OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.
Right to Seek Assurance The Transfer Agent may refuse to transfer, exchange or redeem shares of the Fund or take any action requested by a shareholder until it is satisfied that the requested transaction or action is legally authorized or until it is satisfied there is no basis for any claims adverse to the transaction or action. It may rely on the provisions of the Uniform Act for the Simplification of Fiduciary Security Transfers or the Uniform Commercial Code. The Company shall indemnify the Transfer Agent for any act done or omitted to be done in reliance on such laws or for refusing to transfer, exchange or redeem shares or taking any requested action if it acts on a good faith belief that the transaction or action is illegal or unauthorized.
Right to Set Off Notwithstanding anything to the contrary in this License Agreement, each Party has the right at all times to retain and set off against all amounts due and owing to the other Party as determined in a final judgment any damages recovered by such Party for any Losses incurred by such Party.
Right to Cure Notwithstanding anything to the contrary contained in Section 7.01, in the event that the Borrower fails (or, but for the operation of this Section 7.03, would fail) to comply with the requirements of the Financial Covenant, from the last day of the applicable fiscal quarter until the expiration of the 10th Business Day subsequent to the date the certificate calculating such Financial Covenant is required to be delivered pursuant to Section 5.04(c), Holdings, the Borrower and any Parent Entity shall have the right to issue Permitted Cure Securities for cash or otherwise receive cash contributions to the capital of such entities, and in each case, to contribute any such cash to the capital of the Borrower (collectively, the “Cure Right”), and upon the receipt by the Borrower of such cash (the “Cure Amount”), pursuant to the exercise of the Cure Right, the Financial Covenant shall be recalculated giving effect to a pro forma adjustment by which EBITDA shall be increased with respect to such applicable quarter and any four-quarter period that contains such quarter, solely for the purpose of measuring the Financial Covenant and not for any other purpose under this Agreement, by an amount equal to the Cure Amount; provided, that (i) in each four consecutive fiscal quarter period there shall be at least two fiscal quarters in which a Cure Right is not exercised, (ii) a Cure Right shall not be exercised more than five times during the term of the Revolving Facilities, (iii) for purposes of this Section 7.03, the Cure Amount shall be no greater than the amount required for purposes of complying with the Financial Covenant and (iv) there shall be no pro forma reduction in Indebtedness with the proceeds of the exercise of the Cure Right for determining compliance with the Financial Covenant for the fiscal quarter in respect of which such Cure Right is exercised (either directly through prepayment or indirectly as a result of the netting of Unrestricted Cash) (other than, for future periods, with respect to any portion of such Cure Amount that is used to repay Term Loans or to prepay Revolving Facility Loans to the extent accompanied by permanent reductions in Revolving Facility Commitments). If, after giving effect to the adjustments in this Section 7.03, the Borrower shall then be in compliance with the requirements of the Financial Covenant, the Borrower shall be deemed to have satisfied the requirements of the Financial Covenant as of the relevant date of determination with the same effect as though there had been no failure to comply therewith at such date, and the applicable breach or default of the Financial Covenant that had occurred shall be deemed cured for the purposes of this Agreement.
Limitation on Duty to Collect Custodian shall not be required to enforce collection, by legal means or otherwise, of any money or property due and payable with respect to Securities held for the Fund if such Securities are in default or payment is not made after due demand or presentation.
Right to Cancel You have a right to cancel this Agreement for a period of fourteen (14) days commencing on the date on which this Agreement is concluded or the date on which you receive this Agreement (whichever is later) (the “Cancellation Period”). Should you wish to cancel this Agreement within the Cancellation Period, you should send notice electronically to xxxxxxx@xxxxxxxxxxx.xxx. Cancelling this Agreement within the Cancellation Period will not cancel any Transaction entered into by you during the Cancellation Period. If you fail to cancel this Agreement within the Cancellation Period, you will be bound by its terms but you may terminate this Agreement in accordance with Clause 17 (Termination without Default).
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
RIGHT TO WITHHOLD PAYMENT LEA may withhold payment to CONTRACTOR when: (a) CONTRACTOR has failed to perform, in whole or in part, under the terms of this contract; (b) CONTRACTOR has billed for services rendered on days other than billable days of attendance or for days when student was not in attendance and/or did not receive services; (c) CONTRACTOR was overpaid by XXX as determined by inspection, review, and/or audit of its program, work, and/or records; (d) CONTRACTOR has failed to provide supporting documentation with an invoice, as required by EC 56366(c)(2); (e) education and/or related services are provided to students by personnel who are not appropriately credentialed, licensed, or otherwise qualified; (f) LEA has not received prior to school closure or contract termination, all documents concerning one or more students enrolled in CONTRACTOR’s educational program; (g) CONTRACTOR fails to confirm a student’s change of residence to another district or confirms the change or residence to another district, but fails to notify LEA within five (5) days of such confirmation; or (h) CONTRACTOR receives payment from Medi-Cal or from any other agency or funding source for a service provided to a student. It is understood that no payments shall be made for any invoices that are not received by six (6) months following the close of the prior fiscal year, for services provided in that year. Final payment to CONTRACTOR in connection with the cessation of operations and/or termination of a Master Contract will be subject to the same documentation standards described for all payment claims for regular ongoing operations. In addition, final payment may be withheld by the LEA until completion of a review or audit, if deemed necessary by the LEA. Such review or audit will be completed within ninety (90) days. The final payment may be adjusted to offset any previous payments to the CONTRACTOR determined to have been paid in error or in anticipation of correction of documentation deficiencies by the CONTRACTOR that remain uncorrected.
(a) the value of the service CONTRACTOR failed to perform; (b) the amount of overpayment; (c) the entire amount of the invoice for which satisfactory documentation has not been provided by CONTRACTOR; (d) the amount invoiced for services provided by the individual not appropriately credentialed, licensed, or otherwise qualified; (e) the proportionate amount of the invoice related to the applicable pupil for the time period from the date the violation occurred and until the violation is cured; or (f) the amount paid to CONTRACTOR by Medi-Cal or another agency or funding source for the service provided to the student. If LEA determines that cause exists to withhold payment to CONTRACTOR, LEA shall, within ten (10) business days of this determination, provide to CONTRACTOR written notice that LEA is withholding payment. Such notice shall specify the basis or bases for LEA’s withholding payment and the amount to be withheld. Within thirty (30) days from the date of receipt of such notice, CONTRACTOR shall take all necessary and appropriate action to correct the deficiencies that form the basis for XXX’s withholding payment or submit a written request for extension of time to correct the deficiencies. Upon receipt of CONTRACTOR’s written request showing good cause, XXX shall extend CONTRACTOR’s time to correct deficiencies (usually an additional thirty (30) days), otherwise payment will be denied. If after subsequent request for payment has been denied and CONTRACTOR believes that payment should not be withheld, CONTRACTOR shall send written notice to LEA specifying the reason it believes payment should not be withheld. XXX shall respond to CONTRACTOR’s notice within thirty (30) business days by indicating that a warrant for the amount of payment will be made or stating the reason XXX believes payment should not be made. If XXX fails to respond within thirty (30) business days or a dispute regarding the withholding of payment continues after the LEA’s response to CONTRACTOR’s notice, CONTRACTOR may invoke the following escalation policy.
Right to Offset If We make a claim payment to You or on Your behalf in error or You owe Us any money, You must repay the amount You owe Us. Except as otherwise required by law, if We owe You a payment for other claims received, We have the right to subtract any amount You owe Us from any payment We owe You.