Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Penalties for Non-compliance to Service Level Agreement Where the Supplier/Service Provider fails to deliver the Goods/Services within the agreed and accepted milestone timelines and provided that the cause of the delay was not due to a fault of Transnet, penalties shall be imposed at …………………………………………………… .
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
ODUF Packing Specifications 6.3.1 A pack will contain a minimum of one message record or a maximum of 99,999 message records plus a pack header record and a pack trailer record. One transmission can contain a maximum of 99 packs and a minimum of one pack.
Due-on-Sale Clauses; Assumption and Substitution Agreements When a Property has been or is about to be conveyed by the Mortgagor, the Servicer shall, to the extent it has knowledge of such conveyance or prospective conveyance, exercise its rights to accelerate the maturity of the related Mortgage Loan under any "due-on-sale" clause contained in the related Mortgage or Note; provided, however, that the Servicer shall not exercise any such right if (i) the "due-on-sale" clause, in the reasonable belief of the Servicer, is not enforceable under applicable law or (ii) the Servicer reasonably believes that to permit an assumption of the Mortgage Loan would not materially and adversely affect the interest of the Owners or of the Certificate Insurer. In such event, the Servicer shall enter into an assumption and modification agreement with the person to whom such property has been or is about to be conveyed, pursuant to which such Person becomes liable under the Note and, unless prohibited by applicable law or the related Mortgage Loan documents, the Mortgagor remains liable thereon. If the foregoing is not permitted under applicable law, the Servicer is authorized to enter into a substitution of liability agreement with such person, pursuant to which the original Mortgagor is released from liability and such person is substituted as Mortgagor and becomes liable under the Note; provided, however, that to the extent any such substitution of liability agreement would be delivered by the Servicer outside of its usual procedures for mortgage loans held in its own portfolio the Servicer shall, prior to executing and delivering such agreement, obtain the prior written consent of the Certificate Insurer. The Mortgage Loan, as assumed, shall conform in all respects to the requirements, representations and warranties of this Agreement. The Servicer shall notify the Trustee that any such assumption or substitution agreement has been completed by forwarding to the Trustee the original copy of such assumption or substitution agreement, which copy shall be added by the Trustee to the related File and which shall, for all purposes, be considered a part of such File to the same extent as all other documents and instruments constituting a part thereof. The Servicer shall be responsible for recording any such assumption or substitution agreements. In connection with any such assumption or substitution agreement, the required monthly payment on the related Mortgage Loan shall not be changed but shall remain as in effect immediately prior to the assumption or substitution, the stated maturity or outstanding principal amount of such Mortgage Loan shall not be changed nor shall any required monthly payments of principal or interest be deferred or forgiven. Any fee collected by the Servicer or the Sub-Servicer for consenting to any such conveyance or entering into an assumption or substitution agreement shall be retained by or paid to the Servicer as additional servicing compensation. Notwithstanding the foregoing paragraph or any other provision of this Agreement, the Servicer shall not be deemed to be in default, breach or any other violation of its obligations hereunder by reason of any assumption of a Mortgage Loan by operation of law or any assumption which the Servicer may be restricted by law from preventing, for any reason whatsoever.
Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.
Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded vendor under this Agreement when the TIPS Member has services that need to be undertaken. Notification may occur via phone, the web, email, fax, or in person. Upon notification of a pending request, the awarded vendor shall make contact with the TIPS Member as soon as possible, but must make contact with the TIPS Member within two working days. Scheduling of projects (if applicable) may be accomplished when the TIPS Member issues a Purchase Order and/or an Agreement or Contract that will serve as “the notice to proceed” as agreed by the Vendor and the TIPS Member. The period for the delivery order will include the mobilization, materials purchase, installation and delivery, design, weather, and site cleanup and inspection. No additional claims may be made for delays as a result of these items. When the tasks have been completed the awarded vendor shall notify the client and have the TIPS Member or a designated representative of the TIPS Member inspect the work for acceptance under the scope and terms in the Purchase Order and/or Agreement or Contract. The TIPS Member will issue in writing any corrective actions that are required. Upon completion of these items, the TIPS Member will issue a completion notice and final payment will be issued per the contractual requirements of the project with the TIPS Member. Any Construction contract prepared by the TIPS Member’s Legal Counsel may alter the terms of this subsection, “Scheduling of Projects”.
DISTRIBUTION OF CONTRACTOR PRICE LIST AND CONTRACT APPENDICES Contractor shall provide Authorized Users with electronic copies of the Contract, including price lists and Appendices, upon request. Contract Updates will be handled as provided in Appendix C – Contract Modification Procedures.
