PROJECT DESCRIPTION AND SCHEDULE Sample Clauses

PROJECT DESCRIPTION AND SCHEDULE a. Project Description: Architectural services shall be provided for the planning, development and new construction for the upcoming Measure I Projects (“Project”), which is described in Exhibit A, Project Description and Schedule, attached hereto and incorporated by this reference. The Project is located at Inverness Elementary School, 0 Xxxxxx Xxx, Xxxxxxxxx, Xxxxxxxxxx.
AutoNDA by SimpleDocs
PROJECT DESCRIPTION AND SCHEDULE. Project Description: Architectural/Engineering design services shall be provided for the Project, described as follows: the Project is at the Kentfield Campus, located at 000 Xxxxxxx Xxxxxx, Xxxxxxxxx, XX 00000 and consists of the demolition of the existing Learning Resources Center, adjacent parking and circulation; design, Division of State Architect (“DSA”) approval, construction, and DSA closeout of a new Learning Resources Center; and demolition of the existing features in the courtyard between the Learning Resources Center and the Student Services Center and the construction of improvements thereon. The existing Learning Resources Center building will be completely demolished and the utilities in the footprint of the existing building will need to be removed or relocated to the footprint of the new building. Piers, foundations, and slabs will be removed. Existing fiber and utilities may need relocation. Contractor will be required to coordinate with geotechnical services, archaeological services, and other related entities. The existing courtyard walkways, ramps, lighting, and landscaping will all be removed. The District believes that historic artifacts may be located here, so care must be taken to avoid any disruption to existing artifacts and Contractor must comply with guidelines to be provided by the District. New walkways, ramps, stairs, landscaping, outdoor furniture, and lighting will be installed in this area. The estimated budget for construction hard costs for the Project is $82,000,000 (eighty-two million dollars).
PROJECT DESCRIPTION AND SCHEDULE a. Project Description: Architectural services shall be provided for the Napa Valley College Building 3100 Modernization Construction Project (“Project”), which is described in Exhibit A, Project Description and Schedule, attached hereto and incorporated by this reference. The Project is located at 0000 Xxxx Xxxxxxx Xxx, Xxxx, XX 00000. b. Project Schedule: Included in Exhibit A is the Project Schedule indicating duration and milestone dates for key Project tasks. Architect shall perform services consistent with the Project Schedule as required by Paragraph 19, Time Schedule. Architect shall regularly report to District, not less frequently than once a month, and when the District requests, on actions required to meet milestone schedule dates and shall recommend further adjustments to the Project Schedule, if and when needed.
PROJECT DESCRIPTION AND SCHEDULE. The project includes the design and construction of a new office building of approximately 6,000 square feet within the City of Xxxxxx Valley Corporate Yard property. The proposed building is designed to meet the City’s near-term needs as recommended by the Corporate Yard Space Needs Analysis approved by the City Council. The proposed building is a modified version of Building “F” as shown in the Conceptual Design Study and Phasing Plan of the Corporate Yard, which is to be on the west side of the existing Administration Building (Building “A”). See attached Location Map and “Corporate Yard Facility Space Needs Analysis and Conceptual Design” for more information. Currently there is only limited funding available for the design of the project. The construction of the project will be determined once funding becomes available. The following dates are critical in order to have the design substantially completed by June 2023: DATE EVENT 1 August 10, 2022 Request for Proposals issued 2 August 25, 2022 @ 10:00 a.m. Mandatory pre-proposal meeting at the project site 5 September 19, 2022 Proposals review and consultant selection complete 6 October 6, 2022 City Council to award contract for design service
PROJECT DESCRIPTION AND SCHEDULE 

Related to PROJECT DESCRIPTION AND SCHEDULE

  • LIST OF SCHEDULES AND EXHIBITS Schedules

  • Work Schedules Workweeks and work shifts of different numbers of hours may be established by the Employer in order to meet business and customer service needs, as long as the work schedules meet federal and state laws.

  • Exhibits and Schedules The Exhibits and Schedules shall be construed with and as an integral part of this Agreement to the same extent as if the same had been set forth verbatim herein.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!