Procedures for Claims Described in Subparagraphs Sample Clauses

Procedures for Claims Described in Subparagraphs. 12.3 and 12.4: When Subcontractor prosecutes or defends any claim described in Subparagraph 12.3 or 12.4, Subcontractor shall follow all claim procedures in the Prime Contract. Subcontractor shall be bound to Contractor to the same extent that Contractor is bound to Owner by all decisions made in any proceeding authorized by the Prime Contract. Subcontractor’s compensation on claims described in Paragraph 12.4 shall be limited to the compensation actually paid to Contractor in connection with those claims, and receipt of such payment by Contractor is a condition precedent to Contractor’s obligations hereunder.
AutoNDA by SimpleDocs

Related to Procedures for Claims Described in Subparagraphs

  • Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.

  • Procedure for Claims (1) In the event the Indemnitee is named as a party in any action, claim, suit, proceeding or investigation upon which the Indemnitee intends to base a claim for indemnification hereunder, the Indemnitee shall give the Indemnitor prompt written notice of such action, claim, suit, proceeding or investigation (provided, however, that failure of the Indemnitee to provide such notice shall not relieve the Indemnitor of any liability to the Indemnitee the Indemnitor may have under this Agreement except to the extent that the Indemnitor is materially prejudiced by such failure). (2) The Indemnitor shall participate in and, assume the defence of any such action, including for certainty any derivative action, claim, suit, proceeding or investigation all at the Indemnitor's expense provided, however, that counsel retained by the Indemnitor shall be satisfactory to the Indemnitee in the exercise of his reasonable judgement. Notwithstanding the Indemnitor's assumption of the defense of such action, claim, suit, proceeding or investigation, the Indemnitee shall have the right to employ separate counsel and to participate in, but not control, the defense of such action, claim, suit, proceeding or investigation, and the Indemnitor shall bear the reasonable fees, costs and expenses of such separate counsel as such fees, costs and expenses are incurred (provided that with respect to any single action, claim, suit, proceeding or investigation, the Indemnitor shall not be required to bear the fees, costs and expenses of more than one such counsel in any single jurisdiction) if (a) the use of counsel chosen by the Indemnitor to represent the Indemnitee would present such counsel with a conflict of interest; (b) the defendants, respondents or other parties in any such action, claim, suit, proceeding or investigation include both the Indemnitee on the one hand and the Indemnitor on the other hand, and the Indemnitee has reasonably concluded that representation of both parties by the same counsel would be inappropriate due to actual or potential differing interests between them (in which case the Indemnitor shall not have the right to direct the defense of such action, claim, suit, proceeding or investigation on behalf of the Indemnitee); (c) the Indemnitor shall not have employed counsel satisfactory to the Indemnitee in the exercise of the Indemnitee's reasonable judgment to represent him, within a reasonable time after notice of the institution of such action, proceeding or investigation; or (d) the Indemnitor authorizes the Indemnitee to employ separate counsel at the Indemnitor's expense. (3) The Indemnitee shall cooperate with the Indemnitor in the Indemnitor's defense by providing such information and other assistance which the Indemnitor may reasonably request in connection with such defense. (4) The Indemnitor shall not, without the Indemnitee's prior written consent, settle, compromise, consent to the entry of any judgment in or otherwise seek to terminate any action, claim, suit or proceeding in respect of which indemnification may be sought hereunder (whether or not the Indemnitee is a party thereto) unless such settlement, compromise, consent or termination includes a release of the Indemnitee from any liabilities arising out of such action, claim, suit or proceeding. The Indemnitee shall not, without the Indemnitor's prior written consent, admit liability, settle, compromise, consent to the entry of any judgment in or otherwise seek to terminate any action, claim, suit, investigation or proceeding referred to in the preceding paragraph and the Indemnitee shall not disclose the existence of this Agreement unless required by law, subpoena, court order or upon the advice of counsel.

  • OTHER PROVISIONS RELATING TO RIGHTS OF HOLDERS OF WARRANT CERTIFICATES

  • Other Provisions Relating to Rights of Holders of Warrants 7.1 No Rights as Stockholder. A Warrant does not entitle the Registered Holder thereof to any of the rights of a stockholder of the Company, including, without limitation, the right to receive dividends, or other distributions, exercise any preemptive rights to vote or to consent or to receive notice as stockholders in respect of the meetings of stockholders or the election of directors of the Company or any other matter.

  • Titles of Articles, Sections and Subsections All titles or headings to articles, sections, subsections or other divisions of this Agreement and the other Loan Documents or the exhibits hereto and thereto are only for the convenience of the parties and shall not be construed to have any effect or meaning with respect to the other content of such articles, sections, subsections or other divisions, such other content being controlling as to the agreement between the parties hereto.

  • Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).

  • OTHER PROVISIONS RELATING TO RIGHTS OF HOLDERS OF WARRANT CERTIFICATES

  • Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion First Tier Participants: a. The prospective first tier participant certifies to the best of its knowledge and belief, that it and its principals: (1) Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participating in covered transactions by any Federal department or agency; (2) Have not within a three-year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; (3) Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State or local) with commission of any of the offenses enumerated in paragraph (a)(2) of this certification; and (4) Have not within a three-year period preceding this application/proposal had one or more public transactions (Federal, State or local) terminated for cause or default. b. Where the prospective participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal.

  • Limitations on Re-Disclosure The Provider shall not re-disclose Student Data to any other party or affiliate without the express written permission of the LEA or pursuant to court order, unless such disclosure is otherwise permitted under SOPPA, ISSRA, FERPA, and MHDDCA. Provider will not sell or rent Student Data. In the event another party, including law enforcement or a government entity, contacts the Provider with a request or subpoena for Student Data in the possession of the Provider, the Provider shall redirect the other party to seek the data directly from the LEA. In the event the Provider is compelled to produce Student Data to another party in compliance with a court order, Provider shall notify the LEA at least five (5) school days in advance of the court ordered disclosure and, upon request, provide the LEA with a copy of the court order requiring such disclosure.

  • Indemnification Procedures for Non-Third Party Claims In the event any Indemnified Party should have an indemnification claim against the Shareholder under this Agreement that does not involve a claim by a third party, the Indemnified Party shall promptly deliver notice of such claim to the Shareholder in writing and in reasonable detail. The failure by any Indemnified Party to so notify the Shareholder shall not relieve the Shareholder from any liability that it may have to such Indemnified Party, except to the extent that the Shareholder has been actually prejudiced by such failure. If the Shareholder does not notify the Indemnified Party within fifteen (15) Business Days following its receipt of such notice that the Shareholder disputes such claim, such claim specified by the Shareholder in such notice shall be conclusively deemed a liability of the Shareholder under this Article VII and the Shareholder shall pay the amount of such liability to the Indemnified Party on demand, or in the case of any notice in which the amount of the claim is estimated, on such later date when the amount of such claim is finally determined. If the Shareholder disputes its liability with respect to such claim in a timely manner, Shareholder and the Indemnified Party shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through negotiations, such dispute shall be submitted to arbitration pursuant to Section 9.9.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!