PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract. Delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor, unless otherwise agreed to by the Authorized User and the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of a Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
Purchase Order Pricing/Product Deviation If a deviation of pricing/product on a Purchase Order or contract modification occurs between the Vendor and the TIPS Member, TIPS must be notified within five (5) business days of receipt of change order. TIPS reserves the right to terminate this agreement for cause or no cause for convenience with a thirty (30) days prior written notice. Termination for convenience is conditionally required under Federal Regulations 2 CFR part 200 if the customer is using federal funds for the procurement. All purchase orders presented to the Vendor, but not fulfilled by the Vendor, by a TIPS Member prior to the actual termination of this agreement shall be honored at the option of the TIPS Member. The awarded Vendor may terminate the agreement with ninety (90) days prior written notice to TIPS 0000 XX Xxx Xxxxx, Xxxxxxxxx, Xxxxx 00000. The vendor will be paid for goods and services delivered prior to the termination provided that the goods and services were delivered in accordance with the terms and conditions of the terminated agreement. This termination clause does not affect the sales agreements executed by the Vendor and the TIPS Member customer pursuant to this agreement. TIPS Members may negotiate a termination for convenience clause that meets the needs of the transaction based on applicable factors, such as funding sources or other needs. Usually, purchase orders or their equal are issued by participating TIPS Member to the awarded vendor and should indicate on the order that the purchase is per the applicable TIPS Agreement Number. Orders are typically emailed to TIPS at xxxxxx@xxxx-xxx.xxx. • Awarded Vendor delivers goods/services directly to the participating member. • Awarded Vendor invoices the participating TIPS Member directly. • Awarded Vendor receives payment directly from the participating member. • Fees are due to TIPS upon payment by the Member to the Vendor. Vendor agrees to pay the participation fee to TIPS for all Agreement sales upon receipt of payment including partial payment, from the Member Entity or as otherwise agreed by TIPS in writing and signed by an authorized signatory of TIPS.
Compatibility 1. Any unresolved issue arising from a mutual agreement procedure case otherwise within the scope of the arbitration process provided for in this Article and Articles 25A to 25G shall not be submitted to arbitration if the issue falls within the scope of a case with respect to which an arbitration panel or similar body has previously been set up in accordance with a bilateral or multilateral convention that provides for mandatory binding arbitration of unresolved issues arising from a mutual agreement procedure case.
2. Nothing in this Article and Articles 25A to 25G shall affect the fulfilment of wider obligations with respect to the arbitration of unresolved issues arising in the context of a mutual agreement procedure resulting from other conventions to which the Contracting States are or will become parties.”.
Service Specification The Parties have agreed upon the scope and specification of the Services provided under this Service Agreement in the Service Specification.
Contract Deliverables The Contractor shall provide information technology staff augmentation services, including comprehensive management of staff, as set forth in this Contract. The term “staff” refers to the temporary staff provided by the Contractor to render information technology services identified by Customers, but that staff shall not be deemed an employee of the State or deemed to be entitled to any benefits associated with such employment. Contracts resulting from this solicitation should not be structured as fixed-price agreements or used for any services requiring authorization for payment of milestone tasks. Contractor shall only provide information technology staff augmentation services for those Job Titles awarded to the Contractor and shall be paid on an hourly basis. The Department’s intent is for Contractor’s information technology staff to provide services closely related to those described in the Job Family Descriptions document. Detailed scopes of work, specific requirements of the work to be performed, and any requirements of staff shall be provided by the Customer in a Request for Quote. The Contractor shall possess the professional and technical staff necessary to allocate, outsource, and manage qualified information technology staff to perform the services requested by the Customer. The Contractor shall provide Customers with staff who must have sufficient skill and experience to perform the services assigned to them. All of the information technology staff augmentation services to be furnished by the Contractor under the Contract shall meet the professional standards and quality that prevails among information technology professionals in the same discipline and of similar knowledge and skill engaged in related work throughout Florida under the same or similar circumstances. The Contractor shall provide, at its own expense, training necessary for keeping Contractor’s staff abreast of industry advances and for maintaining proficiency in equipment and systems that are available on the commercial market. The Contractor shall be responsible for the administration and maintenance of all employment and payroll records, payroll processing, remittance of payroll and taxes, and all administrative tasks required by state and federal law associated with payment of staff. The Contractor shall, at its own expense, be responsible for adhering to the Contract background screening requirements, testing, evaluations, advertising, recruitment, and disciplinary actions of Contractor’s information technology staff. The Contractor shall maintain during the term of the Contract all licenses, permits, qualifications, insurance and approvals of whatever nature that are legally required to perform the information technology staff augmentation services.
Outputs Analogue and digital outputs of protected content are allowed if they meet the requirements in this section and if they are not forbidden elsewhere in this Agreement..
Project Deliverables The Contractor shall provide each of the following deliverables in writing to the City for review and approval to achieve the project objectives.
C.1. <Title> Deliverable 1
TRUNK FORECASTING 57.1. CLEC shall provide forecasts for traffic utilization over trunk groups. Orders for trunks that exceed forecasted quantities for forecasted locations will be accommodated as facilities and/or equipment are available. Sprint shall make all reasonable efforts and cooperate in good faith to develop alternative solutions to accommodate orders when facilities are not available. Company forecast information must be provided by CLEC to Sprint twice a year. The initial trunk forecast meeting should take place soon after the first implementation meeting. A forecast should be provided at or prior to the first implementation meeting. The semi-annual forecasts shall project trunk gain/loss on a monthly basis for the forecast period, and shall include:
57.1.1. Semi-annual forecasted trunk quantities (which include baseline data that reflect actual Tandem and end office Local Interconnection and meet point trunks and Tandem-subtending Local Interconnection end office equivalent trunk requirements) for no more than two years (current plus one year);
57.1.2. The use of Common Language Location Identifier (CLLI-MSG), which are described in Telcordia documents BR 000-000-000 and BR 000-000-000;
57.1.3. Description of major network projects that affect the other Party will be provided in the semi-annual forecasts. Major network projects include but are not limited to trunking or network rearrangements, shifts in anticipated traffic patterns, or other activities by CLEC that are reflected by a significant increase or decrease in trunking demand for the following forecasting period.
57.1.4. Parties shall meet to review and reconcile the forecasts if forecasts vary significantly.
PRODUCT MANUFACTURER'S SUPPLIERS Only those dealers/distributors listed by the manufacturer will be considered authorized to act on behalf of the Product Manufacturer.
