Standard Hazard Insurance and Flood Insurance Policies (a) For each Mortgage Loan, the Master Servicer shall enforce any obligation of the Servicers under the related Servicing Agreements to maintain or cause to be maintained standard fire and casualty insurance and, where applicable, flood insurance, all in accordance with the provisions of the related Servicing Agreements. It is understood and agreed that such insurance shall be with insurers meeting the eligibility requirements set forth in the applicable Servicing Agreement and that no earthquake or other additional insurance is to be required of any Mortgagor or to be maintained on property acquired in respect of a defaulted loan, other than pursuant to such applicable laws and regulations as shall at any time be in force and as shall require such additional insurance.
(b) Pursuant to Section 4.01 and 4.02, any amounts collected by the Servicers or the Master Servicer, or by any Servicer, under any insurance policies (other than amounts to be applied to the restoration or repair of the property subject to the related Mortgage or released to the Mortgagor in accordance with the applicable Servicing Agreement) shall be deposited into the Master Servicer Collection Account, subject to withdrawal pursuant to Section 4.02 and 4.03. Any cost incurred by the Master Servicer or any Servicer in maintaining any such insurance if the Mortgagor defaults in its obligation to do so shall be added to the amount owing under the Mortgage Loan where the terms of the Mortgage Loan so permit; provided, however, that the addition of any such cost shall not be taken into account for purposes of calculating the distributions to be made to Certificateholders and shall be recoverable by the Master Servicer or such Servicer pursuant to Section 4.02 and 4.03.
Standard Hazard and Flood Insurance Policies For each Mortgage Loan (other than a Cooperative Loan), the Master Servicer shall maintain, or cause to be maintained by each Servicer, standard fire and casualty insurance and, where applicable, flood insurance, all in accordance with the provisions of this Agreement and the related Servicing Agreement, as applicable. It is understood and agreed that such insurance shall be with insurers meeting the eligibility requirements set forth in the applicable Servicing Agreement and that no earthquake or other additional insurance is to be required of any Mortgagor or to be maintained on property acquired in respect of a defaulted loan, other than pursuant to such applicable laws and regulations as shall at any time be in force and as shall require such additional insurance. Pursuant to Section 4.01, any amounts collected by the Master Servicer, or by any Servicer, under any insurance policies maintained pursuant to this Section 9.16 or any Servicing Agreement (other than amounts to be applied to the restoration or repair of the property subject to the related Mortgage or released to the Mortgagor in accordance with the applicable Servicing Agreement) shall be deposited into the Collection Account, subject to withdrawal pursuant to Section 4.02. Any cost incurred by the Master Servicer or any Servicer in maintaining any such insurance if the Mortgagor defaults in its obligation to do so shall be added to the amount owing under the Mortgage Loan where the terms of the Mortgage Loan so permit; provided, however, that the addition of any such cost shall not be taken into account for purposes of calculating the distributions to be made to Certificateholders and shall be recoverable by the Master Servicer or such Servicer pursuant to Section 4.02.
Maintenance of Mortgage Impairment Insurance Policy In the event that the Servicer shall obtain and maintain a blanket policy issued by an insurer that has a general policy rating of B:VI or better in Best's Key Rating Guide insuring against hazard losses on all of the Mortgage Loans, then, to the extent such policy provides coverage in an amount equal to the amount required pursuant to Section 3.10 and otherwise complies with all other requirements of Section 3.10, it shall conclusively be deemed to have satisfied its obligations as set forth in Section 3.10, it being understood and agreed that such policy may contain a deductible clause, in which case the Servicer shall, in the event that there shall not have been maintained on the related Mortgaged Property or REO Property a policy complying with Section 3.10, and there shall have been a loss which would have been covered by such policy, deliver to the Trustee for deposit in the Distribution Account the amount not otherwise payable under the blanket policy because of such deductible clause, which amount shall not be reimbursable to the Servicer from the Trust Fund. In connection with its activities as servicer of the Mortgage Loans, the Servicer agrees to prepare and present, on behalf of the Trustee, claims under any such blanket policy in a timely fashion in accordance with the terms of such policy. Upon request of the Trustee, the Servicer shall cause to be delivered to the Trustee a certified true copy of such policy and a statement from the insurer thereunder that such policy shall in no event be terminated or materially modified without thirty days prior written notice to the Trustee.
Summary of Policy and Prohibitions on Procurement Lobbying Pursuant to State Finance Law §139-j and §139-k, this Contract includes and imposes certain restrictions on communications between OGS and a Vendor during the procurement process. A Vendor is restricted from making contacts from the earliest notice of intent to solicit offers/bids through final award and approval of the Procurement Contract by OGS and, if applicable, the Office of the State Comptroller (“restricted period”) to other than designated staff unless it is a contact that is included among certain statutory exceptions set forth in State Finance Law §139-j(3)(a). Designated staff, as of the date hereof, is identified in Appendix G, Contractor and OGS Information, or as otherwise indicated by OGS. OGS employees are also required to obtain certain information when contacted during the restricted period and make a determination of the responsibility of the Vendor pursuant to these two statutes. Certain findings of non-responsibility can result in rejection for contract award and in the event of two findings within a four-year period; the Vendor is debarred from obtaining governmental Procurement Contracts. Further information about these requirements can be found on the OGS website: xxxx://xxx.xxx.xx.xxx/aboutOgs/regulations/defaultSFL_139j-k.asp.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Maintenance of Primary Mortgage Insurance Policy; Claims With respect to each Mortgage Loan with a LTV in excess of 80%, the Seller shall promptly, without any cost to the Purchaser, maintain or cause the Mortgagor to maintain in full force and effect a Primary Mortgage Insurance Policy issued by a Qualified Insurer insuring the portion over 78% (or such other percentage in conformance with then current Fxxxxx Mae requirements) until terminated pursuant to the Homeowners Protection Act of 1988, 12 USC § 4901, et seq. or any other applicable federal, state or local law or regulation. In the event that such Primary Mortgage Insurance Policy shall be terminated other than as required by law, the Seller shall obtain from another Qualified Insurer a comparable replacement policy, with a total coverage equal to the remaining coverage of such terminated Primary Mortgage Insurance Policy. If the insurer shall cease to be a Qualified Insurer, the Seller shall obtain from another Qualified Insurer a replacement Primary Mortgage Insurance Policy. The Servicer shall not take any action which would result in noncoverage under any applicable Primary Mortgage Insurance Policy of any loss which, but for the actions of the Servicer would have been covered thereunder. In connection with any assumption or substitution agreement entered into or to be entered into pursuant to Subsection 11.18, the Seller shall promptly notify the insurer under the related Primary Mortgage Insurance Policy, if any, of such assumption or substitution of liability in accordance with the terms of such Primary Mortgage Insurance Policy and shall take all actions which may be required by such insurer as a condition to the continuation of coverage under such Primary Mortgage Insurance Policy. If such Primary Mortgage Insurance Policy is terminated as a result of such assumption or substitution of liability, the Seller shall obtain a replacement Primary Mortgage Insurance Policy as provided above. In connection with its activities as interim servicer, the Seller agrees to prepare and present or to assist the Purchaser in preparing and presenting, on behalf of itself and the Purchaser, claims to the insurer under any Primary Mortgage Insurance Policy in a timely fashion in accordance with the terms of such Primary Mortgage Insurance Policy and, in this regard, to take such action as shall be necessary to permit recovery under any Primary Mortgage Insurance Policy respecting a defaulted Mortgage Loan. Pursuant to Subsection 11.04, any amounts collected by the Seller under any Primary Mortgage Insurance Policy shall be deposited in the Custodial Account, subject to withdrawal pursuant to Subsection 11.05.
Maintenance of Hazard Insurance and Errors and Omissions and Fidelity Coverage (a) The Servicer shall cause to be maintained for each Mortgage Loan fire insurance with extended coverage on the related Mortgaged Property in an amount which is at least equal to the least of (i) the outstanding principal balance of such Mortgage Loan, (ii) the amount necessary to fully compensate for any damage or loss to the improvements that are a part of such property on a replacement cost basis and (iii) the maximum insurable value of the improvements which are a part of such Mortgaged Property, in each case in an amount not less than such amount as is necessary to avoid the application of any coinsurance clause contained in the related hazard insurance policy. The Servicer shall also cause to be maintained fire insurance with extended coverage on each REO Property in an amount which is at least equal to the lesser of (i) the maximum insurable value of the improvements which are a part of such property and (ii) the outstanding principal balance of the related Mortgage Loan at the time it became an REO Property, plus accrued interest at the Mortgage Rate and related Servicing Advances. The Servicer will comply in the performance of this Agreement with all reasonable rules and requirements of each insurer under any such hazard policies. Any amounts to be collected by the Servicer under any such policies (other than amounts required to be deposited in the Escrow Account and applied to the restoration or repair of the property subject to the related Mortgage or amounts to be released to the Mortgagor in accordance with the procedures that the Servicer would follow in servicing loans held for its own account, subject to the terms and conditions of the related Mortgage and Mortgage Note) shall be deposited in the Collection Account, subject to withdrawal pursuant to Section 3.11. Any cost incurred by the Servicer in maintaining any such insurance shall not, for the purpose of calculating distributions to the Trustee, be added to the unpaid principal balance of the related Mortgage Loan, notwithstanding that the terms of such Mortgage Loan so permit. It is understood and agreed that no earthquake or other additional insurance is to be required of any Mortgagor other than pursuant to such applicable laws and regulations as shall at any time be in force and as shall require such additional insurance. If the Mortgaged Property or REO Property is at any time in an area identified in the Federal Register by the Federal Emergency Management Agency as having special flood hazards and flood insurance has been made available, the Servicer will cause to be maintained a flood insurance policy in respect thereof. Such flood insurance shall be in an amount equal to the lesser of (i) the unpaid principal balance of the related Mortgage Loan and (ii) the maximum amount of such insurance available for the related Mortgaged Property under the national flood insurance program (assuming that the area in which such Mortgaged Property is located is participating in such program). In the event that the Servicer shall obtain and maintain a blanket policy with an insurer either (i) acceptable to Fannie Mae or Freddie Mac or (ii) having a general policy rating of A:VX xx xexxxr in Xxxx'x (or such other rating that is comparable to such rating) insuring against hazard losses on all of the Mortgage Loans, it shall conclusively be deemed to have satisfied its obligations as set forth in the first two sentences of this Section 3.13, it being understood and agreed that such policy may contain a deductible clause, in which case the Servicer shall, in the event that there shall not have been maintained on the related Mortgaged Property or REO Property a policy complying with the first two sentences of this Section 3.13, and there shall have been one or more losses which would have been covered by such policy, deposit to the Collection Account from its own funds the amount not otherwise payable under the blanket policy because of such deductible clause. In connection with its activities as administrator and servicer of the Mortgage Loans, the Servicer agrees to prepare and present, on behalf of itself and the Trustee, claims under any such blanket policy in a timely fashion in accordance with the terms of such policy.
(b) The Servicer shall keep in force during the term of this Agreement a policy or policies of insurance covering errors and omissions for failure in the performance of the Servicer's obligations under this Agreement, which policy or policies shall be in such form and amount that would meet the requirements of Fannie Mae or Freddie Mac if it were the purchaser of the Mortgage Loanx. Xxx Servicex xxxxx also maintain a fidelity bond in the form and amount that would meet the requirements of Fannie Mae or Freddie Mac, unless the Servicer has obtained a waiver of xxxx requiremxxxx xxom Fannie Mae or Freddie Mac. The Servicer shall provide the Trustee upon xxxxxxt with cxxxxx xf any such insurance policies and fidelity bond. The Servicer shall be deemed to have complied with this provision if an Affiliate of the Servicer has such errors and omissions and fidelity bond coverage and, by the terms of such insurance policy or fidelity bond, the coverage afforded thereunder extends to the Servicer. Any such errors and omissions policy and fidelity bond shall by its terms not be cancelable without thirty days' prior written notice to the Trustee. The Servicer shall also cause each Subservicer to maintain a policy of insurance covering errors and omissions and a fidelity bond which would meet such requirements.
General Policy Our policy is to make funds from your cash and check deposits available to you on the next business day after we receive your deposit. Electronic direct deposits will be available on the day we receive the deposit. Once they are available, you can withdraw the funds in cash and we will use the funds to pay checks that you have written. For determining the availability of your deposits, every day is a business day, except Saturdays, Sundays, and federal holidays. If you make a deposit before 6:00 p.m. within our facilities or through our ATM on a business day that we are open, we will consider that day to be the day of your deposit. However, if you make a deposit after 6:00 p.m. through our ATM or on a day we are not open, we will consider that the deposit was made on the next business day we are open.
Reinsurance Administration A. Within thirty (30) days after the end of each calendar month, the Cedent shall take all reasonable and appropriate steps to furnish the Reinsurer with a seriatim electronic report, as detailed in Schedule C, for each Reinsured Contract, valued as of the last day of that month. On or before September 30, 2001, the Cedent shall provide the initial seriatim electronic report, which shall cover the period from the Effective Date hereof through August 31, 2001; provided, however, that the initial seriatim electronic report may omit Funding Vehicle Values by MorningStar designation. The Cedent shall provide complete seriatim electronic data, as required herein, on or before April 30, 2002. Failure to provide this information as required shall constitute a material breach within the scope of Article XX, Paragraph G.
B. Additionally, within thirty (30) days after the end of each calendar month the Cedent shall furnish the Reinsurer with a separate Summary Statement containing the following:
1. Reinsurance Premiums due to the Reinsurer summarized separately for each premium class by GMDB, EPB, and Income Program, as shown in Exhibit II;
2. benefit claim recoverables due to the Cedent in total and, if applicable, broken down by VNAR, SCNAR, and EEMNAR and Income Program; and
3. the month end date for the period covered by the Summary Statement.
C. If the net balance is due to the Reinsurer, the Cedent shall remit the amount due with the Summary Statement, but no later than thirty (30) days after the month end date for the period covered by the Summary Statement. If the net balance is due to the Cedent, the Reinsurer shall remit the amount due to the Cedent within ten (10) days after receipt of the Summary Statement.
D. The payment of Reinsurance Premiums is a condition precedent to the liability of the Reinsurer under this Agreement. In the event that the Cedent does not pay the Reinsurance Premiums in a timely manner, as defined below, the Reinsurer may exercise the following rights:
1. The Reinsurer shall charge interest if Reinsurance Premiums are not paid within thirty (30) days of the due date, as defined in Paragraph C of this Article. The interest rate charged shall be based on the ninety-(90) day federal Treasury Xxxx, as published in The Wall Street Journal on the first business day in the month following the due date of the Reinsurance Premiums, plus one hundred (100) basis points. The method of calculation shall be simple interest (360-day year).
2. The Reinsurer may terminate this Agreement in the event that Reinsurance Premium payments are more than sixty (60) days past due after the due date, as described in Paragraph C of this Article, by giving sixty (60) day written notice of termination to the Cedent. As of the close of the last day of this sixty-(60) day notice period, the Reinsurer's liability with respect to the ceded liabilities shall terminate. If all Reinsurance Premiums that are the subject of a sixty (60) day termination notice shall have been received by the Reinsurer within the time specified, the termination notice shall be deemed vacated and the Agreement shall remain in effect.
Management; Community Policies Owner may retain employees and management agents from time to time to manage the Property, and Owner’s agent may retain other employees or contractors. Resident, on behalf of himself or herself and his or her Guests, agrees to comply fully with all directions from Owner and its employees and agents, and the rules and regulations (including all amendments and additions thereto, except those that substantially modify the Resident’s bargain and to which Resident timely objects) as contained in this Agreement and the Community Policies of the Property. The Community Policies are available at xxxxx://xxxxxxxxxxxxxx.xxx/policies.pdf or on request from the management office and are considered part of this Agreement.
