Release of Immediate Repair Deposit Sample Clauses

Open Split View

Download

Share

Cite

Release of Immediate Repair Deposit. The Immediate repair Deposit shall be releases in accordance with the terms of the Ply Gem Lease.

Sample 1

Save

Copy

Related to Release of Immediate Repair Deposit

• Release of Required Repair Funds Lender shall disburse to Borrower the Required Repair Funds from the Required Repair Account from time to time upon satisfaction by Borrower of each of the following conditions: (i) Borrower shall submit a written request for payment to Lender at least fifteen (15) days prior to the date on which Borrower requests such payment be made and specifies the Required Repairs to be paid, (ii) on the date such request is received by Lender and on the date such payment is to be made, no Default or Event of Default shall exist and remain uncured, (iii) Lender shall have received a certificate from Borrower (A) stating that all Required Repairs at the Property to be funded by the requested disbursement have been completed in good and workmanlike manner and in accordance with all applicable federal, state and local laws, rules and regulations, such certificate to be accompanied by a copy of any license, permit or other approval by any Governmental Authority required to commence and/or complete the Required Repairs, (B) identifying each Person that supplied materials or labor in connection with the Required Repairs performed at the Property to be funded by the requested disbursement under a contract in excess of $50,000, and (C) stating that each Person who has supplied materials or labor in connection with the Required Repairs to be funded by the requested disbursement has been paid in full or will be paid in full upon such disbursement, such certificate to be accompanied by lien waivers or other evidence of payment satisfactory to Lender, (iv) at Lender’s option, a title search for the Property indicating that the Property is free from all liens, claims and other encumbrances not previously approved by Lender, and (v) Lender shall have received such other evidence as Lender shall reasonably request that the Required Repairs at the Property to be funded by the requested disbursement have been completed and are paid for or will be paid upon such disbursement to Borrower. Lender shall not be required to make disbursements from the Required Repair Account with respect to the Property more than once each calendar month and such disbursement shall be made only upon satisfaction of each condition contained in this Section 7.1.2.

• Maintenance Repairs and Alterations 7.1 Lessee's Obligations. -------------------- (a) Subject to Lessor's obligations under Paragraphs 6.2(b), 6.3(a), 7.3, 9 and 40, Lessee shall keep in good order, condition and repair the non- structural elements of the Premises and every part thereof, (whether or not the need for such repairs occurs as a result of Lessee's use, any prior use, the elements or the age of such portion of the Premises) including, without limiting the generality of the foregoing, all exposed plumbing, heating and air conditioning, ventilating, electrical, lighting facilities and equipment within the Premises, fixtures, walls (interior and nonstructural elements of exterior), ceilings, floors, windows, doors, plate glass and skylights located within the Premises, and all driveways, parking lots and striping thereon, landscaping, exterior lighting, fences and signs located on the Premises and sidewalks and parkways adjacent to the Premises. If the cost of repairing an element of the Premises is covered by a warranty obtained by Lessor from a third party contractor, subcontractor, consultant or material supplier in connection with construction work performed on the Premises prior to the Effective Date, Lessor shall make available such warranty to Lessee and shall assign to Lessee Lessor's rights thereunder, provided that Lessee shall not take any action which shall invalidate any such warranty or derogate from Lessor's remedies or recourse thereunder. (b) Lessee shall maintain the Premises as provided in Paragraph 7. I (a) and in accordance with the requirements of all Laws and any covenants or restrictions as may from time to time be applicable to Lessee's specific manner of use of the Premises and the conduct and operation of Lessee's business. Lessee, in keeping the Premises in good order, condition and repair, shall exercise and perform good maintenance practices and any damage or deterioration shall not be deemed "ordinary wear and tear" if the same could have been prevented by good maintenance practice. Lessee's obligations shall include restorations, replacements or renewals when determined not to be due to ordinary wear and tear or when made necessary due to failure to perform proper maintenance. (c) If the term of this Lease, as the same may be extended or renewed, exceeds five (5) years, Lessor shall have the right to require Lessee to repaint the exterior of THE improvements. but not more often than once every five (5) years, as reasonably necessary. (d) Lessee's obligations under this Paragraph 7.1 shall not apply to replacement, repair or restoration of items which are Lessor's obligation to replace, repair or restore pursuant to the terms of Paragraph 6.3(a) (relating to Existing Defects) Paragraph 7.3(a) relating to structural repairs and certain replacements) Paragraph 9 (relating to destruction of the Premises) or Paragraph 14 (relating to condemnation of the Premises).

• Maintenance Repairs Utility Installations Trade Fixtures and Alterations (a) Section 8.1(a) is amended in its entirety to read as follows: Subject to the provisions of Sections 8.2, 10, and 15, Tenant shall, at Tenant's sole cost and expense and at all times, keep the Building Complex and every part thereof in good order, condition and repair (whether or not the need for such repairs occurs as a result of Tenant's use, any prior use, the elements or the age of such portion of the Building Complex), including, without limiting the generality of the foregoing, plumbing, electrical lighting facilities, boilers, fired or unfired pressure vessels, fire hose connections, fixtures, interior walls, exterior walls, roof, ceilings, floors, windows, doors, plate glass, and skylights, parking areas and lighting, driveways, sidewalks, landscaping, irrigation systems, and subject to Section 8.1(b) below, heating, air conditioning and ventilating systems, but excluding any items which are the responsibility of Landlord pursuant to Section 8.2 below. Tenant, in keeping the Building Complex in good order, condition and repair, shall exercise and perform good maintenance practices, including, without limitation, providing janitorial services to the Building Complex substantially equivalent to those attached hereto as Exhibit I and, snow, ice and trash removal service. Tenant's obligations shall include restorations, replacements or renewals when necessary to keep the Building Complex and all improvements thereon or a part thereof in good order, condition and state of repair. (b) Section 8.1(b) is amended in its entirety to read as follows: Tenant shall procure and pay the cost of a contract for maintenance of the heating, air conditioning and ventilating systems for the Building Complex with a reputable contractor licensed in the State of Colorado and reasonably satisfactory to Landlord. (c) Section 8.1(c) is amended to replace, in both places where it is used, the word "Premises" with the words "Building Complex" and to add the words "including, without limitation, the Premises," before the words "after twenty". (d) Section 8.2 is amended in its entirety to read as follows:

• Required Repairs Borrower shall perform all of the repairs (on an Individual Property by Individual Property basis) at the applicable Individual Properties, as more particularly set forth on Schedule 5.1.32 hereto (such repairs hereinafter referred to as “Required Repairs”) (i) in compliance with all applicable Legal Requirements, (ii) in a Lien-free, good and workmanlike manner and (iii) prior to the date set forth on Schedule 5.1.32 with respect to such Required Repairs (each such date, a “Required Repair Deadline”). It shall constitute an Event of Default if Borrower does not complete each Required Repair by the applicable Required Repair Deadline, provided that, if Borrower shall have been unable to complete a Required Repair by the applicable Required Repair Deadline, after using commercially reasonable efforts to do so, including, without limitation, if caused by delays due to weather or force majeure, such Required Repair Deadline shall be automatically extended solely as to such Required Repair to permit Borrower to complete such Required Repair so long as Borrower is at all times thereafter diligently and expeditiously proceeding to complete the same. Notwithstanding the foregoing, to the extent any Required Repair is the responsibility of a Tenant pursuant to a Lease, Borrower shall be obligated only to use commercially reasonably efforts to have such Tenant complete such Required Repair on or prior to the Required Repair Deadline.

• Tenant’s Repairs Subject to Section 13 hereof, Tenant, at its expense, shall repair, replace and maintain in good condition all portions of the Premises, including, without limitation, entries, doors, ceilings, interior windows, interior walls, and the interior side of demising walls. Such repair and replacement may include capital expenditures and repairs whose benefit may extend beyond the Term. Should Tenant fail to make any such repair or replacement or fail to maintain the Premises, Landlord shall give Tenant notice of such failure. If Tenant fails to commence cure of such failure within 10 days of Landlord’s notice, and thereafter diligently prosecute such cure to completion, Landlord may perform such work and shall be reimbursed by Tenant within 10 days after demand therefor; provided, however, that if such failure by Tenant creates or could create an emergency, Landlord may immediately commence cure of such failure and shall thereafter be entitled to recover the costs of such cure from Tenant. Subject to Sections 17 and 18, Tenant shall bear the full uninsured cost of any repair or replacement to any part of the Project that results from damage caused by Tenant or any Tenant Party and any repair that benefits only the Premises. Notwithstanding anything to the contrary contained in this Lease, as of the Rent Commencement Date, the maintenance and repair obligations for the Premises shall be allocated between Landlord and Tenant as set forth on Exhibit H attached hereto. The maintenance obligations allocated to Tenant pursuant to Exhibit H (the “Tenant Maintenance Obligations”) shall be performed by Tenant at Tenant’s sole cost and expense. The Tenant Maintenance Obligations shall include the procurement and maintenance of contracts, in form and substance reasonably satisfactory to Landlord, with copies to Landlord upon Landlord’s written request, for and with contractors reasonably acceptable to Landlord specializing and experienced in the respective Tenant Maintenance Obligations. Notwithstanding anything to the contrary contained herein, the scope of work of any such contracts entered into by Tenant pursuant to this paragraph shall, at a minimum, comply with manufacturer’s recommended maintenance procedures for the optimal performance of the applicable equipment. Landlord shall, notwithstanding anything to the contrary contained in this Lease, have no obligation to perform any Tenant Maintenance Obligations. The Tenant Maintenance Obligations shall not include the right or obligation on the part of Tenant to make any structural and/or capital repairs or improvements to the Project, and Landlord shall continue, as part of Operating Expenses, to be responsible, as provided in Section 13, for capital repairs and replacements required to be made to the Project. If Tenant fails to maintain any portion of the Premises for which Tenant is responsible as part of the Tenant Maintenance Obligations in a manner reasonably acceptable to Landlord within the requirements of this Lease, Landlord shall have the right, but not the obligation, to provide Tenant with written notice thereof and to assume the Tenant Maintenance Obligations if Tenant does not cure Tenant’s failure within 10 days after receipt of such notice.

• Alterations, Additions, and Improvements Subject to the provisions of this Article IV, Lessee may make any alterations, additions, improvements or other changes to the Premises and the Relevant Assets as may be necessary or useful in connection with the operation of the Relevant Assets (collectively, the “Additional Improvements”). If such Additional Improvements require alterations, additions or improvements to the Premises or any of the Shared Access Facilities, Lessee shall notify Lessor in writing in advance and the parties shall negotiate in good faith any increase to the fees paid by Lessee under the Site Services Agreement by Lessee or otherwise provide for reimbursement of any material increase in cost (if any) to Lessor under the Site Services Agreement that results from any modifications to the Premises or the Shared Access Facilities necessary to accommodate the Additional Improvements, or as otherwise mutually agreed by the parties. Any alteration, addition, improvement or other change to the Premises, Relevant Assets or Additional Improvements (and, if agreed by Lessee and Lessor, to the Shared Access Facilities) by Lessee shall be made in a good and workmanlike manner and in accordance with all applicable Laws. The Relevant Assets and all Additional Improvements shall remain the property of Lessee and shall be removed by Lessee within one (1) year after termination of this Lease (provided that such can be removed by Lessee without unreasonable damage or harm to the Premises) or, at Lessee’s option exercisable by notice to Lessor, surrendered to Lessor upon the termination of this Lease. Lessee shall not have the right or power to create or permit any lien of any kind or character on the Premises by reason of repair or construction or other work. In the event any such lien is filed against the Premises, Lessee shall cause such lien to be discharged or bonded within thirty (30) days of the date of filing thereof.

• Release of Escrow Subject to the provisions of Section 4.2, the Escrow Agent shall release the Company Documents and Subscriber Documents as follows: (a) On the Closing Date, the Escrow Agent will simultaneously release the Company Documents to the Subscriber and release the Subscriber Documents to the Company except that the Due Diligence Fee will be released to the Due Diligence Fee Recipient and the Legal Fees will be released to the Subscriber’s attorneys. (b) All funds to be delivered to the Company shall be delivered on the Closing Date pursuant to the wire instructions to be provided in writing by the Company to the Escrow Agent. (c) Notwithstanding the above, upon receipt by the Escrow Agent of joint written instructions ("Joint Instructions") signed by the Company and the Subscriber, it shall deliver the Company Documents and Subscriber Documents in accordance with the terms of the Joint Instructions. (d) Notwithstanding the above, upon receipt by the Escrow Agent of a final and non-appealable judgment, order, decree or award of a court of competent jurisdiction (a "Court Order"), the Escrow Agent shall deliver the Company Documents and Subscriber Documents in accordance with the Court Order. Any Court Order shall be accompanied by an opinion of counsel for the party presenting the Court Order to the Escrow Agent (which opinion shall be satisfactory to the Escrow Agent) to the effect that the court issuing the Court Order has competent jurisdiction and that the Court Order is final and non-appealable.

• Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.

• Release of Escrow Funds The Escrow Funds shall be paid by the Escrow Agent in accordance with the following: (a) In the event that the Company advises the Escrow Agent in writing that the Offering has been terminated (the “Termination Notice”), the Escrow Agent shall promptly return the funds paid by each Investor to such Investor without interest or offset. (b) At each Closing, the Company and the Placement Agent shall provide the Escrow Agent with written instructions regarding the disbursement of the Escrow Funds in accordance with Exhibit A attached hereto and made a part hereof and signed by the Company and the Placement Agent (the “Disbursement Instructions”). (c) If by 5:00 P.M. Eastern time on the Final Termination Date, the Escrow Agent has not received written Disbursement Instructions from the Company and Placement Agent regarding the disbursement of the Escrow Funds in the Escrow Account, if any, then the Escrow Agent shall promptly return such Escrow Funds, if any, to the Investors without interest or offset. The Escrow Funds returned to the Investors shall be free and clear of any and all claims of the Escrow Agent. (d) The Escrow Agent shall not be required to pay any uncollected funds or any funds that are not available for withdrawal. (e) The Placement Agent or the Company will provide the Escrow Agent with the payment instructions for each Investor, to whom the funds should be returned in accordance with this section. (f) In the event that Escrow Agent makes any payment to any other party pursuant to this Escrow Agreement and for any reason such payment (or any portion thereof) is required to be returned to the Escrow Account or another party or is subsequently invalidated, declared to be fraudulent or preferential, set aside and/or required to be repaid to a receiver, trustee or other party under any bankruptcy or insolvency law, other federal or state law, common law or equitable doctrine, then the recipient party shall repay to the Escrow Agent upon written request the amount so paid to it. (g) The Escrow Agent shall, in its sole discretion, comply with judgments or orders issued or process entered by any court with respect to the Escrow Amount, including without limitation any attachment, levy or garnishment, without any obligation to determine such court's jurisdiction in the matter and in accordance with its normal business practices. If the Escrow Agent complies with any such judgment, order or process, then it shall not be liable to any of the Parties or any other person by reason of such compliance, regardless of the final disposition of any such judgment, order or process. (h) Each Party understands and agrees that Escrow Agent shall have no obligation or duty to act upon a written direction delivered to Escrow Agent for the disbursement of all or part of the Escrow Amount under this Agreement (a “Written Direction”) if such Written Direction is not (i) in writing, (ii) signed by representatives of both Parties listed in Schedule II to this Agreement, in each case, each such individual an “Authorized Representative” of such Party), and (iii) delivered to, and able to be authenticated by, Escrow Agent in accordance with Section 1.4 below. (i) Upon request by any Party, the Escrow Agent set up each Party with on-line access to the account(s) established pursuant to this Agreement, which each Party can use to view and verify transaction on such account(s). (j) A Party may specify in a Written Direction whether such Escrow Amount shall be disbursed by way of wire transfer or check. If the written notice for the disbursement of funds does not so specify the disbursement means, Escrow Agent may disburse the Escrow Amount by wire transfer.

• Disbursement of the Tenant Improvement Allowance Except as otherwise set forth in this Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord (each of which disbursements shall be made pursuant to Landlord’s disbursement process, which disbursement process shall require the Architect to make field verifications and written certifications as required by Landlord in connection with Landlord’s disbursements to Contractor (as defined below)) only for the following items and costs (collectively the “Tenant Improvement Allowance Items”): (a) Payment of (i) the fees of the Architect and the Engineers (as defined below), (ii) charges for Landlord’s construction consultant and Building engineer, and (iii) the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the Construction Drawings (as defined below); (b) The payment of plan check, permit and license fees relating to construction of the Tenant Improvements; (c) The cost of construction of the Tenant Improvements, including, without limitation, any cost of after-hours freight elevator usage; (d) The cost of any changes in the Base, Shell, and Core when such changes are required by the Construction Drawings, such cost to include all direct architectural and/or engineering fees and expenses incurred in connection therewith; (e) The cost of any changes to the Construction Drawings or Tenant Improvements required by applicable laws and building codes (collectively, “Code”); (f) Sales and use taxes; and (g) All other costs to be expended by Landlord in connection with the construction of the Tenant Improvements. In no event shall the Tenant Improvement Allowance Items include any costs of procuring or installing in the Premises any trade fixtures, equipment, furniture, furniture partitions or systems, furnishings, telephone, telecommunications, data and security wiring, cabling and equipment, or other personal property (“Personal Property”) to be used in the Premises by Tenant, and the cost of such Personal Property shall be paid by Tenant.