Possession Commencement and Termination of Lease Term Sample Clauses

Open Split View

Download

Share

Cite

Possession Commencement and Termination of Lease Term 

Sample 1

Save

Copy

Related to Possession Commencement and Termination of Lease Term

• COMMENCEMENT AND TERMINATION 10.1 This Agreement shall be effective as of the date hereof and shall continue in force until terminated in accordance with the provisions herein.

• Commencement and Term This Agreement shall commence upon the Effective Date and continue for the Agreement Term.

• Term of Agreement and Termination 4.1. Either party may terminate this Agreement, if the other party is in material breach of the Agreement, by giving written notice thereof to the other party, to cure such breach, following which, without curing the breach, this Agreement shall terminate. Such notice shall specify the alleged material breach, shall state the termination date and shall be sent by certified mail, return receipt requested, to the other party at the notice address specified.

• Termination of Lease Should Landlord elect to terminate this Lease pursuant to the provisions of Sections 24.1 (a) or (c) above, Landlord may recover from Tenant, as damages, the following: (a) The worth at the time of award of any unpaid rental which had been earned at the time of the termination, plus (b) the worth at the time of award of the amount by which the unpaid rental which would have been earned after termination until the time of award exceeds the amount of rental loss Tenant proves could have been reasonably avoided, plus (c) the worth at the time of award of the amount by which the unpaid rental for the balance of the Term after the time of award exceeds the amount of rental loss that Tenant proves could be reasonably avoided, plus (d) any other amounts necessary to compensate Landlord for all the detriment proximately caused by Tenant's failure to perform its obligations under this Lease or which, in the ordinary course of things, would be likely to result therefrom including, but not limited to, any costs or expenses incurred by Landlord in (i) retaking possession of the Premises, including reasonable attorneys' fees therefor, (ii) maintaining or preserving the Premises after any default, (iii) preparing the Premises for reletting to a new tenant, including repairs or alterations to the Premises, (iv) leasing commissions, or (v) any other costs necessary or appropriate to relet the Premises, plus (e) at Landlord's election, any other amounts in addition to or in lieu of the foregoing as may be permitted from time to time by the laws of the State of Nevada. As used in subparagraphs (a) and (b) above, the "worth at the time of award" is computed by allowing interest at the maximum lawful rate. As used in subparagraph (c) above, the "worth at the time of award" is computed by discounting such amount at the discount rate of the Federal Reserve Bank situated nearest to the location of the Shopping Center at the time of award plus one percent (1%).

• Termination of the Lease If for any reason the term of the Master Lease shall terminate prior to the Sublease Expiration Date, this Sublease shall automatically be terminated and Sublandlord shall not be liable to Subtenant by reason thereof unless said termination shall have been caused by the default of Sublandlord under the Master Lease, and said Sublandlord default was not as a result of a Subtenant default hereunder.

• Lease Termination Except as provided in this Section 9.04, upon expiration or earlier termination of this Lease Tenant shall surrender the Premises to Landlord in the same condition as existed on the date Tenant first occupied the Premises, (whether pursuant to this Lease or an earlier lease), subject to reasonable wear and tear. All Alterations shall become a part of the Premises and shall become the property of Landlord upon the expiration or earlier termination of this Lease, unless Landlord shall, by written notice given to Tenant, require Tenant to remove some or all of Tenant's Alterations, in which event Tenant shall promptly remove the designated Alterations and shall promptly repair any resulting damage, all at Tenant's sole expense. All business and trade fixtures, machinery and equipment, furniture, movable partitions and items of personal property owned by Tenant or installed by Tenant at its expense in the Premises shall be and remain the property of Tenant; upon the expiration or earlier termination of this Lease, Tenant shall, at its sole expense, remove all such items and repair any damage to the Premises or the Building caused by such removal. If Tenant fails to remove any such items or repair such damage promptly after the expiration or earlier termination of the Lease, Landlord may, but need not, do so with no liability to Tenant, and Tenant shall pay Landlord the cost thereof upon demand. Notwithstanding the foregoing to the contrary, in the event that Landlord gives its consent, pursuant to the provisions of Section 9.01 of this Lease, to allow Tenant to make an Alteration in the Premises, Landlord agrees, upon Tenant's written request, to notify Tenant in writing at the time of the giving of such consent whether Landlord will require Tenant, at Tenant's cost, to remove such Alteration at the end of the Lease Term.

• Premises and Term In consideration of the obligation of Tenant to pay Rent as provided in this Lease, and in consideration of the other terms, provisions, and covenants of this Lease, Landlord hereby demises and leases to Tenant, and Tenant hereby takes from Landlord certain premises described and delineated on the demising plan contained in Exhibit A attached hereto and incorporated herein by this reference, situated within a building (the "Building") located on certain real property (the "Land") within the above-named County and State and more particularly described as follows: Approximately 16,111 square feet of space located at 0000 Xxxxxxxx Xxxxxxxxx, Suites 105, 106, 107, 108, and 109, Xxxxxx, Xxxxxx County, Texas, together with the other improvements erected upon said premises (the said premises and the improvements located therein being herein referred to as the "Premises"). To Have and to Hold the Premises, subject to the other terms and provisions of this Lease, for a term (the "Term") commencing on FEBRUARY 15, 2004 (the "Commencement Date") and ending THIRTY-SIX (36) months thereafter. If this Lease is executed before the Premises become vacant or otherwise available and ready for occupancy, or if any present tenant or occupant of the Premises holds over and Landlord cannot acquire possession of the Premises prior to the originally scheduled commencement date, Landlord shall not be deemed to be in default, and Tenant agrees to accept possession of the Premises at such time as Landlord is able to tender the same; and Landlord hereby waives payment of rent covering any period prior to the tendering of possession of the Premises to Tenant. Landlord will not be liable to Tenant if Landlord does not deliver possession of the Premises to Tenant on the Commencement Date stated above. Landlord's non-delivery of possession of the Premises to Tenant on the Commencement Date will not affect this Lease or the obligations of Tenant under this Lease. However, the Commencement Date will be delayed until possession of the Premises is delivered to Tenant. The Term will be extended for a period equal to the delay in delivery of possession of the Premises to Tenant. If delivery of possession of the Premises to Tenant is delayed, Landlord and Tenant shall, upon such delivery, execute an amendment to this Lease setting forth the revised Commencement Date and expiration date of the Term. If Tenant occupies the Premises before the Commencement Date, Tenant's occupancy of the Premises will be subject to all of the provisions of this Lease. By taking possession of the Premises, Tenant shall be deemed to have acknowledged that it has inspected the Premises and accepts the Premises in their then present condition as suitable for the purpose for which the Premises are leased. Tenant further acknowledges that no representations as to the repair of the Premises, nor promises to alter, remodel, or improve the Premises, have been made by Landlord, except for those expressly set forth in this Lease.

• Commencement of Term (a) The Premises shall be deemed substantially completed upon the issuance of a certificate of substantial completion by Landlord's architect or a certificate of occupancy by the local building authority, notwithstanding that minor or insubstantial details of construction, mechanical adjustment or decoration remain to be performed. If the substantial completion of the Premises by Landlord is delayed in any way by Tenant or Tenant's Representatives, the Premises shall be deemed substantially completed for purposes of this Section on the date when they would have been substantially completed but for such delay. (b) Tenant's taking possession of the Premises shall be conclusive evidence that the Premises were in good order, condition and repair when Tenant took possession, except for those matters (for which Landlord is responsible as provided in this Lease) of which Tenant gives Landlord notice within 10 days after taking possession. Landlord shall complete or repair such matters as soon as reasonably possible. (c) If Landlord is unable to deliver possession of the Premises to Tenant within 180 days after the Expected Commencement Date (the Outside Commencement Date), then Tenant, as its sole remedy, may terminate this Lease by notice to Landlord given within 10 days after the Outside Commencement Date. The Outside Commencement Date shall be extended by the period of any delay described in Section 1(a). Landlord shall not be liable to Tenant or any third party for its failure to deliver possession of the Premises to Tenant. If the Commencement Date does not occur within one year after the Expected Commencement Date, this Lease shall terminate and Landlord and Tenant shall have no further obligations to the other, except as may otherwise be provided in this Lease. (d) After the Commencement Date has been determined, Landlord and Tenant shall execute a supplemental agreement specifying the Commencement Date, Termination Date and such other information as Landlord shall reasonably require.

• Effective Date of Agreement and Termination This Agreement shall become effective upon the execution and delivery of this Agreement by the parties hereto. This Agreement may be terminated at any time on or prior to the Closing Date by you by notice to the Company if any of the following has occurred (i) on or after the Applicable Time, any Material Adverse Change occurs, which, in the judgment of the Representatives, makes it impracticable or inadvisable to market the Securities or to enforce contracts for sale of the Securities, (ii) any new outbreak or material escalation of hostilities or other national or international calamity or crisis or material adverse change in the financial markets of the United States or elsewhere, or any other substantial national or international calamity or emergency if the effect of such outbreak, escalation, calamity, crisis or emergency would, in the judgment of the Representatives, make it impracticable or inadvisable to market the Securities or to enforce contracts for the sale of the Securities, (iii) any suspension or limitation of trading in the Company’s securities or in trading generally in securities on the New York Stock Exchange, the NYSE Amex Equities, the NASDAQ Stock Market or in the over-the-counter markets or any setting of minimum prices for trading on such exchange or markets, or a material disruption has occurred in commercial banking or securities settlement or clearance services in the United States, (iv) any declaration of a general banking moratorium by Federal, New York or Maryland authorities, (v) the taking of any action by any Federal, state or local government or agency in respect of its monetary or fiscal affairs that in your judgment has a material adverse effect on the financial markets in the United States, and would, in the judgment of the Representatives, make it impracticable or inadvisable to proceed with the offering, sale or delivery of the Securities on the terms and in the manner contemplated by this Agreement, the Pricing Disclosure Package and the Prospectus or to enforce contracts for the sale of the Securities or (vi) the enactment, publication, decree, or other promulgation of any Federal or state statute, regulation, rule or order of any court or other governmental authority which would, in the judgment of the Representatives, have a Material Adverse Effect. The indemnities and contribution provisions and the other agreements, representations and warranties of the Company, its officers and directors and the Underwriters set forth in or made pursuant to this Agreement shall remain operative and in full force and effect, and will survive delivery of and payment for the Securities, regardless of (i) any investigation, or statement as to the results thereof, made by or on behalf of any of the Underwriters or by or on behalf of the Company, its officers or directors or any controlling person thereof, (ii) acceptance of the Securities and payment for them hereunder and (iii) termination of this Agreement. If this Agreement shall be terminated by the Underwriters pursuant to clauses (i) or (iii) (with respect to the Company’s securities) of the second paragraph of this Section 11 or because of the failure or refusal on the part of the Company to comply with the terms or to fulfill any of the conditions of this Agreement, the Company agrees to reimburse you for all out-of-pocket expenses incurred by you. Notwithstanding any termination of this Agreement, the Company shall be liable for all expenses which they have agreed to pay pursuant to Section 5(e) hereof. Except as otherwise provided, this Agreement has been and is made solely for the benefit of and shall be binding upon the Company, the Underwriters, any Indemnified Person referred to herein and their respective successors and assigns, all as and to the extent provided in this Agreement, and no other person shall acquire or have any right under or by virtue of this Agreement. The terms “successors and assigns” shall not include a purchaser of any of the Securities from any of the Underwriters merely because of such purchase.

• Term Renewal and Termination 14.1. This Agreement shall, with respect to the Portfolio, become effective as of the date first above written and shall remain in force for two years thereafter, and for successive annual periods thereafter but only so long as each such continuance is specifically approved at least annually by (1) a majority of the Directors of the Company who are not parties to this Agreement or interested persons of any such parties (other than as Directors of the Company), by vote cast in person at a meeting called for the purpose of voting on such approval; or (2) a vote of the holders of a majority of the outstanding voting securities (as defined in the 0000 Xxx) of such Portfolio. It shall be the duty of the Directors of the Company to request and evaluate, and the duty of the Manager and Sub-Adviser to furnish, such information as may be reasonably necessary to evaluate the terms of this Agreement and any renewal hereof.