Ceding Commission The Reinsurer shall allow the Company a ceding commission of (or a proportionate share of such amount in the event of a Quota Share Reduction) per annum, to be taken as a deduction from the first monthly premium payment to the Reinsurer at the commencement of this Contract and at each annual anniversary thereof, to cover the Company's operational costs directly allocable to writing the business subject hereto.
Payment of Commission 7 (1) The Company may exercise the power to make payments by way of brokerage or commission conferred by the Law in the manner provided by the Law.
7 (2) Payments by way of brokerage or commission may be satisfied by the payment of cash and, after the Establishment Period, by the allotment of fully or partly paid shares, or partly by the payment of cash and partly by the allotment of fully or partly paid shares.
Payment of Commissions Payments of selling commissions and any other fees due to the Dealer pursuant to this Agreement will be made by the Dealer Manager to the Dealer. Selling commissions and such other fees and expense reimbursements due to the Dealer pursuant to this Agreement will be paid to the Dealer within 30 days after their receipt by the Dealer Manager. The Dealer, in its sole discretion, may authorize the Dealer Manager to deposit selling commissions and any other fees or payments due to it pursuant to this Agreement directly to its bank account. If the Dealer so elects, the Dealer shall provide such deposit authorization and instructions in Schedule 2 to this Agreement.
Provisional Certificate 12.2.1 Subject to the provisions of Clause 12.2.5, upon completion of all Works forming part of the Project Highway, save and except the Works for which Time Extension has been granted under Clause 10.5, the Authority’s Engineer shall, at the request of the Contractor, issue a provisional certificate of completion substantially in the form set forth in Schedule-L (the “Provisional Certificate”) if the Tests for and in respect of the completed Works are successful. The Provisional Certificate shall have appended thereto a list of outstanding items of work (the “Punch List”) that need to be completed in accordance with the provisions of this Agreement. The Contractor undertakes to complete the minor outstanding items of works in respect of those Sections of the Project Highway for which the Provisional Certificate has been issued, within a period of 30 (thirty) days of the date of Provisional Certificate, and those parts of the Works in respect of which Time Extension has been granted, within the extended period thereof. For the avoidance of doubt, the Parties agree that the Punch List shall include all Works for which Time Extension has been granted and shall also include any minor outstanding items of work forming part of the completed Sections if such works do not materially affect the use of the completed Sections for their intended purpose. The Parties further agree that Provisional Certificate shall not be issued if the completed Works can not be safely and reliably placed in service of the Users thereof.
12.2.2 Upon issue of Provisional Certificate, the provisions of Articles 14 and 17 shall apply to the completed parts of the Project Highway and the property and ownership of all such completed Works shall vest in the Authority.
12.2.3 If the Authority’s Engineer determines that the Project Highway or any completed part thereof does not conform to the provisions of this Agreement and cannot be safely and reliably placed in operation, it shall forthwith make a report in this behalf and send copies thereof to the Authority and the Contractor and withhold issuance of the Provisional Certificate until the Defects or deficiencies are rectified by the Contractor and Tests are successful in accordance with this Article 12.
12.2.4 Notwithstanding anything to the contrary contained in Clause 12.2.3, the Authority may, at any time after receiving a report from the Authority’s Engineer under that Xxxxxx, direct the Authority’s Engineer to issue a Provisional Certificate under Clause 12.2.1 and such direction shall be complied forthwith.
12.2.5 No Provisional Certificate shall be issued under the provisions of this Clause 12.2 until the Contractor has submitted valid claims for payment of at least 80% (eighty per cent) of the amount arrived at after reducing the lump sum price specified in Clause 19.1.1 by the amount attributable to works which have been withdrawn under the provisions of Clause 8.3.3. For the avoidance of doubt and by way of illustration, the Parties agree that if the Contract Price specified in Clause 19.1.1 is Rs. 105 cr. (Rs. one hundred and five crore) and the works withdrawn under Clause 8.3.3 have a value of Rs. 5 cr. (Rs. five crore), a Provisional Certificate shall not be issued until valid claims for payment of an amount of Rs. 80 cr. (Rs. eighty crore) have been submitted by the Contractor in accordance with the provisions of this Agreement. It is further agreed that all price adjustments made in pursuance of Clause 19.10 shall not be reckoned for computation of the claims for payments referred to in this Clause 12.2.5.
Securities Exchange Commission Certification The Corporation confirms that as at the date hereof it does not have a class of securities registered pursuant to Section 12 of the U.S. Exchange Act or a reporting obligation pursuant to Section 15(d) of the U.S.
CFR PART 200 Procurement of Recovered Materials A non-Federal entity that is a state agency or agency of a political subdivision of a state and its contractors must comply with section 6002 of the Solid Waste Disposal Act, as amended by the Resource Conservation and Recovery Act. The requirements of Section 6002 include procuring only items designated in guidelines of the Environmental Protection Agency (EPA) at 40 CFR part 247 that contain the highest percentage of recovered materials practicable, consistent with maintaining a satisfactory level of competition, where the purchase price of the item exceeds $10,000 or the value of the quantity acquired during the preceding fiscal year exceeded $10,000; procuring solid waste management services in a manner that maximizes energy and resource recovery; and establishing an affirmative procurement program for procurement of recovered materials identified in the EPA guidelines. Does vendor certify that it is in compliance with the Solid Waste Disposal Act as described above? Yes
Grievance Commissioner System This is to confirm the discussion of the parties during collective bargaining that they are committed to encouraging early discussion and resolution of labour relations issues at the local level and seek to resolve grievances in a timely and cost efficient manner. To that end, this is to confirm that pursuant to Article 8, the parties agree that the Employer and Union at individual nursing homes may agree to utilize the following process in order to resolve a particular grievance through the utilization of a joint mediation-arbitration procedure:
Leasing Commissions On or before the Closing Date, Seller shall pay in full all leasing commissions due to leasing or other agents for the current remaining term of the Lease (determined without regard to any unexercised termination or cancellation right).
Commission Approval The Parties understand and agree that this Agreement will be filed with the Commission for approval by such Commission (or the FCC if the Commission fails to act) pursuant to Section 252 of the Act. Each Party specifically reserves its right to judicial review of this Agreement under Section 252(e)(6) of the Act, or any other available remedy at law or equity. If the Commission, the FCC or any court rejects any portion of this Agreement, the Parties agree to meet and negotiate in good faith to arrive at a mutually acceptable modification of the rejected portion and any provisions that would be materially affected by deletion of the rejected portion; provided that such rejected portion shall not affect the validity of the remainder of this Agreement. The Parties acknowledge that nothing in this Agreement shall limit a Party's ability, independent of such Party's agreement to support and participate in the approval of this Agreement, to assert public policy issues relating to the Act, including challenging the validity of any portion of the Act or an FCC or Commission rule, order, Guideline or other determination made pursuant to the Act, or the application by CBT for suspension or modification of portions of the Act or rules pursuant to Section 251(f)(2) of the Act. In the event CBT obtains a suspension or modification of any portion of the Act or rules thereunder pursuant to Section 252(f)(2) of the Act, the Parties shall negotiate as necessary to incorporate the applicable terms and conditions of such suspension or modification and the Parties agree to negotiate as necessary in order to clarify the application of such suspension or modification to the terms of into this Agreement.
Provisional Application Upon signature of this Compact, and until this Compact has entered into force in accordance with Section 7.3, the Parties will provisionally apply the terms of this Compact; provided that, no MCC Funding, other than Compact Implementation Funding, will be made available or disbursed before this Compact enters into force.
