ERISA Liabilities The Borrower shall not, and shall cause each of its ERISA Affiliates not to, (i) permit the assets of any of their respective Plans to be less than the amount necessary to provide all accrued benefits under such Plans, or (ii) enter into any Multiemployer Plan.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2
Certain Liabilities Except as disclosed on Schedule 4.10, to such Credit Parties’ knowledge, none of the present or previously owned or operated Property of any such Credit Party or of any Subsidiary thereof, wherever located, (i) has been placed on or proposed to be placed on the National Priorities List, the Comprehensive Environmental Response Compensation Liability Information System list, or their state or local analogs, or have been otherwise investigated, designated, listed, or identified as a potential site for removal, remediation, cleanup, closure, restoration, reclamation, or other response activity under any Environmental Laws; (ii) is subject to a Lien, arising under or in connection with any Environmental Laws, that attaches to any revenues or to any Property owned or operated by any Credit Party, wherever located, which could reasonably be expected to cause a Material Adverse Change; or (iii) has been the site of any Release of Hazardous Substances or Hazardous Wastes from present or past operations which has caused at the site or at any third party site any condition that has resulted in or could reasonably be expected to result in the need for Response that could cause a Material Adverse Change.
Environmental Liabilities No action, proceeding, revocation proceeding, amendment procedure, writ, injunction or claim is pending, or to the Company's knowledge, threatened concerning any Environmental Permit, Hazardous Material or any Hazardous Materials Activity of the Company. The Company is not aware of any fact or circumstance which could involve the Company in any environmental litigation or impose upon the Company any environmental liability.
ERISA Plans and Liabilities All currently existing ERISA Plans are listed in the Disclosure Schedule. Except as disclosed in the Initial Financial Statements or in the Disclosure Schedule, no Termination Event has occurred with respect to any ERISA Plan and all ERISA Affiliates are in compliance with ERISA in all material respects. No ERISA Affiliate is required to contribute to, or has any other absolute or contingent liability in respect of, any "multiemployer plan" as defined in Section 4001 of ERISA. Except as set forth in the Disclosure Schedule: (i) no "accumulated funding deficiency" (as defined in Section 412(a) of the Code exists with respect to any ERISA Plan, whether or not waived by the Secretary of the Treasury or his delegate, and (ii) the current value of each ERISA Plan's benefits does not exceed the current value of such ERISA Plan's assets available for the payment of such benefits by more than $500,000.
Environmental Remediation Failure to remediate (or pursue the remediation process with due diligence and good faith) within the time period required by law or governmental order, (or within a reasonable time in light of the nature of the problem if no specific time period is so established), environmental problems in violation of Applicable Law related to Properties of the Borrower and/or its Subsidiaries where the estimated cost of remediation is in the aggregate in excess of Seventy-Five Million Dollars ($75,000,000), in each case after all administrative hearings and appeals have been concluded.
Remedial Actions Each Party will notify the other Parties immediately, and promptly confirm such notice in writing, if it obtains information indicating that any Licensed Product may be subject to any recall, corrective action or other regulatory action with respect to such product taken by virtue of Applicable Law (a “Remedial Action”). The Parties will assist each other in gathering and evaluating such information as is necessary to determine the necessity of conducting a Remedial Action. Each Party shall, and shall ensure that its Affiliates and sublicensees will, maintain adequate records to permit the Parties to trace the manufacture, distribution and use (to the extent possible) of the Licensed Products. As between the Parties, ZAI shall have sole discretion with respect to any matters relating to any Remedial Action for the Licensed Product in the ZAI Territory and TESARO shall have sole discretion with respect to any matters relating to any Remedial Action for the Licensed Product in the TESARO Territory. In the event that a Party determines that any Remedial Action with respect to the Licensed Product in its Territory should be commenced, or if Remedial Action is required by any Regulatory Authority having jurisdiction over the matter in its Territory, such Party will control and coordinate all efforts necessary to conduct such Remedial Action and shall be responsible for all cost and expense of such Remedial Action in its territory.
Tenant Improvement Plans Any work proposed by Tenant at the Premises or Building (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit, which approval shall not be unreasonably withheld or delayed except for good cause shown. All architectural, engineering and other design fees shall be paid by Tenant, provided that, of the total Tenant Improvement Allowance, up to Five and No/100 Dollars (S5.00) per rentable square foot of the Premises of such fees may be subject to reimbursement under the Tenant Improvement Allowance. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Santa Xxxxx and the State of California. Tenant shall cause its architect, who shall be subject to Landlord’s prior approval (“Tenant’s Architect”), which approval shall not be unreasonably withheld or delayed except for good cause shown, to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld or delayed) within twenty-one (21) days following mutual execution of the Lease. (If available upon mutual execution of this Lease, a mutually-approved preliminary space plan for the Tenant Improvements has been attached hereto as Exhibit C-1.) Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan, and Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval within five (5) business days thereafter. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval within sixty (60) days following Landlord’s approval of the final Space Plan. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion as supported by statement or reports from licensed engineers, the work, as described in any such item: (i) will adversely affect Building systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) will materially impair Landlord’s ability to furnish services to Tenant or other tenants at the Project; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances not permitted under Applicable Laws; (vi) would affect the external appearance of the Building; (vii) would materially and adversely affect another tenant’s premises at the Project: or (viii) is prohibited by any mortgage, trust deed or other instrument encumbering the Building or Project. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, and Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval within ten (10) business days thereafter. Such process shall continue until Landlord has approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively the “Tenant Improvement Allowance Items”):
Litigation and Contingent Liabilities No litigation (including derivative actions), arbitration proceeding or governmental investigation or proceeding is pending or, to the Company’s knowledge, threatened against any Loan Party which might reasonably be expected to have a Material Adverse Effect, except as set forth in Schedule 9.6. Other than any liability incident to such litigation or proceedings, no Loan Party has any material contingent liabilities not listed on Schedule 9.6 or permitted by Section 11.1.
