. These reports shall include, but not be limited to, the following information: status of achieving goals, objectives and benchmarks specified in the annual workplan; progress or completion of components, elements or activities against planned targets; description of overall Program status, other accomplishments and major highlights of Program implementation; identification and explanation of significant problems or delays related to achievement of objectives or activities; a brief summary of significant corrective actions and major activities planned for the subsequent reporting period. The mid-year and annual reports should be 2-3 pages in length for each activity (see Annex A). A proposed format is provided in Attachment 2. Additional information or important documents developed as part of the activity can be attached to the reporting form. USAID and CDC may negotiate more comprehensive reporting requirements for specific activities. If more comprehensive reporting requirements are negotiated that report should be submitted in lieu of the proposed format to avoid duplicate reporting. For USAID Mission-funded activities, CDC should submit reports directly to the appropriate USAID Mission. In accordance with E.2 above, CDC shall also submit to USAID on a quarterly basis a financial report that includes budget information, 08/18/2006 disaggregated by budget category, on accrued expenditures, commitments, and disbursements of funds provided under this Agreement. CDC must use the categories of obligations and expenditures set forth in Annex B of this agreement.
Periodic Progress Reports. Construction Manager shall submit to the Architect information to allow the Architect to prepare its periodic progress reports to the Owner. Such information must include key events, changes, and performance relative to schedule and budget.
Periodic Progress Reports. Developer shall provide periodic progress reports as agreed in any applicable Delivery Order accepted by Developer.
