Notice Requirement for Termination No termination of this Agreement will be effective unless and until the Party terminating this Agreement gives prior written notice to the other Party to this Agreement of its intent to terminate, and such notice shall set forth the basis for such termination. Furthermore: (a) in the event that any termination is based upon the provisions of Sections 6.1(a) or 6.1(e) hereof, such prior written notice shall be given at least six (6) months in advance of the effective date of termination unless a shorter time is agreed to by the Parties hereto; (b) in the event that any termination is based upon the provisions of Sections 6.1(b) or 6.1(c) hereof, such prior written notice shall be given at least ninety (90) days in advance of the effective date of termination unless a shorter time is agreed to by the Parties hereto; and (c) in the event that any termination is based upon the provisions of Sections 6.1(d), 6.1(f), 6.1(g), 6.1(h) or 6.1(i) hereof, such prior written notice shall be given as soon as possible within twenty-four (24) hours after the terminating Party learns of the event causing termination to be required.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Payment for TIPS Sales TIPS Members may make payments for TIPS Sales directly to Vendor, Vendor’s Authorized Reseller, or as otherwise agreed to in the applicable Supplemental Agreement after receipt of the invoice and in compliance with applicable payment statutes. Regardless of how payment is issued or received for a TIPS Sale, Vendor is responsible for all reporting and TIPS Administration Fee payment requirements as stated herein.
Annual Statement as to Compliance, Notice of Servicer Termination Event (a) To the extent required by Section 1123 of Regulation AB, the Servicer, shall deliver to the Trustee, the Owner Trustee, the Trust Collateral Agent, the Backup Servicer and each Rating Agency, on or before March 31 of each year (regardless of whether the Seller has ceased filing reports under the Exchange Act), beginning on March 31, 2012, an officer’s certificate signed by any Responsible Officer of the Servicer, dated as of December 31 of the previous calendar year, stating that (i) a review of the activities of the Servicer during the preceding calendar year (or such other period as shall have elapsed from the Closing Date to the date of the first such certificate) and of its performance under this Agreement has been made under such officer’s supervision, and (ii) to such officer’s knowledge, based on such review, the Servicer has fulfilled in all material respects all its obligations under this Agreement throughout such period, or, if there has been a failure to fulfill any such obligation in any material respect, identifying each such failure known to such officer and the nature and status of such failure. (b) The Servicer shall deliver to the Trustee, the Owner Trustee, the Trust Collateral Agent, the Backup Servicer and each Rating Agency, promptly after having obtained knowledge thereof, but in no event later than two (2) Business Days thereafter, written notice in an officer’s certificate of any event which with the giving of notice or lapse of time, or both, would become a Servicer Termination Event under Section 9.1(a). The Seller or the Servicer shall deliver to the Trustee, the Owner Trustee, the Trust Collateral Agent, the Backup Servicer, the Servicer or the Seller (as applicable) and each Rating Agency promptly after having obtained knowledge thereof, but in no event later than two (2) Business Days thereafter, written notice in an officer’s certificate of any event which with the giving of notice or lapse of time, or both, would become a Servicer Termination Event under any other clause of Section 9.1. (c) The Servicer will deliver to the Issuer, on or before March 31 of each year, beginning on March 31, 2012, a report regarding the Servicer’s assessment of compliance with certain minimum servicing criteria during the immediately preceding calendar year, as required under Rules 13a-18 and 15d-18 of the Exchange Act and Item 1122 of Regulation AB. (d) To the extent required by Regulation AB, the Servicer will cause any affiliated servicer or any other party deemed to be participating in the servicing function pursuant to Item 1122 of Regulation AB to provide to the Issuer, on or before March 31 of each year, beginning on March 31, 2012, a report regarding such party’s assessment of compliance with certain minimum servicing criteria during the immediately preceding calendar year, as required under Rules 13a-18 and 15d-18 of the Exchange Act and Item 1122 of Regulation AB. (e) Xxxxx Fargo Bank, National Association acknowledges, in its capacity as Backup Servicer and Trust Collateral Agent under this Agreement and in its capacity as Indenture Trustee under the Basic Documents, that to the extent it is deemed to be participating in the servicing function pursuant to Item 1122 of Regulation AB, it will take any action reasonably requested by the Servicer to ensure compliance with the requirements of Section 4.10(d) and Section 4.11(b) hereof and with Item 1122 of Regulation AB. Such required documentation will be delivered to the Servicer by March 15 of each calendar year.
System for Award Management (XXX) Requirement Alongside a signed copy of this Agreement, Grantee will provide Florida Housing with a XXX.xxx proof of registration and Commercial and Government Entity (CAGE) number. Grantee will continue to maintain an active XXX registration with current information at all times during which it has an active award under this Agreement.
Payment for Material Completion The Contractor may request payment of the remaining contract balance, including retainage, less amounts credited the Owner or incurred as liquidated damages, and less amounts withheld for the Punchlist by reason of Minor Items or Permitted Incomplete Work (See Paragraph 6.5.3.2). Payment for Material Completion shall be made by a check payable jointly to the Contractor and Surety and shall be mailed to the Surety.
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Planning for Future Years (a) Advance Notice. The Funder will give at least 60 Days’ Notice to the HSP of the date by which a Planning Submission, approved by the HSP’s governing body, must be submitted to the Funder.
