Building Codes The following Building Codes, in the latest editions approved by the Georgia Department of Community Affairs, shall be used. (See O.C.G.A. §8-2-20.) The Design Professional will designate any additional codes or special modifications in the Supplementary General Conditions. As of the year 2000, these codes are published jointly by the Southern Building Code Congress International, the International Code Council, the Building Officials and Code Administrators, International, and the International Conference of Building Officials, and are commonly referred to as the International Building Codes. 1.7.1.3.1 Georgia State Minimum Standard Building Code (International Building Code, 2000 Edition) with Georgia Amendments. 1.7.1.3.2 Georgia State Minimum Standard Mechanical Code (International Mechanical Code, 2000 Edition), with Georgia Amendments. 1.7.1.3.3 Georgia State Minimum Standard Gas Code (International Fuel Gas Code, 2000 Edition), with Georgia Amendments. 1.7.1.3.4 Georgia State Minimum Standard Plumbing Code (International Plumbing Code, 2000 Edition), with Georgia Amendments. 1.7.1.3.5 Georgia State Minimum Standard Electric Code (National Electrical Code, 2002 Edition), with Georgia Amendments. 1.7.1.3.6 Georgia State Minimum Standard Energy Code (International Energy Conservation Code, 2000 Edition), with Georgia Amendments. 1.7.1.3.7 Georgia State Minimum Standard Fire Prevention Code (International Fire Code, 2003 Edition), with Georgia Amendments.
COMPLIANCE WITH COVENANTS, RESTRICTIONS AND BUILDING CODE Lessor warrants that any improvements (other than those constructed by Lessee or at Lessee's direction) on or in the Premises which have been constructed or installed by Lessor or with Lessor's consent or at Lessor's direction shall comply with all applicable covenants or restrictions of record and applicable building codes, regulations and ordinances in effect on the Commencement Date. Lessor further warrants to Lessee that Lessor has no knowledge of any claim having been made by any governmental agency that a violation or violations of applicable building codes, regulations, or ordinances exist with regard to the Premises as of the Commencement Date. Said warranties shall not apply to any Alterations or Utility Installations (defined in Paragraph 7.3(a)) made or to be made by Lessee. If the Premises do not comply with said warranties, Lessor shall, except as otherwise provided in this Lease, promptly after receipt of written notice from Lessee given within six (6) months following the Commencement Date and setting forth with specificity the nature and extent of such non-compliance, take such action, at Lessor's expense, as may be reasonable or appropriate to rectify the non-compliance. Lessor makes no warranty that the Permitted Use in Paragraph 1.8 is permitted for the Premises under Applicable Laws (as defined in Paragraph 2.4).
Construction or Rehabilitation of Mortgaged Property No Mortgage Loan was made in connection with the construction or rehabilitation of a Mortgaged Property or facilitating the trade-in or exchange of a Mortgaged Property;
PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:
COMPLIANCE WITH NEW YORK STATE INFORMATION SECURITY BREACH AND NOTIFICATION ACT Contractor shall comply with the provisions of the New York State Information Security Breach and Notification Act (General Business Law Section 899-aa; State Technology Law Section 208).
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Environmental and Safety Matters (a) The Company and its Subsidiaries have at all times complied in all material respects with all applicable Environmental and Safety Requirements, which compliance has included obtaining and complying in all material respects at all times with all material permits, licenses and other authorizations required pursuant to Environmental and Safety Requirements for the occupation of their facilities and the operation of their respective businesses. (b) Except as set forth in Section 4.27(b) of the Disclosure Schedule, since February 19, 2008, neither the Company nor any of its Subsidiaries has received any notice, report, order, or directive regarding any, and is not subject to any litigation, proceedings or order regarding any, actual or alleged violation of Environmental and Safety Requirements, or any liability or potential liability arising under Environmental and Safety Requirements, in effect prior to and as of the date of the applicable Closing, relating to the business, the Owned Real Property or Leased Real Property. (c) Except as set forth in Section 4.27(c) of the Disclosure Schedule, neither the Company nor any of its Subsidiaries has treated, stored, disposed of, arranged for or permitted the disposal of, transported, handled, released, or exposed any Person to, any substance (including without limitation any hazardous substance), owned or operated any property or facility which is or has been contaminated by any substance, so as to give rise to any current or future liabilities under any Environmental and Safety Requirements in effect at the time of such treatment, storage, disposal, transportation, handling, release or exposure. (d) Except as set forth in Section 4.27(d) of the Disclosure Schedule, neither the Company nor any of its Subsidiaries has assumed, undertaken, or provided any indemnity with respect to, any liability of any other Person relating to Environmental and Safety Requirements. (e) The Company has furnished to Investor true and correct copies of all environmental audits, reports, assessments and all other documents materially bearing on environmental, health or safety liabilities relating to the past or current operations or facilities of the Company and all of its Subsidiaries, in each case which are in its possession or under its reasonable control.
SURVIVAL OF COVENANTS/SUPERSESSION All covenants, agreements, representations and warranties made herein and in or pursuant to the Initial Purchase Agreement and each Additional Purchase Agreement executed pursuant to these Master Terms shall survive the consummation of the acquisition of the Purchased Loans provided for in the related Purchase Agreement. All covenants, agreements, representations and warranties made or furnished pursuant hereto by or on behalf of SLM ECFC shall bind and inure to the benefit of any successors or assigns of Funding and the Interim Eligible Lender Trustee on behalf of Funding and shall survive with respect to each Purchased Loan. Each Purchase Agreement supersedes all previous agreements and understandings between Funding and SLM ECFC with respect to the subject matter thereof. These Master Terms and any Purchase Agreement may be changed, modified or discharged, and any rights or obligations hereunder may be waived, only by a written instrument signed by a duly authorized officer of the party against whom enforcement of any such waiver, change, modification or discharge is sought. The waiver by Funding of any covenant, agreement, representation or warranty required to be made or furnished by SLM ECFC or the waiver by Funding of any provision herein contained or contained in any Purchase Agreement shall not be deemed to be a waiver of any breach of any other covenant, agreement, representation, warranty or provision herein contained, nor shall any waiver or any custom or practice which may evolve between the parties in the administration of the terms hereof or of any Purchase Agreement, be construed to lessen the right of Funding to insist upon the performance by SLM ECFC in strict accordance with said terms.
Project or Building Name and Signage Landlord shall have the right at any time to change the name of the Project or Building and to install, affix and maintain any and all signs on the exterior and on the interior of the Project or Building as Landlord may, in Landlord’s sole discretion, desire. Tenant shall not use the name of the Project or Building or use pictures or illustrations of the Project or Building in advertising or other publicity or for any purpose other than as the address of the business to be conducted by Tenant in the Premises, without the prior written consent of Landlord.
Data Protection Impact Assessment If, pursuant to Data Protection Law, Customer (or its Controllers) are required to perform a data protection impact assessment or prior consultation with a regulator, at Customer’s request, SAP will provide such documents as are generally available for the Cloud Service (for example, this DPA, the Agreement, audit reports or certifications). Any additional assistance shall be mutually agreed between the Parties.
