Final Completion 6.5.1 Final Completion of the Work shall be achieved within ninety (90) Days after the earlier of the actual date of Substantial Completion or the Scheduled Substantial Completion Date (the “Final Completion Date”).
Project Completion Within five (5) days after the delivery by Supplier to Purchaser of a Commissioning Certificate for the Project’s final Turbine, Supplier shall also deliver to Purchaser a completion certificate for all Turbines in the Project (the “Project Completion Certificate”), in the form attached hereto as Exhibit N, together with a list of any remaining Punch List Work on any Turbine, a schedule for completing the Punch List Work and an estimate of the cost of each item of Punch List Work. Supplier shall thereafter promptly complete all Punch List Work.
Check and complete if Transferee will take delivery of a beneficial interest in the IAI Global Note or a Restricted Definitive Note pursuant to any provision of the Securities Act other than Rule 144A or Regulation S. The Transfer is being effected in compliance with the transfer restrictions applicable to beneficial interests in Restricted Global Notes and Restricted Definitive Notes and pursuant to and in accordance with the Securities Act and any applicable blue sky securities laws of any state of the United States, and accordingly the Transferor hereby further certifies that (check one):
Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.
Development and Regulatory Milestones With respect to each of the following milestones, Ikaria shall pay BioLineRx the corresponding payment set forth below within [**] days after the achievement by Ikaria, its Affiliates or Licensees of such milestone: MILESTONE PAYMENT
Approval and Completion If any dispute regarding the design of the Tenant Improvements is not settled within 10 business days after notice of such dispute is delivered by one party to the other, Tenant may make the final decision regarding the design of the Tenant Improvements, provided (i) Tenant acts reasonably and such final decision is either consistent with or a compromise between Landlord’s and Tenant’s positions with respect to such dispute, (ii) that all costs and expenses resulting from any such decision by Tenant shall be payable out of the TI Fund (as defined in Section 5(d) below), and (iii) Tenant’s decision will not affect the base Building, structural components of the Building or any Building systems (in which case Landlord shall make the final decision). Any changes to the TI Construction Drawings following Landlord’s and Tenant’s approval of same requested by Tenant shall be processed as provided in Section 4 hereof.
Tenant Improvement Plans Any work proposed by Tenant at the Premises or Building (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit, which approval shall not be unreasonably withheld or delayed except for good cause shown. All architectural, engineering and other design fees shall be paid by Tenant, provided that, of the total Tenant Improvement Allowance, up to Five and No/100 Dollars (S5.00) per rentable square foot of the Premises of such fees may be subject to reimbursement under the Tenant Improvement Allowance. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Santa Xxxxx and the State of California. Tenant shall cause its architect, who shall be subject to Landlord’s prior approval (“Tenant’s Architect”), which approval shall not be unreasonably withheld or delayed except for good cause shown, to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld or delayed) within twenty-one (21) days following mutual execution of the Lease. (If available upon mutual execution of this Lease, a mutually-approved preliminary space plan for the Tenant Improvements has been attached hereto as Exhibit C-1.) Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan, and Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval within five (5) business days thereafter. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval within sixty (60) days following Landlord’s approval of the final Space Plan. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion as supported by statement or reports from licensed engineers, the work, as described in any such item: (i) will adversely affect Building systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) will materially impair Landlord’s ability to furnish services to Tenant or other tenants at the Project; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances not permitted under Applicable Laws; (vi) would affect the external appearance of the Building; (vii) would materially and adversely affect another tenant’s premises at the Project: or (viii) is prohibited by any mortgage, trust deed or other instrument encumbering the Building or Project. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, and Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval within ten (10) business days thereafter. Such process shall continue until Landlord has approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Feasibility Study Buyer is granted the right to conduct engineering and/or market and economic feasibility studies of the Property and a physical inspection of the Property, including studies or inspections to determine the existence of any environmental hazards or conditions (collectively, the “Feasibility Study”) during the period (the “Feasibility Period”) commencing on the Effective Date and ending at 5:00 p.m., Central Time, on the June 3, 2010. With Seller’s permission, after Seller has received advance notice sufficient to permit it to schedule in an orderly manner Buyer’s examination of the Property and to provide at least 24-hours’ advance written notice to any affected tenants, Buyer or its designated agents may enter upon the Property during normal business hours for purposes of analysis or other tests and inspections which may be deemed necessary by Buyer for the Feasibility Study. Buyer or its designated representative must be accompanied by a designated representative of Seller or have received Seller’s written permission prior to entering upon the Property in connection with Buyer’s Feasibility Study; provided, however, Buyer may not enter into any space leased by any tenant without being accompanied by a designated representative of Seller. Seller agrees to make its representative reasonably available during normal business hours. Buyer will not alter the physical condition of the Property or conduct invasive testing without notifying Seller of its requested tests, and obtaining the written consent of Seller to any physical alteration of the Property or invasive testing. Buyer will utilize commercially reasonable diligence to conduct or cause to be conducted all inspections and tests in a manner and at times which will not unreasonably interfere with any tenant’s use and occupancy of the Property. If Buyer determines, in its sole judgment, that the Property is not suitable for any reason for Buyer’s intended use or purpose, or is not in satisfactory condition, then Buyer may terminate this Contract by written notice to Seller prior to expiration of the Feasibility Period, in which case the Xxxxxxx Money (other than the Option Money) will be returned to Buyer, and neither party shall have any further right or obligation hereunder other than as set forth herein with respect to rights or obligations which survive termination. If this Contract is not terminated pursuant to this Section 5(a), then after expiration of the Feasibility Period, after Seller has received advance notice sufficient to permit it to schedule in an orderly manner Buyer’s examination of the Property and to provide at least 24-hours’ advance written notice to any affected tenants, Buyer or its designated agents may enter upon the Property during normal business hours. Buyer or its designated representative must be accompanied by a designated representative of Seller or have received Seller’s written permission prior to entering upon the Property; provided, however, Buyer may not enter into any space leased by any tenant without being accompanied by a designated representative of Seller. If this Contract is not timely terminated pursuant to this Section 5(a), Buyer’s right to terminate this Contract pursuant to this Section 5(a) and any and all objections with respect to the Feasibility Study will be deemed to have been waived by Buyer for all purposes.
Space Plans Within a commercially reasonable time period after the Execution Date, Tenant shall, at its sole expense (but subject to the Premises Construction Allowance), deliver to Landlord space plans prepared by an architect (“Architect”) chosen by Tenant and reasonably approved by Landlord in electronic Autocad format together with a full-size hard copy depicting all improvements and alterations desired by Tenant to be installed in or made to the Premises. Landlord shall notify Tenant whether it approves of such space plans within five (5) business days after receipt thereof. If Landlord disapproves of the space plans, Landlord shall notify Tenant thereof specifying in reasonable detail the reasons for such disapproval, in which case Tenant shall revise the space plans in accordance with Landlord’s objections and submit revised space plans in accordance with subparagraph (a) above to Landlord for its review and approval. Landlord shall notify Tenant in writing whether or not it approves of the resubmitted space plans within three (3) business days after its receipt thereof and, if Landlord disapproves, Landlord shall notify Tenant thereof specifying in reasonable detail the reasons for such disapproval. This process shall be repeated until the space plans have been finally approved by Landlord and Tenant. If Landlord fails to approve or disapprove of the space plans or the resubmitted space plans, as the case may be, within the applicable time period set forth above in this Section 2.(a), and any such failure is not cured by Landlord within three (3) business days after written notice from Tenant to Landlord of such failure, then the space plans as submitted, or as resubmitted, as the case may be, shall be deemed approved by Landlord. As used herein, “Space Plans” means the Preliminary Spaces Plans finally approved or deemed approved by Landlord as provided above. Material changes to the Space Plans shall require Landlord’s prior consent, which consent shall not be unreasonably withheld, conditioned or delayed. To the extent not attached hereto on the Execution Date, this Work Letter will be automatically amended to include as Annex 1 hereto the finally approved Space Plan.
After Completion the Seller shall at its cost execute and deliver all such further documents and/or take such other action as the Purchaser may reasonably request in order to effect (i) the release and discharge in full of the relevant member of the Purchaser’s Group from any and all Retained Liabilities and any Liabilities related to the Retained Assets and (ii) the assumption by the Seller or any member of the Seller’s Group as the primary obligor in respect of any and all Retained Liabilities or Liabilities related to the Retained Assets in substitution for the relevant member of the Purchaser’s Group (in each case on a non-recourse basis to any member of the Purchaser’s Group).
