Pre-qualification Submittal Sample Clauses

Pre-qualification Submittal. The bidder shall provide Corporate experience including: The applicant has operated under the current corporate name for the last 4 years. Provide name, address and telephone number of applicant’s corporate headquarters, relevant regional office (s) and subsidiaries, if any. Provide name, title and biographical summary of all corporate officers. Provide Georgia State Utility Contractor’s identification number. The applicant has sufficient bonding capacity to provide performance and payment bonds, both in the amount of $250,000.00. Provide statement of bonding capacity, bonding company and insurance agent contact person and telephone numbers. The applicant has access to adequate equipment to complete the project. Provide a statement that the applicant has never failed to complete a project. If this is not the case, explain. The applicant has a history of completing projects consistently on time and within the bid amount. Provide a statement that the applicant has not been involved in liquidated damages in the past 5 years or served the Owner with a claim for additional compensation prepared by an attorney or a claims consultant, excluding routing change order requests. If this is not the case, explain. The applicant has a history of not being involved in litigation against Owners or Engineering Firms. The applicant should provide a statement that they have not been involved in litigation as a plaintiff against the Owner or Engineering Firm in the past 5 years. If this is not the case, explain. The applicant has available project management personnel with at least two years’ experience on projects with the technical characteristics to complete the project. Provide experience for proposed on-site field superintendent who would supervise and be in charge of the project. Experience can be from previous employment but must be pertinent to technical requirements of the project. If your firm is the successful bidder, key personnel must be actively involved in the day-to-day operations of construction of the project. List all other projects currently under contract, the current contract amounts and scheduled completion. Bidder will be required to have a DOT Anti-Drug and Alcohol Misuse Plan and an Operator Qualification Plan and provide the procedures used for Operator Qualifications to the Owner no later than Wednesday, March 27, 2019 by 5:00 P.M., unless a pre-qualification package has already been approved by the Owner within the past 12 months. The applicant’s ...
Sample 1
AutoNDA by SimpleDocs

Related to Pre-qualification Submittal

  • Due Qualification The Servicer is duly qualified to do business as a foreign corporation, is in good standing and has obtained all necessary licenses and approvals, in all jurisdictions in which the ownership or lease of property or the conduct of its business (including the servicing of the Receivables as required by this Agreement) requires or shall require such qualification;

  • Employee Qualifications “The qualifications to be met by individuals to be employed by the school.” (Ed. Code § 47605(b)(5)(E).)

  • Performance Qualifications The Buyer reserves the right to investigate or inspect at any time whether the product, qualifications, or facilities offered by Respondent meet the Contract requirements. Respondent shall at all times during the Contract term remain responsive and responsible. In determining Respondent’s responsibility as a vendor, the agency shall consider all information or evidence which is gathered or comes to the attention of the agency which demonstrates the Respondent’s capability to fully satisfy the requirements of the solicitation and the contract. Respondent must be prepared, if requested by the Buyer, to present evidence of experience, ability, and financial standing, as well as a statement as to plant, machinery, and capacity of the respondent for the production, distribution, and servicing of the product bid. If the Buyer determines that the conditions of the solicitation documents are not complied with, or that the product proposed to be furnished does not meet the specified requirements, or that the qualifications, financial standing, or facilities are not satisfactory, or that performance is untimely, the Buyer may reject the response or terminate the Contract. Respondent may be disqualified from receiving awards if respondent, or anyone in respondent’s employment, has previously failed to perform satisfactorily in connection with public bidding or contracts. This paragraph shall not mean or imply that it is obligatory upon the Buyer to make an investigation either before or after award of the Contract, but should the Buyer elect to do so, respondent is not relieved from fulfilling all Contract requirements.

  • IRO Qualifications The IRO shall:

  • Staff Qualifications a) CONTRACTOR shall ensure that all individuals employed, contracted, and/or otherwise hired by CONTRACTOR to provide classroom and/or individualized instruction or related services hold a license, certificate, permit, or other document equivalent to that which staff in a public school are required to hold in the service rendered consistent with Education Code section 56366.1(n)(1) and are qualified pursuant to Title 5 of the California Code of Regulations sections 3064 and 3065.

  • Required Qualifications Not Applicable

  • Foreign Qualification Prior to the Company’s conducting business in any jurisdiction other than Delaware, the Majority Members shall cause the Company to comply, to the extent procedures are available and those matters are reasonably within the control of the Majority Members, with all requirements necessary to qualify the Company as a foreign limited liability company in that jurisdiction.

  • Professional Qualifications It shall be a condition of continued professional employment that employees must apply for enrolment in their appropriate professional licensing body by the thirtieth day of continuous service.

  • CORPORATE QUALIFICATIONS TO DO BUSINESS IN CALIFORNIA a. When agreements are to be performed in the state by corporations, the contracting agencies will be verifying that the contractor is currently qualified to do business in California in order to ensure that all obligations due to the state are fulfilled.

  • Minimum Qualifications If applicable pursuant to Article 3, I acknowledge that the Bidder meets the minimum qualification requirements established for this solicitation.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!