Reconstruction of the Bank or Customer Sample Clauses

Reconstruction of the Bank or Customer. The security, liabilities and obligations created by this Agreement and by the Security Documents shall continue to be valid and binding for all purposes whatsoever, notwithstanding any change by amalgamation, reconstruction or otherwise which may be made in the constitution of the Bank or the Customer, or both, and it is expressly declared that no change whatsoever in relation to or affecting the Bank or the Customer, or both, shall in any way affect the security, liabilities and obligations created hereunder in relation to any transaction whatsoever whether past present or future.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Reconstruction of the Bank or Customer. The security, liabilities and obligations created by this Assignment shall continue to be valid and binding for all purposes whatsoever notwithstanding any change by amalgamation reconstruction or otherwise which may be made in the constitution of the Bank or the Customer, or both. and it is expressly declared that no change whatsoever in relation to or affecting the Bank or the Customer, or both, shall in any way affect the security, liabilities and obligations created hereunder in relation to any transaction whatsoever whether past present or future.
Sample 1

Related to Reconstruction of the Bank or Customer

  • Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.

  • Reconstruction (a) Subject to the provisions of subparagraphs (b) and (c) below, in the event the Premises or any other portion of the Building is damaged by fire or other perils covered by extended coverage insurance, and such damage does not require structural demolition and reconstruction of all or part of the Building, Landlord agrees to forthwith repair such damage utilizing the proceeds of insurance and this Lease shall remain in full force and effect, except that Tenant shall be entitled to an equitable reduction of Minimum Rent from the date of damage until completion of such repairs, based on the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises. (b) In the event that any casualty requires structural demolition and reconstruction of all or a material part of the Building (whether or not such reconstruction involves any portion of the Premises), Tenant may, at its election, give notice to Landlord at any time within sixty (60) days after such damage, terminating this Lease as of the date of the casualty. In the event of giving such notice, this Lease and all interest of Tenant in the Premises shall terminate on the date of the casualty, the Rent shall be paid up to the date of such casualty, and Landlord shall be entitled to all insurance maintained by Tenant on the Building (except for proceeds attributable to Tenant’s personal property in, on or about the Premises). In the alternative, and so long as at least five (5) years remain in the Term or Tenant then exercises an Option pursuant to Paragraph 3(b), if any Tenant may, by written notice to Landlord within such 60-day period, elect to require Landlord to repair or restore such damage, in which case the Minimum Rent shall be proportionately reduced as provided in subparagraph (a) above and this Lease shall continue in full force and effect; PROVIDED, HOWEVER, that Tenant shall have the right to alter the size and configuration of the Building in the course of such reconstruction, so long as the Building as reconstructed is an integrated architectural unit, the dimensions of the Premises are substantially the same as prior to such casualty and Tenant is able to operate its business as intended at the time of Lease execution, subject to Landlord’s approval which will not be unreasonably conditioned, delayed or denied. If Tenant elects to require Landlord to construct the improvements, Tenant will make available to Landlord all insurance proceeds received by Tenant or due to Tenant, and, prior to any reconstruction, Tenant will deposit with Landlord or its contractor the amount by which the cost of reconstruction exceeds the amount of the insurance proceeds.

  • Preconstruction Services During the Design & Preconstruction Phase, the Design-Builder shall provide such design and preconstruction services as are necessary to properly advance the Project. Without limiting the generality of the foregoing, during the Preconstruction Phase, the Design-Builder shall: (i) work with its Architect and any design consultants to advance the design for the Project in consultation with Client Agency, the Department and its Program Manager; (ii) obtain bids from trade subcontractors to perform the work described in the Design Development Documents and provide bid tabulations to the Department; (iii) engage in any value engineering and scoping exercises necessary to return the cost of the work to the Project Budget; (iv) engage in preconstruction activities, including identifying any long-lead items; (v) develop a GMP proposal for the Project; and (vi) enter into a GMP for the Project. Throughout the Design & Preconstruction Phase, the Design-Builder shall schedule and attend regular meetings with the Department, the Program Manager and the Architect. A list of preconstruction deliverables is set forth in Exhibit C.

  • Duration of the Processing Personal Data will be Processed for the duration of the Agreement, subject to Section 4 of this DPA.

  • Operation of the Business Except as set forth on Section 10.1 of the Sentech Disclosure Schedule, as contemplated by this Agreement or as expressly agreed to in writing by Sensec and Ensec, during the period from the date of this Agreement to the Effective Time, Sentech and its Subsidiaries will conduct their operations only in the ordinary course of business consistent with sound financial, operational and regulatory practice, and will take no action which would materially adversely affect their ability to consummate the Transactions. Without limiting the generality of the foregoing, except as otherwise expressly provided in this Agreement or except as disclosed in the Sentech Disclosure Schedule, prior to the Effective Time, neither Sentech nor any of its Subsidiaries will, without the prior written consent of Sensec and Ensec: (a) amend its Charter Documents or bylaws (or similar organizational documents); (b) authorize for issuance, issue, sell, deliver, grant any options for, or otherwise agree or commit to issue, sell or deliver any shares of its capital stock or any other securities, other than pursuant to and in accordance with the terms of any Existing Options or Sentech Warrants listed on the Sentech Disclosure Schedule; (c) recapitalize, split, combine or reclassify any shares of its capital stock; declare, set aside or pay any dividend or other distribution (whether in cash, stock or property or any combination thereof) in respect of its capital stock; or purchase, redeem or otherwise acquire any of its or its Subsidiaries' securities or modify any of the terms of any such securities; (d) (i) create, incur, assume or permit to exist any long-term debt or any short-term debt for borrowed money other than under existing notes payable, lines of credit or other credit facilities or in the ordinary course of business, or with respect to its Wholly-Owned Subsidiaries in the ordinary course of business; (ii) assume, guarantee, endorse or otherwise become liable or responsible (whether directly, contingently or otherwise) for the obligations of any other Person except its Wholly-Owned Subsidiaries in the ordinary course of business or as otherwise may be contractually required and disclosed in the Sentech Disclosure Schedule; or (iii) make any loans, advances or capital contributions to, or investments in, any other Person except its Wholly-Owned Subsidiaries; (i) amend any Sentech Benefit Plan or (ii) except in the ordinary course of business consistent with usual practice or established policy (a) increase in any manner the rate of compensation of any of its directors, officers or other employees everywhere, except for increases in the ordinary course of business; (b) pay or agree to pay any bonus, pension, retirement allowance, severance or other employee benefit except as required under currently existing Sentech Benefit Plans disclosed in the Sentech Disclosure Schedule or in the ordinary course of business; or (c) amend, terminate or enter into any employment, consulting, severance, change in control or similar agreements or arrangements with any of its directors, officers or other employees; (f) enter into any material agreement, commitment or contract, except agreements, commitments or contracts for the purchase, sale or lease of goods or services in the ordinary course of business; (g) other than in the ordinary course of business, authorize, recommend, propose or announce an intention to authorize, recommend or propose, or enter into any Contract with respect to, any (i) plan of liquidation or dissolution, (ii) acquisition of a material amount of assets or securities, (iii) disposition or Encumbrance of a material amount of assets or securities, (iv) merger or consolidation or (v) material change in its capitalization; (h) change any material accounting or Tax procedure or practice; (i) take any action the taking of which, or knowingly omit to take any action the omission of which, would cause any of the representations and warranties herein to fail to be true and correct in all material respects as of the date of such action or omission as though made at and as of the date of such action or omission; (j) compromise, settle or otherwise modify any material claim or litigation not identified in the Sentech Disclosure Schedule; or (k) commit or agree to do any of the foregoing.

  • Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.

  • ADMINISTRATION OF THE CONTRACT 2.2.1 The Architect will provide administration of the Contract as hereinafter described. 2.2.2 The Architect will be the State's representative during construction and until final payment is due. The Architect will advise and consult with the State. The State's instructions to the Contractor shall be forwarded through the Architect. The Architect will have authority to act on behalf of the State only to the extent provided in the Contract Documents, unless otherwise modified by written instrument in accordance with Subparagraph 2.2.10. 2.2.3 The Architect will visit the site at intervals appropriate to the stage of construction to familiarize himself or herself generally with the progress and quality of the Work and to determine in general if the Work is proceeding in accordance with the Contract Documents. However, the Architect will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. On the basis of his or her on-site observations as an architect, he or she will keep the State informed of the progress of the Work, and will endeavor to guard the State against defects and deficiencies in the Work of the Contractor. 2.2.4 The Architect will not be responsible for and will not have control or charge of construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, and he or she will not be responsible for the Contractor's failure to carry out the Work in accordance with the Contract Documents. The Architect will not be responsible for or have control or charge over the acts or omissions of the Contractor, 2.2.5 The Architect shall at all times have access to the Work wherever it is in preparation and progress. The Contractor shall provide facilities for such access so the Architect may perform his or her functions under the Contract Documents.

  • CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Description of the procurement Under this Lot the supplier will provide the below packs (this list is not exhaustive): o Orthopaedic Day Case o Hip Arthroplasty o Knee Arthroplasty o Shoulder Arthroplasty o Arthroscopy- Knee, Hip, Shoulder, Ankle o Hand Surgery o Foot & Ankle Surgery o ACL (Anterior Cruciate Ligament) o Spine- Lumbar, Cervical TERMS AND CONDITIONS / ACTIVITY BASED INCOME (ABI) The terms and conditions of this Agreement and any resulting call-off contract is appended to the ITT. These terms include provisions requiring the payment by the supplier of an ABI management charge in consideration of the award of this Agreement, the management and administration by HTE of the overall contract structure and associated documentation, as well as the requirement to submit regular management information to HTE. SUBMISSION OF EXPRESSIONS OF INTEREST AND PROCUREMENT INFORMATION This exercise will be conducted on the HTE Bravo portal. Candidates wishing to be considered must register expressions of interest as follows: Register on the HTE portal at xxxxx://xxxxxxxxxxxxxxxxx.xxxxxxxxxxxxx.xx.xx. Login to the portal with username/password. Click the SQs/ITTs Open to All Suppliers link. These are the SQs/ITTs open to any registered supplier. Click on the relevant SQ/ ITT to access the content. Click the Express Interest button at the top of the page. This will move the SQ/ITT into your My SQs/My ITTs page. You can access any attachments by clicking Buyer Attachments in the SQ/ITT Details box. Follow the onscreen instructions to complete the SQ/ITT. Submit your reply using the Submit Response button at the top of the page. If you require any further advice, contact the Bravo e- Tendering Help Desk at xxxx@xxxxxxxxxxxxx.xx.xx. Sid4Gov HTE utilises the sid4gov supplier information database. Candidates should register on sid4gov at xxxxx://xxx0xxx.xxxxxxxxxxxxx.xxx.xx/organisation/register and submit their sid4gov company profile for publication on the database. Candidates already registered on sid4gov must ensure information is up to date. Where access to sid4gov is unavailable, please contact the sid4gov helpdesk at xxx0xxx@xxx.xxx.xxx.xx. Please note that sid4gov does not prepopulate any fields of the SQ on HTE's Bravo portal. Candidates must complete the Qualification & Technical Envelopes of the SQ in Bravo in full.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!