Product Specific Terms these terms apply to specific Products referenced in this section.
Quality- and Cost-Based Selection Except as ADB may otherwise agree, the Borrower shall apply quality- and cost-based selection for selecting and engaging consulting services.
Country Specific Terms Appendix A contains additional terms and conditions of the Agreement applicable to Participants residing in those countries. In addition, Appendix A also contains information and notices of exchange control and certain other issues of which the Participant should be aware.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Technical Objections to Grievances It is the intent of both Parties of this Agreement that no grievance shall be defeated merely because of a technical error, other than time limitations in processing the grievance through the grievance procedure. To this end, an arbitration board shall have the power to allow all necessary amendments to the grievance and the power to waive formal procedural irregularities in the processing of a grievance, in order to determine the real matter in dispute and to render a decision according to equitable principles and the justice of the case.
Quality Specifications SANMINA-SCI shall comply with the quality specifications set forth in its Quality Manual, incorporated by reference herein, a copy of which is available from SANMINA-SCI upon request.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Additional Federally Required Orders/Directives Both parties agree that they will comply with the following laws and directives, where applicable: 11.20.1 Executive Order 11061, as amended, which directs the Secretary of HUD to take all action which is necessary and appropriate to prevent discrimination by agencies that utilize federal funds. 11.20.2 Public Law 88-352, Title VI of the Civil Rights Act of 1964, which provides that no person in the United States shall, on the basis of race, color, national origin, or sex, be excluded from participation in, denied the benefits of, or subjected to discrimination under any program or activity which receives federal financial assistance. The Agency hereby extends this requirement to the Contractor and its private contractors. Specific prohibited discriminatory actions and corrective action are described in Chapter 2, Subtitle C, Title V of the Anti-Drug Abuse Act of 1988 (42 U.S.C. 19901 et. seq.). 11.20.3 Public Law 90-284, Title VIII of the Civil Rights Act of 1968., popularly known as the Fair Housing Act, which provides for fair housing throughout the United States and prohibits any person from discriminating in the sale or rental of housing, the financing of housing or the provision of brokerage services, including in any way making unavailable or denying a dwelling to any person because of race, color, religion, sex, or national origin. Pursuant to this statute, the Agency requires that the Contractor administer all programs and activities, which are related to housing and community development in such a manner as affirmatively to further fair housing. 11.20.4 The Age Discrimination Act of 1975, which prohibits discrimination on the basis of age. 11.20.5 Anti-Drug Abuse Act of 1988 (42 U.S.C. 11901 et. seq.). 11.20.6 HUD Information Bulletin 909-23 which is the following: 11.20.6.1 Notice of Assistance Regarding Patent and Copyright Infringement; 11.20.6.2 Clean Air and Water Certification; and,
Packing Specifications 7.3.1 A pack will contain a minimum of one message record or a maximum of 99,999 message records plus a pack header record and a pack trailer record. One transmission can contain a maximum of 99 packs and a minimum of one pack.
Deviation from Grievance Procedure The Employer agrees that, after a grievance has been discussed at Step 2 of the grievance procedure the Employer or his representatives shall not initiate any discussion or negotiations with respect to the grievance, either directly or indirectly with the aggrieved employee without the consent of the xxxxxxx or the Union.
