Insignificant Changes No adjustment in the Purchase Price shall be required unless such adjustment would require an increase or decrease of at least 1% in the Purchase Price. Any adjustments which by reason of this Section 11.5 are not required to be made shall be carried forward and taken into account in any subsequent adjustment. All calculations under this Section 11 shall be made to the nearest cent or to the nearest one-hundred thousandth of a Preferred Share or the nearest one-hundredth of a Common Share or other share or security, as the case may be.
Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Residence Life or the Director’s designee.
Project Changes 1.8.1. All changes shall be administered per the UGC.
1.8.2. Upon authorization by the Owner, the Owner or Architect/Engineer will prepare and issue all changes to the Contract affecting cost, scope and/or time as a formal Change Order to the Contract on the standard University of Texas MD Xxxxxxxx Cancer Center Change Order form. The Change Order may include separate change issues, identified as Change Proposals and field orders.
1.8.3. Upon authorization by the Owner, Change Proposals may be issued to the Architect/Engineer for pricing by the Contractor. Contractor shall submit pricing to the Owner within twenty-one (21) days and pricing shall be indicated on the standard Owner "Change in Work Cost Analysis" ("Cost Analysis") form provided in the Pre-Construction Conference Brochure. Contractor may not include a Change Proposal within a Change Order unless the Owner has accepted the Change Proposal.
1.8.3.1. The Contractor shall summarize all costs for each change at each level of subcontractor and supplier by preparing the "Cost Analysis" form, and shall provide each subcontractor's cost summary on separate "Cost Analysis" forms as backup. Additional support documentation from both the Contractor and Contractor’s subcontractors is encouraged, but such will not replace use of the standard form.
1.8.3.2. When the Contractor believes it is entitled to a time extension, Contractor shall so state as part of Contractor’s response to the Change Proposal, including a justifica- tion for a time extension. Owner may grant time extensions only if a Change Proposal affects the activities on the Longest Path of an Owner approved Work Progress Schedule; i.e., when the Work impacts the "Contract Substantial Completion Date".
1.8.3.3. If the Owner’s Project Manager and Contractor cannot mutually agree upon a fair and reasonable cost and time settlement, the Owner’s Project Manager may: 1) Reject the quotation and void the Change Proposal, 2) Issue instructions to the Contractor to proceed on a time and material basis for a price to be determined later not to exceed a fixed maximum dollar and time, or 3) Issue a Unilateral Change Order.
1.8.3.4. The Owner’s Construction Inspector and/or Owner’s Project Manager may issue field orders directly to the Contractor for minor changes to the Contract, which can be negotiated in the field. Pricing backup is at the discretion of the Owner’s Construction Inspector, but pricing backup is required for any field order, the pricing backup is to be outlined on the "Cost Analysis" form. When the Owner and Contractor have signed the field order, the Work is authorized and the field order may be included in the next Change Order.
1.8.4. Request for payment for Change Order work may be submitted only after the Change Order has been fully executed.
Undue Burden and Fundamental Alteration For any technology-related requirement in this Agreement for which the Recipient asserts an undue burden or fundamental alteration defense, such assertion may only be made by the Superintendent or by an individual designated by the Superintendent and who has budgetary authority after considering all resources available for use in the funding and operation of the service, program, or activity, and must be accompanied by a written statement of the reasons for reaching that conclusion, including the cost of meeting the requirement and the available funding and other resources. The written statement will be certified by the determining official. If such a determination is made, the certifying official will describe in the written statement how it will provide equally effective alternate access, i.e., other action that would not result in such an alteration or such burdens but would nevertheless ensure that, to the maximum extent possible, individuals with disabilities receive the same benefits or services provided by the Recipient as their nondisabled peers.
Benchmark Replacement Conforming Changes In connection with the use, administration, adoption or implementation of a Benchmark Replacement, the Administrative Agent will have the right to make Conforming Changes from time to time and, notwithstanding anything to the contrary herein or in any other Loan Document, any amendments implementing such Conforming Changes will become effective without any further action or consent of any other party to this Agreement or any other Loan Document.
Common Areas - Changes Lessor shall have the right, in Lessor's sole discretion, from time to time:
(a) To make changes to the Common Areas, including, without limitation, changes in the location, size, shape and number of driveways, entrances, parking spaces, parking areas, loading and unloading areas, ingress, egress, direction of traffic, landscaped areas, walkways and utility raceways;
(b) To close temporarily any of the Common Areas for maintenance purposes so long as reasonable access to the Premises remains available;
(c) To designate other land outside the boundaries of the Industrial Center to be a part of the Common Areas;
(d) To add additional buildings and improvements to the Common Areas;
(e) To use the Common Areas while engaged in making additional improvements, repairs or alterations to the Industrial Center, or any portion thereof; and
(f) To do and perform such other acts and make such other changes in, to or with respect to the Common Areas and Industrial Center as Lessor may, in the exercise of sound business judgment, deem to be appropriate.
Improvements and Alterations (a) The Lessee, at the Lessee’s own cost and expense, (i) shall make alterations, renovations, repairs, improvements and additions to the Leased Property or any part thereof and substitutions and replacements therefor (collectively, “Alterations”) which are (A) necessary to repair or maintain the Improvements or the Site in the condition required by Section 9.1 or (B) necessary or advisable to restore the Improvements and the Site to its condition existing prior to a Casualty or Condemnation to the extent required pursuant to Article XIII, and (ii) so long as no Material Default or Event of Default has occurred and is continuing, may undertake Alterations on the Leased Property so long as such Alterations comply in all material respects with Applicable Laws and are consistent and comply with Section 9.1 and subsection (b) of this Section 9.2.
(b) The making of any Alterations pursuant to subsection (a)(i) above of this Section 9.2 must be in compliance with the following requirements: The Lessee shall not make any Alterations in violation of the terms of any restriction, easement, condition, covenant or other similar matter affecting title to or binding on the Improvements or the Site.
(i) No Alterations shall be undertaken until the Lessee shall have procured and paid for, so far as the same may be required from time to time, all permits and authorizations relating to such Alterations of all municipal and other Authorities having jurisdiction over the Improvements or the Site. Lessor, at the Lessee’s expense, shall join in the application for any such permit or authorization and execute and deliver any document in connection therewith, whenever such joinder is necessary or advisable; provided that, however, such joinder shall not constitute or be deemed to constitute, any assumption or responsibility or liability whatsoever.
(ii) The Alterations shall be completed in a good and workmanlike manner and in compliance in all material respects with all Applicable Laws then in effect and with the Insurance Requirements.
(iii) All Alterations shall, when completed, be of such a character as to not materially diminish (A) the utility of the Improvements as a corporate office complex including a corporate office building and any uses ancillary thereto, (B) the then current Fair Market Value as determined by reference to the Appraisal, or (C) the Fair Market Value as determined by reference to the Appraisal as of the scheduled expiration date of the Lease Term.
(iv) The Lessee shall have made adequate arrangements for payment of the cost of all Alterations when due so that the Improvements and the Site shall at all times be free of Liens for labor and materials supplied or claimed to have been supplied to the Improvements or the Site, other than Permitted Liens; provided, that the Lessee shall have the right to engage in Permitted Contests in accordance with Section 9.5.
(v) The Alterations must be located solely on the Site.
Additions and Alterations After Substantial Completion of the Facility and Leased Premises, Lessee shall have the right to make, at Lessee’s sole cost and expense, additions, alterations, and changes ("Alterations"), in or to the Leased Premises or the Improvements, provided Lessee shall not then be in default in the performance of any of Lessee's covenants or agreements in this Lease, subject, however, in all cases to the following:
(1) No Alterations of any kind shall be made without the prior written consent of Lessor if the Alterations would tend to: (a) change the general character or structure of the Improvements on the Leased Premises, or (b) reduce or impair the value, rental, rental value, rentability, or usefulness of the Leased Premises or the Improvements or any part of same;
(2) No Alterations shall be undertaken until Lessee shall have procured and paid for, to the extent the same may be required from time to time, all permits and authorizations of all municipal departments and governmental subdivisions having jurisdiction, and complied with all other laws, statutes, codes, ordinances, orders, rules, regulations, permits, or licenses relating to the Alterations;
(3) Any structural Alterations involving in the aggregate an estimated cost of more than $ shall be conducted under the supervision of an architect or engineer selected by Lessee and approved in advance and in writing by Lessor (which approval shall not be unreasonably withheld or delayed). No such structural Alterations shall be made, except in accordance with detailed plans and specifications and cost estimates prepared and approved in writing by such architect or engineer and approved in advance and in writing by Lessor (which approval shall not be unreasonably withheld or delayed). In the event of Lessor's disapproval, Lessor shall give to Lessee an itemized statement of reasons for the disapproval. If Lessor does not disapprove the plans and specifications provided for in this paragraph within fifteen (15) days after they have been submitted to Lessor, the plans and specifications shall be deemed to have been approved by Lessor. Prior to commencing any work under this Section 11, Lessee shall furnish Lessor, on demand, with a good and sufficient surety bond insuring the completion of the work and the payment of all bills in connection with the work.
(4) Any Alterations shall be made promptly, subject to Force Majeure Delay, and in a good and workmanlike manner and in compliance with all applicable laws, statutes, codes, ordinances, orders, rules, regulations, permits, or licenses, and all insurance policy provisions and requirements;
(5) The cost of any such alterations shall be paid solely by Lessee in cash or its equivalent, including the cost of labor and materials supplied to the Leased Premises or the Improvements;
(6) Workers' compensation insurance covering all persons employed in connection with the Alteration work and with respect to whom death or bodily injury claims could be asserted against Lessor, Lessee, or the Leased Premises or the Improvements, and commercial general liability insurance for the mutual benefit of Lessor and Lessee with limits of not less than $ in the event of bodily injury or death to one person and not less than $ in the event of bodily injury or death to any number of persons in any one accident, and with limits of not less than $ for damages or injury to property, with not more than a $ deductible, shall be maintained by Lessee at Lessee's sole cost and expense at all times when any substantial work is in progress in connection with any Alterations. All such insurance, if readily obtainable, shall be effected under standard form policies issued by insurers of recognized responsibility, which are duly licensed to issue such insurance in the State of Oklahoma and well rated by national rating organizations. SECTION TWELVE INSPECTIONS Lessee shall permit Lessor, Lessor’s agents, employees, and contractors to enter all parts of the Leased Premises and the Improvements during Lessee's regular business hours to inspect the same and to enforce or carry out any provisions of this Lease, provided Lessee is given reasonable advance notice, which may be verbal (except in an emergency, in which case no notice shall be necessary), and Lessee's Permitted Use shall not be unreasonably interfered with by Lessor during any entry authorized in this Section 12.
Emergency Schedule Changes The Employer may adjust an overtime-eligible employee’s workweek and work schedule without prior notice in emergencies or unforeseen operational needs.
ALTERATIONS & IMPROVEMENTS Tenant shall not make any alterations, additions or improvements or do any type of construction to the Property without first obtaining Landlord's written consent. Unless prior written agreement is reached between Tenant and Landlord, any such alterations, additions, improvements or construction shall become part of the Property and shall remain at the expiration of Tenant's Lease term. If Landlord approves of alterations, additions, improvements or construction in writing and Tenant intends to use contractors to undertake such work, the contractors must first be approved in writing by Landlord. Tenant must also place any funds to cover the amount of any alterations, additions, improvements or construction in an escrow account approved by Landlord before the commencement of the work. Landlord shall designate the times and manner of the work being done, exclusively.
