Preconstruction Submittals Sample Clauses
The Preconstruction Submittals clause requires the contractor to provide specific documents, plans, or samples to the owner or architect before actual construction work begins. These submittals may include schedules, shop drawings, product data, or mock-ups, which are reviewed and approved to ensure compliance with project requirements. By mandating this process, the clause helps prevent misunderstandings, ensures that all parties agree on materials and methods, and reduces the risk of costly changes or delays during construction.
POPULAR SAMPLE Copied 2 times
Preconstruction Submittals. Submittals requiring Owner’s acceptance before Contractor may proceed with the installation of Work or the procurement of the materials and/or equipment covered by the Submittal.
Preconstruction Submittals. If the Project Management Contractor fails to review either of the submittals required under Section 1.5.5 (and unless such failure is the result of any event of Force Majeure), the Program Management Contractor shall be subject to liquidated damages in an amount of One Thousand Dollars ($1,000) plus Two Hundred Fifty Dollars ($250) per day after receiving written notice from either the COTR or the Contracting Officer of failure to submit such report. Failure to produce such reports shall also be a factor in selecting among the various IDIQ contractors for future assignments.
Preconstruction Submittals i. CONSULTANT will develop a list of CONTRACTOR required pre-construction submittals.
ii. CONSULTANT will review CONTRACTOR’s pre-construction submittals, schedule of values, and preliminary schedule.