Improvements to Premises Lessee shall take the Premises in its "as-is" condition for the Extended Term except for certain Leasehold Improvements (herein so called) to the Premises which shall be completed in accordance with the specifications attached hereto as Exhibit A (the "Approved Plans"), which have been approved by both Lessor and Lessee. Lessor shall cause the Leasehold Improvements to be installed or constructed in accordance with the Approved Plans by Lessor's contractor. So long as no Event of Default (or event which with notice or lapse of time could become an Event of Default) has occurred under the Lease, Lessor agrees to provide Lessee an allowance equal to One Hundred Fifty-Three Thousand One Hundred Nineteen and No/100 Dollars ($153,119.00) (the "Improvement Allowance"), which allowance is to be used solely for completion of the Leasehold Improvements in accordance with the Approved Plans, and an additional allowance equal to Three Thousand Two Hundred and No/100 Dollars ($3,200.00) (the "Architectural Allowance"), which allowance is to be used solely for space planning and design services for the Premises. In the event that any alterations or modifications to the Premises are required in order to comply with applicable law, including, without limitation, the Americans with Disabilities Act of 1990, as amended, or the State of Texas equivalent laws and regulations, the cost of any such alterations or modifications shall be satisfied out of the Improvement Allowance. The cost of the Leasehold Improvements and the space planning and design fees is to be paid by Lessor out of the Improvement Allowance and the Architectural Allowance, respectively. Any completed work (labor or materials) outside the scope of the Approved Plans or the cost of which is in excess of the Improvement Allowance or the Architectural Allowance, as the case may be, shall be at Lessee's sole cost and will be billed to Lessee by Lessor and will be due and payable within ten (10) days after Lessee's receipt of an invoice therefor. Notwithstanding the foregoing, Lessee will not be liable for work outside the scope of the Approved Plans or excess costs over the amount of the Improvement Allowance or the Architectural Allowance unless Lessee has consented in writing to such work outside the scope of the Approved Plans or excess costs prior to the commencement of such work or the incurring of such excess costs. Any portion of the Improvement Allowance or the Architectural Allowance remaining upon the completion of the Leasehold Improvements shall be deemed forfeited by Lessee. Lessor further acknowledges and agrees that Section 4.07 of the Lease is hereby amended to provide that Lessee shall not be required to surrender possession of the Premises to Lessor "in the same condition as when received", but rather shall be entitled to surrender possession of the Premises in the same condition as exists upon the completion of the Leasehold Improvements described in Paragraph 3 above, subject to any and all other requirements set forth in Section 4.07 of the Lease.
Maintenance of Common Areas Landlord shall maintain the Common Areas in good order, condition and repair and shall operate the Project and Park, in Landlord’s reasonable discretion, as a first-class industrial/commercial real property development. Tenant shall pay, on a monthly basis, Tenant’s Pro-Rata Share (as determined below) of the costs specified below and incurred by Landlord for the operation and maintenance of the Common Areas in the manner stated in Section 4.05(e). Common Area costs include, but are not limited to, costs and expenses for the following: the emergency generator gardening and landscaping; utilities, water, storm water and sanitary sewage charges; maintenance of signs (other than tenants’ signs); premiums for liability, property damage, fire and other types of casualty insurance on the Common Areas and all Common Area improvements; all Real Property Taxes levied on or attributable to the Common Areas and all Common Area improvements; all personal property taxes levied on or attributable to personal property used in connection with the Common Areas; straight-line depreciation on personal property owned by Landlord which is consumed or used in the operation or maintenance of the Common Areas; rental or lease payments paid by Landlord for rented or leased personal property used in the operation or maintenance of the Common Areas; fees for required licenses and permits; repairing, resurfacing and repaying, striping or restriping, maintaining, painting, lighting, cleaning, refuse removal, security and similar items; sales taxes; business and occupations taxes; and a reasonable fee to Landlord for Landlord’s supervision of the Common Areas and Project management (not to exceed three percent (3%) of the Base Rents of the Project for the calendar year). Landlord may cause any or all of such services to be provided by third parties and the cost of such services shall be included in Common Area costs. Common Area costs shall not include depreciation of real property which forms part of the Common Areas. The parties acknowledge and agree that the costs for maintaining the emergency generator shall be divided pro-rata among the four buildings to which it is connected.
Premises Parking and Common Areas 2.1 Letting Lessor hereby leases to Lessee, and Lessee hereby leases from Lessor, the Premises, for the term, at the rental, and upon all of the terms covenants and conditions set forth in this Lease. Unless otherwise provided herein, any statement of square footage set forth in this Lease, or that may have been used in calculating rental and/or Common Area Operating Expenses, is an approximation which Lessor and Lessee agree is reasonable and the rental and Lessee's Share (as defined in Paragraph 1.6(b)) based thereon is not subject to revision whether or not the actual square footage is more or less.
Payment for Improvements If payment is made directly to contractors, Tenant shall (i) comply with Landlord's requirements for final lien releases and waivers in connection with Tenant's payment for work to contractors, and (ii) sign Landlord's standard contractor's rules and regulations. If Tenant orders any work directly from Landlord, Tenant shall pay to Landlord an amount equal to five percent of the cost of such work to compensate Landlord for all overhead, general conditions, fees and other costs and expenses arising from Landlord's involvement with such work. If Tenant does not order any work directly from Landlord, Tenant shall reimburse Landlord for Landlord's reasonable, actual, out-of-pocket costs and expenses actually incurred in connection with Landlord's review of such work.
Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.
Tenant's Improvements If the Lessor is the Insuring Party, the Lessor shall not be required to insure Lessee Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease. If Lessee is the Insuring Party, the policy carried by Lessee under this Paragraph 8.3 shall insure Lessee Owned Alterations and Utility Installations.
Common Area Maintenance Landlord will maintain or cause to be maintained the Common Areas and Tenant will reimburse Landlord for Tenant’s prorata share of the cost of such maintenance as hereinafter provided.
(a) Common area maintenance costs and expenses shall be determined in accordance with generally accepted accounting principles consistently applied and allocated to any particular calendar year on the accrual method of accounting. Such costs and expenses shall include, but shall not be limited to upkeep, exterior painting, repairs, replacements and improvements in the Common Areas, snow removal, sweeping and cleanup, depreciation allowance on any machinery and equipment owned by Landlord and used in connection therewith, utility services including fire line water service charges, premiums for public liability, property damage and fire insurance including the Common Areas, any real estate tax and/or tax consultant expense incurred for the purpose of maintaining equitable tax assessments on the Development, all property taxes or assessments levied or assessed against all Common Areas, which, if not separately assessed, shall be determined, for land, by the ratio of land area designated for Common Area use to the total land area in the Development and, for improvements, on a fair and equitable allocation among the various improvements in the Development, giving weight to the factors which determine the amount of the real property tax or assessment in question. In addition, such costs shall include administrative costs equal to ten percent (10%) of the total cost paid or incurred by Landlord under this paragraph.
(b) Tenant shall pay as additional rent to Landlord, Tenant’s prorata share of such Common Area expenses in the following manner:
(1) From and after the date the minimum rental provided for herein has commenced, but subject to adjustment as hereinafter in this subparagraph (1) provided, Tenant shall pay Landlord in advance on the first day of each calendar month during the term of this Lease an estimated and adjustable amount covering Tenant’s proportionate share of common area services and expenses, which amount may be adjusted by Landlord by notice to Tenant at the end of any calendar month on the basis of Landlord’s experience and reasonably anticipated costs. (See Lease Rider “A” Building Expenses attached hereto and incorporated herein.)
(2) Within thirty (30) days following the end of each calendar year, Landlord shall furnish Tenant a statement covering the calendar year just expired, showing the total operating costs, the amount of Tenant’s prorata share of such Common Area expenses for such calendar year and the payments made by Tenant with respect to such calendar year as set forth in subparagraph (b) I. If Tenant’s prorata share of such Common Area expenses exceeds Tenant’s payments so made, Tenant shall pay Landlord the deficiency within ten (10) days after receipt of such statement. If said payments exceed Tenant’s prorata share of such Common Area expenses, Tenant shall be entitled to offset the excess against payments next thereafter to become due Landlord as set forth in said subparagraph (b) I. Tenant’s pro-rata share of the total Common Area expenses for the previous calendar year shall be that portion of all such expenses which is equal to the proportion which the number of square feet of gross leasable area in the Demised Premises bears to the total number of square feet of gross leasable area of buildings in the entire Development which are from time to time completed and occupied as of the commencement of each calendar year.
Premises Building Project and Common Areas 1.1 Premises, Building, Project and Common Areas.
LANDLORD’S MAINTENANCE AND REPAIR Subject to Section 7.1 and Article XI, Landlord shall provide service, maintenance and repair with respect to any air conditioning, ventilating or heating equipment which serves the Premises (exclusive, however, of supplemental HVAC equipment serving only the Premises), and shall maintain in good repair the roof, foundations, footings, the exterior surfaces of the exterior walls of the Building (including exterior glass), and the structural, electrical and mechanical systems, except that Tenant at its expense shall make all repairs which Landlord deems reasonably necessary as a result of the act or negligence of Tenant, its agents, employees, invitees, subtenants or contractors. Landlord shall have the right to employ or designate any reputable person or firm, including any employee or agent of Landlord or any of Landlord's affiliates or divisions, to perform any service, repair or maintenance function. Landlord need not make any other improvements or repairs except as specifically required under this Lease, and nothing contained in this Section shall limit Landlord's right to reimbursement from Tenant for maintenance, repair costs and replacement costs as provided elsewhere in this Lease. Tenant understands that it shall not make repairs at Landlord's expense or by rental offset. Tenant further understands that Landlord shall not be required to make any repairs to the roof, foundations, footings, the exterior surfaces of the exterior walls of the Building (excluding exterior glass), or structural, electrical or mechanical systems unless and until Tenant has notified Landlord in writing of the need for such repair and Landlord shall have a reasonable period of time thereafter to commence and complete said repair, if warranted. All costs of any maintenance, repairs and replacement on the part of Landlord provided hereunder shall be considered part of Project Costs. Tenant further agrees that if Tenant fails to report any such need for repair in writing within sixty (60) days of its discovery by Tenant, Tenant shall be responsible for any costs and expenses and other damages related to such repair which are in excess of those which would have resulted had such need for repair been reported to Landlord within such sixty (60) day period.
LANDLORD'S MAINTENANCE Subject to the provisions of Articles 4 and 14, Landlord shall, as an Operating Expense, maintain and make necessary repairs to the foundations, roofs, exterior walls, and the structural elements of the Building, the electrical, plumbing, heating, ventilating, air-conditioning, mechanical, communication, security and the fire and life safety systems of the Building and those corridors, washrooms and lobbies which are Common Areas of the Building, except that: (a) Landlord shall not be responsible for the maintenance or repair of any floor or wall coverings in the Premises or any of such systems which are located within the Premises and are supplemental or special to the Building’s standard systems; and (b) the cost of performing any of said maintenance or repairs whether to the Premises or to the Building caused by the negligence of Tenant, its employees, agents, servants, licensees, subtenants, contractors or invitees, shall be paid by Tenant, subject to the waivers set forth in Section 16.4. Landlord shall not be liable to Tenant for any expense, injury, loss or damage resulting from work done in or upon, or in connection with the use of, any adjacent or nearby building, land, street or alley.
