Right to Make Agreement Each party warrants, with respect to itself, that neither the execution of this Agreement, nor the consummation of any transaction contemplated hereby, shall violate any provision of any law, or any judgment, writ, injunction, order or decree of any court or governmental authority having jurisdiction over it; nor result in or constitute a breach or default under any indenture, contract, other commitment or restriction to which it is a party or by which it is bound; nor require any consent, vote or approval which has not been given or taken, or at the time of the transaction involved shall not have been given or taken. Each party covenants that it has and will continue to have throughout the term of this Agreement and any extensions thereof, the full right to enter into this Agreement and perform its obligations hereunder.
Right to Lease Landlord reserves the absolute right to effect such other tenancies in the Project as Landlord in the exercise of its sole business judgment shall determine to best promote the interests of the Building or Project. Tenant does not rely on the fact, nor does Landlord represent, that any specific tenant or type or number of tenants shall, during the Lease Term, occupy any space in the Building or Project.
RIGHT TO MORTGAGE Landlord reserves the right to mortgage or otherwise place a lien on the Property and Tenant agrees to accept the Property subject and subordinate to any such mortgage or lien. Tenant hereby grants power of attorney to Landlord for the sole and limited purpose of executing and delivering any document required in the name of Tenant for any such mortgage or lien.
Landlord’s Right To Mortgage Tenant agrees to accept the premises subject to and subordinate to any existing or future mortgage or other lien, and Landlord reserves the right to subject premises to same. Tenant agrees to and hereby irrevocably grants Landlord power of attorney for Tenant for the sole purpose of executing and delivering in the name of the Tenant any document(s) related to the Landlord’s right to subject the premises to a mortgage or other lien.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
Our Right to Make Payments and Recover Overpayments If payments which should have been made by us according to this provision have actually been made by another organization, we have the right to pay those organizations the amounts we decide are necessary to satisfy the rules of this provision. These amounts are considered benefits provided under this plan and we will not have to pay those amounts again. If we make payments for allowable expenses, which are more than the maximum amount needed to satisfy the conditions of this provision, we have the right to recover the excess amounts from: • the person to or for whom the payments were made; • any other insurers; and/or • any other organizations (as we decide). As the subscriber, you agree to pay back any excess amount paid, provide information and assistance, or do whatever is necessary to aid in the recovery of this excess amount. The amount of payments made includes the reasonable cash value of any
SUBLETTING OR ASSIGNING THE CONTRACT This provision is applicable to all Federal-aid construction contracts on the National Highway System.
1. The contractor shall perform with its own organization contract work amounting to not less than 30 percent (or a greater percentage if specified elsewhere in the contract) of the total original contract price, excluding any specialty items designated by the contracting agency. Specialty items may be performed by subcontract and the amount of any such specialty items performed may be deducted from the total original contract price before computing the amount of work required to be performed by the contractor's own organization (23 CFR 635.116).
a. The term “perform work with its own organization” refers to workers employed or leased by the prime contractor, and equipment owned or rented by the prime contractor, with or without operators. Such term does not include employees or equipment of a subcontractor or lower tier subcontractor, agents of the prime contractor, or any other assignees. The term may include payments for the costs of hiring leased employees from an employee leasing firm meeting all relevant Federal and State regulatory requirements. Leased employees may only be included in this term if the prime contractor meets all of the following conditions:
(1) the prime contractor maintains control over the supervision of the day-to-day activities of the leased employees;
(2) the prime contractor remains responsible for the quality of the work of the leased employees;
(3) the prime contractor retains all power to accept or exclude individual employees from work on the project; and
(4) the prime contractor remains ultimately responsible for the payment of predetermined minimum wages, the submission of payrolls, statements of compliance and all other Federal regulatory requirements.
b. Specialty Items" shall be construed to be limited to work that requires highly specialized knowledge, abilities, or equipment not ordinarily available in the type of contracting organizations qualified and expected to bid or propose on the contract as a whole and in general are to be limited to minor components of the overall contract.
2. The contract amount upon which the requirements set forth in paragraph (1) of Section VI is computed includes the cost of material and manufactured products which are to be purchased or produced by the contractor under the contract provisions.
3. The contractor shall furnish (a) a competent superintendent or supervisor who is employed by the firm, has full authority to direct performance of the work in accordance with the contract requirements, and is in charge of all construction operations (regardless of who performs the work) and (b) such other of its own organizational resources (supervision, management, and engineering services) as the contracting officer determines is necessary to assure the performance of the contract.
4. No portion of the contract shall be sublet, assigned or otherwise disposed of except with the written consent of the contracting officer, or authorized representative, and such consent when given shall not be construed to relieve the contractor of any responsibility for the fulfillment of the contract. Written consent will be given only after the contracting agency has assured that each subcontract is evidenced in writing and that it contains all pertinent provisions and requirements of the prime contract.
5. The 30% self-performance requirement of paragraph (1) is not applicable to design-build contracts; however, contracting agencies may establish their own self-performance requirements.
LANDLORD'S RIGHT TO INSPECT Tenant shall permit Landlord and its authorized representatives to inspect the Leased Property, or any portion thereof, during usual business hours upon not less than forty-eight (48) hours’ notice and to make such repairs as Landlord is permitted or required to make pursuant to the terms of this Agreement, provided that any inspection or repair by Landlord or its representatives will not unreasonably interfere with Tenant’s use and operation of the Leased Property and further provided that in the event of an emergency, as determined by Landlord in its reasonable discretion, prior Notice shall not be necessary.
Lessor’s Right to Inspect Lessee shall permit Lessor and its authorized representatives as frequently as reasonably requested by Lessor to inspect the Leased Property and Lessee’s accounts and records pertaining thereto and make copies thereof, during usual business hours upon reasonable advance Notice, subject only to any business confidentiality requirements reasonably requested by Lessee.
HHS Right to Use Contractor agrees that HHS has the right to use, produce, and distribute copies of and to disclose to HHS employees, agents, and contractors and other governmental entities all or part of this Contract or any related Solicitation Response as HHS deems necessary to complete the procurement process or comply with state or federal laws.
